The following Act and amending Act have been published in the Federal Gazette:
|
|
- Anastasia Casey
- 5 years ago
- Views:
Transcription
1 Legal Updates June 2014 Legislation The following Act and amending Act have been published in the Federal Gazette: 1. Goods and Services Act 2014 [Act 762] An Act to provide for the imposition and collection of goods and services tax These two Acts will be repealed: Sales Tax Act 1972 [Act 64] Service Tax Act 1975 [Act 151] 2. Corrosive and Explosive Substances and Offensive Weapons (Amendment) Act 2014 [Act A1463] An Act to amend the Corrosive and Explosive Substances and Offensive Weapons Act 1958 Cases Bankruptcy Dato Ramesh a/l Rajaratnam v Datin Zaleha Abd Rahman & Ors [2014] 5 CLJ 669; [2014] AMEJ # 0658 (CA) Facts of Al-Rashidy Kassim & Ors v Rosman Roslan and that of present case have no resemblance to attract special circumstances concept JC wrong to rely on Kosma Palm Oil Mill Sdn & Ors v Koperasi Serbausaha Makmur Bhd in application of special circumstances concept The grounds of judgment may also be viewed here: For the High Court judgment, see [2014] 7 MLJ 192; [2013] 7 CLJ 468 Civil Procedure Yam Kong Seng & Anor v Yee Weng Kai [2014] 6 CLJ 285; [2014] AMEJ 0748; [2014] MLJU^ 476 (FC)
2 Clear judicial admission of debt owed Electronic message such as SMS, with all the attributes of s 8 Electronic Commerce Act 2006 (ECA) present, was as good as in writing Legal requirement for a signature was fulfilled as sender was adequately identified; electronic signature means any letter, character, number, sound or other symbol or any combination created in an electronic form adopted by a person as a signature: s 5 ECA Abdul Manaf Mohd Ghows & Ors v Nusantara Timur Sdn Bhd distinguished For the Court of Appeal decision, see [2013] 4 CLJ 493; [2013] 2 MLJ 575 Or see For the High Court grounds of judgment, see pdf Contract Boustead Naval Shipyard Sdn Bhd v Dynaforce Corporation Sdn Bhd [2014] 5 CLJ 533; [2014] AMEJ 0644 (CA) Exhibits taken collectively or individually did not create any assignment at all, and were far from perfect Elements of legal assignment not fulfilled; serious uncertainties with regard to nature of and parties to the assignment Terang Tanah Sdn Bhd & Anor v Chong Choy Lin Civil Appeal No W /2012 (CA) Sale and purchase agreement (SPA) terminated when purchaser rejected options offered, and had instead demanded compensation With termination of the SPA, purchaser could no longer invoke and rely on its terms to claim liquidated damages Allowing award of liquidated damages and one for general damages to be assessed tantamount to granting purchaser double relief Purchaser not entitled to claim for liquidated damages whether calculated up to date of termination of SPA or to date of expiry of 24 months from date of SPA in addition to general damages
3 The grounds of judgment may be viewed here: Bank Islam Malaysia Bhd v Aquasix Corporation Sdn Bhd & Ors [2014] 3 MLJ 812; [2014] 3 MLRA 449 (CA) Pleaded case different from that presented in court Issue of waiver should not be raised and considered by court judge in determining plaintiffs claim against defendant Judge erred in concluding defendant had already waived condition precedent The grounds of judgment may also be viewed here: PKNS Engineering & Construction Bhd v Global Inter-Dream (M) Sdn Bhd and another appeal [2014] AMCR ~ 883; [2014] 1 LNS 381; [2014] AMEJ 0504 (CA) Trial judge erred in first finding that PKNS unit owed a duty to produce Method Statement of works and that failure to do so was the cause behind main subcontractor s delay in completing project including showroom unit Main sub-contractor had to prove but failed that termination of its contract was unlawful because it ought to have been granted extension of time to complete project Trial judge erred in the reasons advanced in judgment leading to the finding that it was the conduct of PKNS unit that caused main sub-contractor to be behind schedule pdf Tan Sri Halim Saad v Tan Sri Nor Mohamed Yakcop & Ors [2014] AMCR 978; [2014] 4 CLJ 232 (HC) Cause of action of fraud untenable, tycoon had no basis to rely on s 29 Limitation Act 1953 See also
4 Intellectual Property Vision Cast Sdn Bhd & Anor v Dynacast (Melaka) Sdn Bhd & Ors Civil Appeal No J /2011 (CA) Trial judge s observations and conclusions were without proper and sufficient appreciation of totality of evidence before court Had omitted or overlooked agreed 12 months extent of any restraint between the parties if at all that was enforceable and valid Had misdirected herself on relevant law governing controversy between parties Incomprehensible how trial judge could have reached conclusion that there had been poaching of customers Trial judge right in holding mere calling of a witness from agency not sufficient to prove ownership of copyright to images/photographs in question The grounds of decision may be viewed here: Lee Chye Yen (t/a Ebiz Solution Network ) v EoneNet.Com Sdn Bhd [2014] 3 MLRA 468; [2014] AMEJ 0217; [2013] MLJU 1429; [2013] 1 LNS * 1241 (CA) Judge erred in admitting statutory declaration tendered under s 42 Copyright Act 1987 and in allowing company s claim against sisters Land Law The State Government of Sarawak & Ors v Teo Soo Chuan [2014] 5 CLJ 68; [2014] 4 MLJ 114; [2014] AMEJ 0226 (CA) Deeds signified grantor had granted a right of way in the nature of an easement to the grantees and their successors in title Right of way was granted over whole of Lot 27 for as long as dominant tenements needed it Only right reserved by grantor over Lot 27 was a right of way for himself and all others lawfully using the same from time to time Quality of the right of way as improved benefited all parties
