IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : ARBITRATION MATTER. OMP No.358 of Date of decision :

Size: px
Start display at page:

Download "IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : ARBITRATION MATTER. OMP No.358 of Date of decision :"

Transcription

1 IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : ARBITRATION MATTER OMP No.358 of 2005 Date of decision : OIL and NATURAL GAS CORPORATION LIMITED...PETITIONER Through: Mr.R.G.Shrivastava, Advocate - VERSUS - M/s MITRA GUHA BUILDER (INDIA) COMPANY...RESPONDENT Through: Mr. S.K.Taneja, Sr. Adv with Mr. S.S.Sastry, Advocate AND OMP No.359 of 2005 OIL and NATURAL GAS CORPORATION LIMITED...PETITIONER Through: Mr.R.G.Shrivastava, Advocate - VERSUS - M/s MITRA GUHA BUILDER (INDIA) COMPANY...RESPONDENT Through: Mr. S.K.Taneja, Sr. Adv with Mr. S.S.Sastry, Advocate

2 SANJAY KISHAN KAUL, J. (ORAL) (1)The petitioner assigned the work to the respondent of construction of multi- storied residential flats in Sector 39, NOIDA under two separate contracts. (2)Disputes arose between the parties about the liability to pay the amount to the respondent resulting in two separate similar arbitrations before Justice P.K.Bahri, (Retd.). There are two separate similar Awards made by the arbitrator dated which are now sought to be challenged by the petitioner under Section 34 (2) of the Arbitration Act, 1996 ('the said Act' for short). It has to be noticed that in both the Awards, the arbitrator has taken note of the fact that there are delays attributable to both the petitioner and the respondent. There are, in fact, substantive delays attributable to the petitioner. It is in these circumstances that the arbitrator had granted to the respondent only the balance amount payable under the contract as per the running bills, the amount withheld by the petitioner and the escalation on account of delay along with interest and costs. The claim for damages of both the petitioner and the respondent attributing fault to the other party for delays has been rejected. (3)Learned counsel contends that the Awards given by the arbitrator are against the law declared by the Apex Court and are against the terms of the contract inasmuch as the petitioner sought to impose, as stated to be, preestimated damages and reasonable compensation rather than penalty. (4)Learned counsel next contends that in terms of Clause 10C escalation was payable only where the contractor had to pay for the increased price and it was not as if there was an automatic payment as per a prescribed formula to be made in case of delay. (5)Lastly, it is contended that in terms of Clause 25 