5 For the High Court decision, see [2012] 7 CLJ 777 Or see Maybank Islamic Bhd lwn Azirairil Jahabarsadiqe Abdul Rahman [2014] 3 MLJ 635; [2014] 3 MLRA 477; [2014] 1 LNS 129 (MR) HC judge erred in setting aside public auction that had been carried out Also failed to consider and scrutinise HC order as well as sale declaration that clearly stated where the auction was to be conducted, ie at the High Court compound in line with s 6 Auction Sales Enactment FMS Cap 81 (No 2 of 1929) The judgment (in BM) may also be viewed here: Moneylending Lo Ga Lung v Diong Ching Diung [2014] 3 MLRA 565; [2014] 1 LNS 390 (CA) Trial judge had misconstrued s 3 Moneylenders Ordinance (Sarawak) (Cap 114) to extent of rendering debt documents as void, when in fact s 3 only has the limited effect of prohibiting admissibility of the impugned debt documents as evidence in court Tort RHB Bank Bhd v Moon Trading Sdn Bhd [2014] 5 CLJ 443 (CA) HC erred in allowing claim for defamation against RHB when it was Citibank, and not RHB, that published the defamatory statement; RHB could not be held vicariously liable for statement, nor was it liable for defamation just by entering wrong code Wrong for High Court to equate RHB as master and Citibank as RHB s servant, and, consequently, find RHB vicariously liable Words complained of did not have the meaning ascribed by Moon Trading either in its pleading or in its evidence; words not reasonably capable of bearing a meaning defamatory of Moon Trading
6 For the High Court decision, see [2012] 6 MLJ 271 ~ All Malaysia Commercial Reports Monthly publication of High Court and appellate court decisions on commercial law # All Malaysia Electronic Judgments Cases which have not been reported in All Malaysia Reports * Legal Network Series Cases available on the Current Law Journal website but which have not been published in CLJ ^ Malayan Law Journal Unreported Cases available on the LexisNexis website but which have not been published in MLJ Malaysian Law Review (Appellate Courts) Cases from the Court of Appeal and the Federal Court Compiled by knowledge@lh-ag.com Lee Hishammuddin Allen & Gledhill. All Rights Reserved. DISCLAIMER: The views and opinions attributable to the editors of this newsletter are not to be imputed to the firm, Lee Hishammuddin Allen & Gledhill. The contents are intended for general information only, and should not be constructed as legal advice or legal opinion. The firm bears no responsibility for any loss that might occur from reliance on information contained in this newsletter. It is sent to you as a client of or a person with whom Lee Hishammuddin Allen & Gledhill has professional dealings. Please do not reproduce, transmit or distribute the contents therein in any form, or by any means, without prior permission from the firm.
Minister of Human Resources, Malaysia v Diamet Klang (Malaysia) Sdn Bhd and another appeal [2015] 2 AMR 659; [2013] 1 LNS * 1466 (CA)
Legal Updates April 2015 Cases Administrative Law Minister of Human Resources, Malaysia v Diamet Klang (Malaysia) Sdn Bhd and another appeal [2015] 2 AMR 659; [2013] 1 LNS * 1466 (CA) Whether (i) minister
More informationThe following amending Act came into force on 20 February 2015:
Legal Updates February 2015 Legislation The following amending Act came into force on 20 February 2015: Companies Commission of Malaysia (Amendment) Act 2015 [Act A1478], except sections 9-11, 13-15 [PU(B)
More informationMajlis Perbandaran Subang Jaya v Laguna De Bay Sdn Bhd Civil Appeal No B /2013 (CA)
Legal Updates November 2014 Cases Administrative Law Majlis Perbandaran Subang Jaya v Laguna De Bay Sdn Bhd Civil Appeal No B-01-162-04/2013 (CA) Assignment in s 68 National Land Code 1965 (NLC) has nothing
More informationMalaysia Airline System Bhd v Wan Sa Syed Sa adi Wan Mustafa Civil Appeal No 02(f)-15-04/2013 (N) (FC)
Legal Updates December 2014 Cases Administrative Law Malaysia Airline System Bhd v Wan Sa adi @ Syed Sa adi Wan Mustafa Civil Appeal No 02(f)-15-04/2013 (N) (FC) Award of Industrial Court restored Industrial
More informationLegal Aspects of Islamic Finance LCA4592 DR. ZULKIFLI HASAN
Legal Aspects of Islamic Finance LCA4592 DR. ZULKIFLI HASAN Contents n Islamic finance cases n 1987-2002 n 2003-2007 n 2008-2011 1987-2002 n Tinta Press Sdn Berhad v BIMB (1987) 1 MLJ 474; 1 CLJ 474: IJarah
More informationLegal Herald. Is a Cross-Appeal Not an Appeal?
Legal Herald JULY 2017 1. Is a Cross-Appeal Not an Appeal? 11. REITs and Leases 15. Entering the Third Dimension 20. Principles of Conflict of Interest 26. Partner Profile in this issue Is a Cross-Appeal
More informationFor the appellants Lim Kian Leong (Tony Ng TT, Keith Kwan & Rachel Tan Pak Theen with him); M/s Mohd Zain & Co
NGAN & NGAN HOLDINGS SDN BHD & ANOR v. CENTRAL MERCANTILE CORPORATION (M) SDN BHD [2010] 3 CLJ 818 COURT OF APPEAL, PUTRAJAYA HELILIAH MOHD YUSOF JCA, KN SEGARA JCA, RAMLY ALI JCA [CIVIL APPEAL NO: W-02-85-2007]
More informationMALAYSIA IN THE HIGH COURT IN SABAH AND SARAWAK AT FEDERAL TERRITORY, LABUAN. CIVIL CASE NO: LBN-24NCvC-6/ BETWEEN SEJATI SDN. BHD..
MALAYSIA IN THE HIGH COURT IN SABAH AND SARAWAK AT FEDERAL TERRITORY, LABUAN CIVIL CASE NO: LBN-24NCvC-6/8-2016 BETWEEN SEJATI SDN. BHD.. PLAINTIFF AND DIRECTOR OF LANDS AND SURVEYS.. 1 ST DEFENDANT SABAH
More informationd) To introduce a new Part on Anti-Camcording to combat camcording activities in a place for the screening of any film or cinematography.
COPYRIGHT COMMITTEE REPORT MALAYSIA 1. Proposals for Changes in Copyright Law in Malaysia There have been proposals to amend the Copyright Act and comments have been given by stakeholders to the proposed
More information10th Anniversary Edition The Baker McKenzie International Arbitration Yearbook. Malaysia
10th Anniversary Edition 2016-2017 The Baker McKenzie International Arbitration Yearbook Malaysia 2017 Arbitration Yearbook Malaysia Malaysia Elaine Yap 1 A. Legislation and rules A.1 Legislation Arbitration
More informationINDUSTRIAL COURT OF MALAYSIA CASE NO : 2/4-346/15 BETWEEN MOHAMED HASLAM BIN ABDUL RAZAK AND PERUSAHAAN OTOMOBIL NASIONAL SDN BHD
INDUSTRIAL COURT OF MALAYSIA CASE NO : 2/4-346/15 BETWEEN MOHAMED HASLAM BIN ABDUL RAZAK AND PERUSAHAAN OTOMOBIL NASIONAL SDN BHD AWARD NO. 552 OF 2018 Before : Y.A. PUAN ROSENANI BINTI ABD RAHMAN - Chairman
More informationREFERENCE TO THE SHARI AH ADVISORY COUNCIL IN ISLAMIC FINANCE : PRELIMINARY ANALYSIS ON CIVIL COURT DECISIONS
REFERENCE TO THE SHARI AH ADVISORY COUNCIL IN ISLAMIC FINANCE : PRELIMINARY ANALYSIS ON CIVIL COURT DECISIONS Surianom Miskam surianom@kuis.edu.my Noor Aimi Mohamad Puad nooraimi@kuis.edu.my Nurauliani
More informationWong Kian Wah v Ng Kien Boon
IN THE COURT OF APPEAL OF MALAYSIA Coram: Hamid Sultan Abu Backer, JCA; Abdul Rahman Sebli, JCA; Mary Lim, JCA Wong Kian Wah v Ng Kien Boon Citation: [2018] MYCA 230 Suit Number: Civil Appeal No. W 02(NCVC)(W)
More informationIN THE FEDERAL COURT OF MALAYSIA (APPELLATE JURISDICTION) CIVIL APPEAL NO: 01(i)-15-04/2014(C) BETWEEN SERUAN GEMILANG MAKMUR SDN BHD AND SUMMARY
IN THE FEDERAL COURT OF MALAYSIA (APPELLATE JURISDICTION) CIVIL APPEAL NO: 01(i)-15-04/2014(C) BETWEEN SERUAN GEMILANG MAKMUR SDN BHD.. APPELLANT AND 1. KERAJAAN NEGERI PAHANG DARUL MAKMUR 2. PENGARAH
More informationPRIVACY ISSUES IN THE ASIA PACIFIC REGION: THE IMPACT OF THE PERSONAL DATA PROTECTION ACT 2010 ON PRIVACY LAWS IN MALAYSIA
PRIVACY ISSUES IN THE ASIA PACIFIC REGION: THE IMPACT OF THE PERSONAL DATA PROTECTION ACT 2010 ON PRIVACY LAWS IN MALAYSIA 28 TH LAWASIA CONFERENCE Sydney, Australia 9 November 2015 Adlin Abdul Majid Content
More informationMALAYSIA IN THE HIGH COURT IN SABAH AND SARAWAK AT KUCHING SUIT NO II BETWEEN AND
MALAYSIA IN THE HIGH COURT IN SABAH AND SARAWAK AT KUCHING SUIT NO. 22-74-08-II BETWEEN CMS ENERGY SDN BHD (Company No.34309-A) Level 6, Wisma Mahmud Jalan Sungai Sarawak 930 Kuching, Sarawak Plaintiff
More informationJUDGMENT. Low Hop Bing JCA:
DANCOM TELECOMMUNICATION (M) SDN BHD v. UNIASIA GENERAL INSURANCE BHD COURT OF APPEAL, PUTRAJAYA LOW HOP BING JCA, HELILIAH YUSOF JCA, ABDUL MALIK ISHAK JCA [CIVIL APPEAL NO: W-02-259-2005] 1 AUGUST 2008
More informationIN THE HIGH COURT OF MALAYA IN KUALA LUMPUR (COMMERCIAL DIVISION) IN THE FEDERAL TERRITORY OF KUALA LUMPUR, MALAYSIA WRIT NO: 22IP-29-06/2015 BETWEEN
IN THE HIGH COURT OF MALAYA IN KUALA LUMPUR (COMMERCIAL DIVISION) IN THE FEDERAL TERRITORY OF KUALA LUMPUR, MALAYSIA WRIT NO: 22IP-29-06/2015 BETWEEN 1) WORLD GRAND DYNAMIC MARKETING SDN BHD (Company No
More informationMehrzad Nabavieh & Anor v Chong Shao Fen & Anor and Another Appeal
Mehrzad Nabavieh & Anor v Chong Shao Fen & Anor and Another Appeal COURT OF APPEAL, PUTRAJAYA CIVIL APPEALS NOs: W 02 (NCVC) (W) 1698 07/2013 & W 0 2(NCVC) (W) 1699 07/2013 ALIZATUL KHAIR OSMAN JCA, LIM
More informationThe Companies Bill Revamping the Companies Act December LEE SHIH & SHEBA GUMIS
1 The Companies Bill 2013- Revamping the Companies Act 1965 17 December 2013 - LEE SHIH & SHEBA GUMIS SUMMARY OF PART TWO Company Secretaries Meetings and Written Resolutions Issues Relating to Directors
More informationCASE SUMMARY by Alliff Benjamin Suhaimi
CASE SUMMARY by Alliff Benjamin Suhaimi Recognition of Common Law defences in defamation claims in Malaysia: Reynolds Privilege and Lucas Box Federal Court Civil Appeal No.: 02(f)- 31-03/2014(W) : Syarikat
More informationESSENTIALS OF EMPLOYMENT LAW MALAYSIA & ASIA Topic: MALAYSIAN EMPLOYMENT & INDUSTRIAL LAW : BRIEF OVERVIEW AND SPECIFIC INSIGHTS
ESSENTIALS OF EMPLOYMENT LAW MALAYSIA & ASIA 2008 Topic: MALAYSIAN EMPLOYMENT & INDUSTRIAL LAW : BRIEF OVERVIEW AND SPECIFIC INSIGHTS 2008 All Rights Reserved. Trevor George De Silva. 1 Malaysian Employment
More informationCOMPOUNDED INTEREST IN FATAL ACCIDENT AND PERSONAL INJURY CLAIMS IN MALAYSIA: THE DEPARTURE FROM THE TRADITIONAL APPROACH
COMPOUNDED INTEREST IN FATAL ACCIDENT AND PERSONAL INJURY CLAIMS IN MALAYSIA: THE DEPARTURE FROM THE TRADITIONAL APPROACH Nazli Mahdzir School of Law, UUM COLGIS, Sintok, Malaysia, mnazli@uum.edu.my Abstract
More informationJUDGMENT (Court enclosure no. 4)
IN THE HIGH COURT OF MALAYA AT KUALA LUMPUR (COMMERCIAL DIVISION) IN THE FEDERAL TERRITORY OF KUALA LUMPUR, MALAYSIA CIVIL SUIT NO: WA-22IP-37-09/2017 BETWEEN DARUL FIKIR (Business Registration No.: 000624088-H)
More informationPilecon Engineering Bhd ABDUL KADIR SULAIMAN, JCA ARIFIN ZAKARIA, JCA NIK HASHIM NIK AB. RAHMAN, JCA 23 FEBRUARY 2007
COURT OF APPEAL, MALAYSIA Bintulu Development Authority - vs - Coram Pilecon Engineering Bhd ABDUL KADIR SULAIMAN, JCA ARIFIN ZAKARIA, JCA NIK HASHIM NIK AB. RAHMAN, JCA 23 FEBRUARY 2007 Judgment of the
More informationCOURT OF APPEAL, MALAYSIA Thye Hin Enterprises Sdn Bhd - vs - Daimlerchrysler
Coram COURT OF APPEAL, MALAYSIA Thye Hin Enterprises Sdn Bhd - vs - Daimlerchrysler MOHD GHAZALI JCA NIK HASHIM JCA H.B. LOW J 28 JULY 2004 Judgment Mohd Ghazali JCA (delivering the judgment of the court)
More informationMALAYSIA COUNTRY REPORT FOR APAA 2015 TRADE MARK COMMITTEE DEVELOPMENTS:- Legislative
(I) (i) MALAYSIA COUNTRY REPORT FOR APAA 2015 TRADE MARK COMMITTEE DEVELOPMENTS:- Legislative There was no recent development or change in the Malaysian Trade Marks Act (ii) Other The ASEAN TMview website
More informationARTIST & AGENT AGREEMENT FOR SASKATCHEWAN VISUAL ARTISTS
ARTIST & AGENT AGREEMENT FOR SASKATCHEWAN VISUAL ARTISTS FOR USE WITH COMMERCIAL GALLERIES, DEALERS, AGENTS (REV 2010-05) Background In May 2009, the Saskatchewan government passed a new law called The
More informationEnforceable Contracts: Intention To Create Legal Relations
1194 Entrepreneurship Vision 2020: Innovation, Development Sustainability, and Economic Growth Enforceable Contracts: Intention To Create Legal Relations Nik Malini Nik Mahdi, Universiti Malaysia Kelantan,
More informationCURRENT APPLICATION OF ENGLISH LAW: SECTIONS 3, 5 AND 6 OF THE CIVIL LAW ACT
155 CHAPTER 09 CURRENT APPLICATION OF ENGLISH LAW: SECTIONS 3, 5 AND 6 OF THE CIVIL LAW ACT 1956 1 9.1 INTRODUCTION Malaysia is a common law country with a distinct common law-based legal system. The Malaysian
More informationAPPLICATION OF ENGLISH LAW IN MALAYSIA 3.1Introduction The application of English Law in Malaysia is restricted under the Civil law Act 1956.
APPLICATION OF ENGLISH LAW IN MALAYSIA 3.1Introduction The application of English Law in Malaysia is restricted under the Civil law Act 1956. The common law of English and rules of equity is only applicable
More informationCOMPANY LAW CIVIL PROCEDURE Held: [1] [2]
1 TAN SRI ABDUL AZIZ ZAIN & ORS v. UNITED OVERSEAS LAND LTD & ORS HIGH COURT MALAYA, PULAU PINANG ABDUL HAMID MOHAMAD J CIVIL SUIT NO: 22-265-95 12 OCTOBER 1998 [1998] 4 CLJ 321 COMPANY LAW: Suit by Company
More informationLaw of Arbitration DR. ZULKIFLI HASAN
Law of Arbitration DR. ZULKIFLI HASAN Content Award Extension of time for making an award Enforcement of Award Award AA 1952 and UNCITRAL Model Law do not ascribe any meaning to the term award. S-1: A
More informationDALAM MAHKAMAH RAYUAN MALAYSIA (BIDANGKUSASA RAYUAN) RAYUAN SIVIL NO: W
DALAM MAHKAMAH RAYUAN MALAYSIA (BIDANGKUSASA RAYUAN) RAYUAN SIVIL NO: W-02-2133-2011 ANTARA BOUNTY DYNAMICS SDN BHD (dahulunya dikenali sebagai MEDA DEVELOPMENT SDN BHD) PERAYU DAN CHOW TAT MING DAN 175
More informationAGREEMENT FOR KIB KENANGA AGENCY NETWORK SERVICE
Kenanga Investors Berhad (Co. No. 353563-P) Suite 12.02, 12th Floor Kenanga International Jalan Sultan Ismail 50250 Kuala Lumpur Tel No. : 03-2057 3688 Fax No. : 03-2126 8807 Toll Free: 1-800-88-3737 AGREEMENT
More informationBETWEEN. LAI CHENG OOI (f) (the executrix of the estate of Lee Tain Lee Thien Chiung, deceased) AND
IN THE COURT OF APPEAL, MALAYSIA AT PUTRAJAYA (APPELLATE JURISDICTION) CIVIL APPEAL NO. S-01(IM)(NCVC)-145-04/2016 [Kota Kinabalu High Court OS No. BKI-24NCVC-44/5-2015] BETWEEN LAI CHENG OOI (f) (the
More informationIN THE HIGH COURT OF MALAYA IN SHAH ALAM IN THE STATE OF SELANGOR DARUL EHSAN, MALAYSIA SUMMONS WRIT NO: BETWEEN AND
IN THE HIGH COURT OF MALAYA IN SHAH ALAM IN THE STATE OF SELANGOR DARUL EHSAN, MALAYSIA SUMMONS WRIT NO: 22-753-2005 BETWEEN WING FAH ENTERPRISE SDN BHD PLAINTIFF AND MATSUSHITA ELECTRONIC COMPONENTS (M)
More informationNOTICE OF THE 19 TH ANNUAL GENERAL MEETING
NOTICE IS HEREBY GIVEN THAT the 19 th Annual General Meeting (AGM) of Malaysia Airports Holdings Berhad (MAHB or the Company) will be held at Gateway Ballroom, Level 1, Sama-Sama Hotel, KL International
More informationAmendment to Program Information
Amendment to Program Information AMENDMENT TO PROGRAM INFORMATION Type of Information: Amendment to Program Information Date of Announcement: 20 May 2016 Issuer Name: Name and Title of Representative:
More informationPROCEDURAL ASPECTS OF CLASS LITIGATION IN BRUNEI DARUSSALAM
PROCEDURAL ASPECTS OF CLASS LITIGATION IN BRUNEI DARUSSALAM MOHD SHAZALE HAJI MAT SALLEH Advocate & Solicitor Supreme Court of Brunei Darussalam INTRODUCTION The class litigation or class action as it
More informationIN THE KUALA LUMPUR REGIONAL CENTRE FOR ARBITRATION BETWEEN CHELSEA TEA COMPANY (CTC) (CLAIMANT) AND ALMOND TEA COMPANY (ATC) (RESPONDENT)
1026 - R THE 11 TH LAWASIA INTERNATIONAL MOOT COMPETITION IN THE KUALA LUMPUR REGIONAL CENTRE FOR ARBITRATION 2016 BETWEEN CHELSEA TEA COMPANY (CTC) (CLAIMANT) AND ALMOND TEA COMPANY (ATC) (RESPONDENT)
More informationPLAINTIFFS' SKELETAL SUBMISSIONS (CROSS-EXAMINATION)
IN THE HIGH COURT OF MALAYA AT KUALA LUMPUR (CIVIL DIVISION) CIVIL SUIT NO. S2-23 - 38-2006 BETWEEN 1. SARAWAK SHELL BHD (71978-W) 2. SHELL MALAYSIA TRADING SENDIRIAN BERHAD (6078-M) 3. SHELL REFINING
More informationCHEMICAL COMPANY OF MALAYSIA BERHAD (5136-T)
CHEMICAL COMPANY OF MALAYSIA BERHAD (5136-T) (Incorporated in Malaysia) SUMMARY OF THE 55 th ANNUAL GENERAL MEETING HELD AT JUNIOR BALLROOM, INTERCONTINENTAL KUALA LUMPUR, 165 JALAN AMPANG, 50450 KUALA
More informationA guide to civil litigation and arbitration in Hong Kong, from a Mainland perspective
A guide to litigation and arbitration in Hong Kong October 12014 A guide to civil litigation and arbitration in Hong Kong, from a Mainland perspective 1. Brief description of the civil litigation process
More informationDALAM MAHKAMAH PERSEKUTUAN MALAYSIA (BIDANGKUASA RAYUAN) RAYUAN SIVIL NO (P) ANTARA
DALAM MAHKAMAH PERSEKUTUAN MALAYSIA (BIDANGKUASA RAYUAN) RAYUAN SIVIL NO. 02-4-2004(P) ANTARA 1. JOCELINE TAN POH CHOO 2. THE GROUP EDITOR, NEW STRAITS TIMES 3. THE NEW STRAITS TIMES PRESS (M) BHD Perayu-
More informationView Esteem Sdn Bhd v Bina Puri Holdings Bhd*
CIDB Construction Law Report 2016 View Esteem Sdn Bhd v Bina Puri Holdings Bhd* COURT OF APPEAL, PUTRAJAYA CIVIL APPEAL NO: W 02(C)(A) 1507 09/2015 HAMID SULTAN BIN ABU BACKER JCA, PRASAD SANDOSHAM ABRAHAM
More informationCONSULTANCY SERVICES AGREEMENT
DATED 2010 [INSERT NAME OF CUSTOMER] (Customer) CAVALLINO HOLDINGS PTY LIMITED ACN 136 816 656 ATF THE DAYTONA DISCRETIONARY TRUST T/A INSIGHT ACUMEN (Consultant) CONSULTANCY SERVICES AGREEMENT Suite 5,
More informationNATIVE CUSTOMARY RIGHST (NCR) OVER LAND IN SARAWAK, MALAYSIA. By Baru Bian Advocate & Solicitor High Court, of Sarawak & Sabah MALAYSIA
NATIVE CUSTOMARY RIGHST (NCR) OVER LAND IN SARAWAK, MALAYSIA By Baru Bian Advocate & Solicitor High Court, of Sarawak & Sabah MALAYSIA 1. Native Customary Right (NCR), legal definition and recognition.
More informationExhibit G HKSAR Companies Ordinance, Cap 32 (full text)
FILED: NEW YORK COUNTY CLERK 09/18/2015 02:41 PM INDEX NO. 654290/2013 NYSCEF DOC. NO. 69 RECEIVED NYSCEF: 09/18/2015 Exhibit G HKSAR Companies Ordinance, Cap 32 (full text) Chapter: 32 COMPANIES ORDINANCE
More informationIN THE COURT OF APPEAL, MALAYSIA (APPELLATE JURISDICTION) SITTING AT KUCHING, SARAWAK CIVIL APPEAL NO. Q /2013. Appellant YUNG ING ING
IN THE COURT OF APPEAL, MALAYSIA (APPELLATE JURISDICTION) SITTING AT KUCHING, SARAWAK CIVIL APPEAL NO. Q-02-2628-12/2013 Appellant YUNG ING ING v. Respondent HUNFARA CONSTRUCTION SDN. BHD. [In the matter
More informationProceedings of INTCESS th International Conference on Education and Social Sciences 6-8 February Istanbul, Turkey
ARRESTING THE MALAYSIAN JUDICIARY S AMBIVALENT SYNDROME CONCERNING THE QUANTUM OF PROOF IN ALLEGATIONS OF FRAUD IN CIVIL CASES IN THE INTEREST OF CERTAINTY IN THE LAW Mohd Akram Shair Mohamed 1 * Ashgar
More informationIN THE FEDERAL COURT OF MALAYSIA (APPELLATE JURISDICTION) CIVIL APPEAL NO. 02(f)-31-03/2014 (W) BETWEEN SYARIKAT BEKALAN AIR SELANGOR SDN BHD AND
IN THE FEDERAL COURT OF MALAYSIA (APPELLATE JURISDICTION) CIVIL APPEAL NO. 02(f)-31-03/2014 (W) BETWEEN SYARIKAT BEKALAN AIR SELANGOR SDN BHD APPELLANT AND TONY PUA KIAM WEE RESPONDENT [In The Court of
More informationLAA 3064 MOOT/MOCK AND PLACEMENT PROFESSIONAL MISCONDUCT
LAA 3064 MOOT/MOCK AND PLACEMENT PROFESSIONAL MISCONDUCT CONTENTS Introduction Definition Conviction of Criminal Offence Breach of duty with regards to undertaking Dishonest and fraudulent conduct in the
More informationClass Actions in Malaysia: An Update on the Country Report. Globalization of Class Actions: Oxford Symposium Oxford, England December, 2008
Class Actions in Malaysia: An Update on the Country Report Globalization of Class Actions: Oxford Symposium Oxford, England 11 12 December, 2008 Dr Yeow-Choy Choong and Sujata Balan Introduction This is
More informationINDUSTRIAL COURT OF MALAYSIA CASE NO : 15/4-173/02 BETWEEN MALAYSIAN AIRLINE SYSTEM BHD. AND KARTHIGESU A/L V. CHINNASAMY AWARD NO : 2230 OF 2005
INDUSTRIAL COURT OF MALAYSIA CASE NO : 15/4-173/02 BETWEEN MALAYSIAN AIRLINE SYSTEM BHD. AND KARTHIGESU A/L V. CHINNASAMY AWARD NO : 2230 OF 2005 Before : N. RAJASEGARAN - Chairman (Sitting Alone) Venue:
More informationSKRINE ADVOCATES & SOLICITORS. IS CONSTRUCTION INDUSTRY AND PAYMENT ADJUDICATION ACT 2012 RETROSPECTIVE OR PROSPECTIVE? Shannon Rajan Partner SKRINE
SKRINE ADVOCATES & SOLICITORS IS CONSTRUCTION INDUSTRY AND PAYMENT ADJUDICATION ACT 2012 RETROSPECTIVE OR PROSPECTIVE? Shannon Rajan Partner SKRINE Global Arbitration Review (GAR) Ranked in Top 100 International
More informationWong Kian Kheong - Partner
1. Education 1977-1983 Victoria Institution 1984-1988 Bachelor of Law (LLB) from University of Malaya First Class Honours 1988-1989 Masters of Law (LLM) from University of Cambridge 2. Scholastic Achievements
More informationLEGAL DEVELOPMENTS 2015 Foreword
LEGAL DEVELOPMENTS 2015 Foreword In 2015, the Banking, Insolvency and Commercial Dispute Team kept an eye on the key developments and stand out cases which altered the shape of the legal landscape and
More informationFox&Co Design General Terms & Conditions
Fox&Co Design General Terms & Conditions Latest Revision: April 2016 www.foxandco.design Content No. Contents Page No. 00 01 02 03 04 05 06 07 08 09 10 11 12 13 14 15 16 17 General Terms & Conditions Agreement
More informationISLAMIC FINANCE LITIGATION IN MALAYSIA: AN INTRODUCTION
ISLAMIC FINANCE LITIGATION IN MALAYSIA: AN INTRODUCTION Seminar on An Introduction to Islamic Finance. Date Day Time Venue : 20 th July 2017 : Wednesday : 2.00 p.m. 3.30 p.m. : Perak Bar Auditorium HIZRI
More information(27 November 1998 to date) ALIENATION OF LAND ACT 68 OF 1981
(27 November 1998 to date) [This is the current version and applies as from 27 November 1998, i.e. the date of commencement of the Alienation of Land Amendment Act 103 of 1998 to date] ALIENATION OF LAND
More informationCOURT OF APPEAL, MALAYSIA FANN WOW GALLERY (APPELLANT) DATO RASHID (RESPONDENT) MEMORIAL FOR THE APPELLANT
1606A COURT OF APPEAL, MALAYSIA 2016 FANN WOW GALLERY (APPELLANT) V. DATO RASHID (RESPONDENT) MEMORIAL FOR THE APPELLANT TABLE OF CONTENT TABLE OF CONTENTS... 1 INDEX... 3 SUMMARY OF FACTS...4 SUMMARY
More informationSKRINE BREACH OF CONTRACT: TERMINATION AND OTHER OPTIONS. 10 December LEE SHIH ADVOCATES & SOLICITORS
SKRINE ADVOCATES & SOLICITORS BREACH OF CONTRACT: TERMINATION AND OTHER OPTIONS 10 December 2013 - LEE SHIH 1 SUMMARY OF PART ONE How do I terminate a contract? Termination clauses. Common law right to
More informationATLAN HOLDINGS BHD. ( W) (Incorporated in Malaysia)
Extract of Minutes of the Twenty-Ninth Annual General Meeting of the Company held at the Meeting Room, Wisma Atlan, 8 Persiaran Kampung Jawa, 11900 Bayan Lepas, Penang on Tuesday, 28 August 2018 at 11:00
More informationPerformance Bonds. To guarantee /secure the contractor s performance. Recourse to meet losses suffered as a result of the contractor s breach
Performance Bonds To guarantee /secure the contractor s performance Recourse to meet losses suffered as a result of the contractor s breach Usually corresponds to 10% value of the contract price Usually
More informationPACKET ONE S ARD ANNEXURE I PACKET ONE S ARD ANNEXURE I NON-DISCLOSURE AGREEMENT. THIS NON-DISCLOSURE AGREEMENT ( Agreement ) is made on of 2009
PACKET ONE S ARD ANNEXURE I NON-DISCLOSURE AGREEMENT THIS NON-DISCLOSURE AGREEMENT ( Agreement is made on of 2009 this day BETWEEN Packet One Networks (Malaysia Sdn. Bhd. (Company No. 571389-H, a company
More informationPresenting Expert Evidence in Court and before Tribunals:
Presenting Expert Evidence in Court and before Tribunals: The Lawyer s Perspective By Manmohan S Dhillon Advocate & Solicitor Malaysia Expert Evidence On matters outside the learning of the court P S Ranjan
More informationCOPYRIGHT AGREEMENT ALAM CIPTA IMPORTANT: Thank you for choosing Alam Cipta as your preferred journal. P a g e 1 of 6
COPYRIGHT AGREEMENT REVISED: 15 APRIL 2016 IMPORTANT: This form must be duly completed by the submitting author and must be uploaded during online submission of the manuscript. Pages 2 & 3 must be completed
More informationTHE JUDICIAL CONTROL OF ADMINISTRATIVE ACTION
29 th LAWASIA CONFERENCE 12 15 August 2016 Colombo, Sri Lanka THE JUDICIAL CONTROL OF ADMINISTRATIVE ACTION Steven Thiru President Malaysian Bar The Malaysian judiciary, like their English counter-parts,
More informationALIENATION OF LAND ACT NO. 68 OF 1981
ALIENATION OF LAND ACT NO. 68 OF 1981 [View Regulation] [ASSENTED TO 28 AUGUST, 1981] DATE OF COMMENCEMENT: 19 OCTOBER, 1982] (except s. 26 on 6 December, 1983) (English text signed by the State President)
More informationDALAM MAHKAMAH TINGGI MALAYA DI SHAH ALAM DALAM NEGERI SELANGOR DARUL EHSAN RAYUAN SIVIL NO.: 11ANCVC-44-08/2016 ANTARA
DALAM MAHKAMAH TINGGI MALAYA DI SHAH ALAM DALAM NEGERI SELANGOR DARUL EHSAN RAYUAN SIVIL NO.: 11ANCVC-44-08/2016 ANTARA YEOH LIANG CHUAN (No. K/P: 481027-07-5351). PERAYU DAN JAGJIT SINGH (mendakwa sebagai
More informationGAR KNOW HOW CONSTRUCTION ARBITRATION. Malaysia. Avinash Pradhan Rajah & Tann Asia AUGUST ar ginsight
GAR KNOW HOW CONSTRUCTION ARBITRATION Malaysia Avinash Pradhan Rajah & Tann Asia AUGUST 2018 ar ginsight GAR Know How Construction Arbitration Malaysia 2 Legal system 1 Is your jurisdiction primarily a
More informationTHIS INDEPENDENT ENGINEER'S AGREEMENT (this Independent Engineer's Agreement) is made on [ ]
THIS INDEPENDENT ENGINEER'S AGREEMENT (this Independent Engineer's Agreement) is made on [ ] AMONG (1) REGIONAL TRANSPORTATION DISTRICT (RTD); (2) DENVER TRANSIT PARTNERS, LLC, a limited liability company
More informationPage 1 USER AGREEMENT
USER AGREEMENT This User Agreement ("Agreement") constitutes the agreement between you, the Company ("you", "your") requesting access to the Ocwen Vision Website (the Website ), and us, Ocwen Financial
More informationBERMAZ AUTO BERHAD (Formerly Known As Berjaya Auto Berhad) (Company No: M) (Incorporated in Malaysia)
BERMAZ AUTO BERHAD (Formerly Known As Berjaya Auto Berhad) (Company No: 900557-M) (Incorporated in Malaysia) An Extract of Minutes of the Extraordinary General Meeting of the Company held at Perdana Ballroom,
More informationQUICKPOLE.CA TERMS OF SERVICE. Last Modified On: July 12 th, 2018
1. PRELIMINARY PROVISIONS: QUICKPOLE.CA TERMS OF SERVICE Last Modified On: July 12 th, 2018 1.1 Introduction. Welcome to our website's Terms and Conditions ("Agreement"). The provisions of this Agreement
More informationPROCEDURE & PRINCIPLES: ORDER 26A: ORDER 14 & ORDER 14A
PROCEDURE & PRINCIPLES: ORDER 26A: ORDER 14 & ORDER 14A ISBN 983-41166-7-5 Author: Nasser Hamid Binding: Softcover/Extent: 650 pp Publication Price: MYR 220.00 The law is stated as of July 1, 2004 Chapter
More informationContract for Consultancy Services (Small)
Rail Industry Safety and Standards Board (RISSB Contract for Consultancy Services (Small Part 1: Contract Details Item 1 Consultant: [Insert full name of the party / parties that make up the Consultant]
More informationHOUSING ACT CHAPTER 117 LAWS OF KENYA
LAWS OF KENYA HOUSING ACT CHAPTER 117 Revised Edition 2018 [2015] Published by the National Council for Law Reporting with the Authority of the Attorney-General www.kenyalaw.org CHAPTER 117 HOUSING ACT
More informationENFORCEMENT OF CIVIL CASE JUDGMENTS IN MALAYSIA
ENFORCEMENT OF CIVIL CASE JUDGMENTS IN MALAYSIA INTRODUCTION The Malaysian Civil Judicial system is based on common law, much of which has been codified by statute. The hierarchy of courts in Malaysia
More informationWebsite Terms and Conditions Last Updated September 24, 2016
I. Introduction www.amyroseforan.com Website Terms and Conditions Last Updated September 24, 2016 By using www.amyroseforan.com, also referred to as the Website or the Site, all visitors, referred to as
More informationPedestal Search Terms and Conditions of Service:
Suite 300-100 Broadview Ave, Toronto, ON, M4M 3H3 (416) 545-1467 Pedestal Search Terms and Conditions of Service: WHEREAS these terms and conditions govern Pedestal s services and agreements between Pedestal
More informationARTWORK LICENSING AGREEMENT
ARTWORK LICENSING AGREEMENT THIS ARTWORK LICENSING AGREEMENT ( Agreement ) is made as of, 20 by and between National Real Estate Development, LLC ( Owner ) and ( Artist ). Owner and Artist are each referred
More informationTrademark dispute settlement in Malaysia: A comparative analysis with the TRIPS and the Paris convention
Vol. 9(2), pp. 9-25, July 2017 DOI:10.5897/JLCR2016.0247 Article Number: DAEBDB265459 ISSN 2006-9804 Copyright 2017 Author(s) retain the copyright of this article http://www.academicjournals.org/jlcr Journal
More informationABDUL AZIZ ISMAIL & ORS v. ROYAL SELANGOR CLUB
Abdul Aziz Ismail & Ors [2015] 2 MELR v. Royal Selangor Club 325 ABDUL AZIZ ISMAIL & ORS v. ROYAL SELANGOR CLUB Industrial Court, Kuala Lumpur Eddie Yeo Soon Chye Award No: 327 of 2015 [Case No: 13(25)(22)(25)/4-1255/2011]
More informationCASE UPDATE. The High Court Considers the Status and Scope of an Arbitration Agreement in the Context of a Termination of the Main Contract
The High Court Considers the Status and Scope of an Arbitration Agreement in the Context of a Termination of the Main Contract 6 June 2018 Introduction 1. In the recent decision of Nippon Catalyst Pte
More informationSINGAPORE IP LEGISLATION UPDATE
CLIENT NOTE SINGAPORE IP LEGISLATION UPDATE Advocates & Solicitors Trade Mark & Patent Agents SINGAPORE 50 Raffles Place, #06-00 Singapore Land Tower, Singapore 048623 Tel: +65 62200666 Fax: 65 63241638
More informationThis booklet relates to the Application Form for Business Revolving Credit / Business Instalment Loan Business Card Programme
To: The Hongkong and Shanghai Banking Corporation Limited INSTALMENT LOAN / BUSINESS CARD PROGRAMME / PROFIT TA LOAN / EASY EPORT FINANCE (For Limited Company Only) Note: Please tick where applicable and
More informationPAM NORTHERN CHAPTER
PAM NORTHERN CHAPTER SATURDAY, 27 FEBRUARY 2016 DELAY AND DISRUPTION IN CONSTRUCTION CONTRACTS BY LIM HOCK SIANG MESSRS PRESGRAVE & MATTHEWS STANDARD CHARTERED BANK CHAMBERS, 2 LEBUH PANTAI, 10300 PENANG,
More information156 INDUSTRIAL CO-ORDINATION ACT
LAWS OF MALAYSIA REPRINT Act 156 INDUSTRIAL CO-ORDINATION ACT 1975 Incorporating all amendments up to 1 January 2006 PUBLISHED BY THE COMMISSIONER OF LAW REVISION, MALAYSIA UNDER THE AUTHORITY OF THE REVISION
More informationIN THE COURT OF APPEAL OF MALAYSIA (APPELLATE JURISDICTION) CIVIL APPEAL NO.: W-02(IM)(NCC) /2014 BETWEEN
IN THE COURT OF APPEAL OF MALAYSIA (APPELLATE JURISDICTION) CIVIL APPEAL NO.: W-02(IM)(NCC)-676-04/2014 BETWEEN ZAMIL STEEL VIETNAM BUILDINGS CO. LTD. - APPELLANT AND G.T.K. BERHAD (Company No.: 198500-P)
More informationCHAPTER INTERNATIONAL TRUST ACT
SAINT LUCIA CHAPTER 12.19 INTERNATIONAL TRUST ACT Revised Edition Showing the law as at 31 December 2008 This is a revised edition of the law, prepared by the Law Revision Commissioner under the authority
More informationINTEREST-EARNINGS IN MALAYSIAN CIVIL LITIGATION: QURANIC AND LEGAL ANALYSIS
INTEREST-EARNINGS IN MALAYSIAN CIVIL LITIGATION: QURANIC AND LEGAL ANALYSIS Norman Zakiyy 1 Alifah Hj Hamid 2 Abstract This study examines civil litigation actions in the Malaysian civil courts which are
More informationATLAN HOLDINGS BHD. ( W) (Incorporated in Malaysia)
Extract of Minutes of the Twenty-Eighth Annual General Meeting of the Company held at the Lily Room, 1st Floor, The Zon All Suites Residences On The Park, 161-D, Jalan Ampang, 50450 Kuala Lumpur on Wednesday,
More information197 REGISTRATION OF BUSINESSES ACT
LAWS OF MALAYSIA ONLINE VERSION OF UPDATED TEXT OF REPRINT Act 197 REGISTRATION OF BUSINESSES ACT 1956 As at 1 June 2017 2 REGISTRATION OF BUSINESSES ACT 1956 First enacted 1956 (Ordinance No. 47 of 1956)
More informationthe court has jurisdiction to grant a mandatory injunction on an ex parte application in urgent and exceptional cases;
[1986] 1 MLJ 256 BANK ISLAM MALAYSIA BHD v TINTA PRESS SDN BHD & ORS OCJ KUALA LUMPUR ZAKARIA YATIM J CIVIL SUIT NO C2518 OF 1984 20 August 1985 Practice and Procedure Interlocutory mandatory injunction
More information2A. To reappoint the following directors who are above the 70 years of age and have offered themselves for re-election:- Note 2A
Incorporated in Malaysia AMENDMENT TO THE NOTICE OF 10 TH ANNUAL GENERAL MEETING AND PROXY FORM Dear shareholders of Hap Seng Plantations Holdings Berhad, Reference is made to the notice of 10 th Annual
More informationCOMMON TERMS AND CONDITIONS FOR CASH MANAGEMENT PRODUCTS & SERVICES
v1.2 (01062015) COMMON TERMS AND CONDITIONS FOR CASH MANAGEMENT PRODUCTS & SERVICES By subscribing or applying for the Banking Services the Applicant agrees to the terms and conditions ( Terms ) below.
More informationLEE PEI SZE v. SWIFTLET GARDEN SDN BHD
482 LEE PEI SZE v. SWIFTLET GARDEN SDN BHD Industrial Court, Johor Duncan Sikodol Award No: 167 of 2017 [Case No: 16/4-664/16] 23 January 2017 Dismissal: Probationer Pleadings Allegations of misconduct
More informationLAW OF CONTRACT ACT CHAPTER 23 LAWS OF KENYA
LAWS OF KENYA LAW OF CONTRACT ACT CHAPTER 23 Revised Edition 2012 [2002] Published by the National Council for Law Reporting with the Authority of the Attorney-General www.kenyalaw.org [Rev. 2012] CAP.
More information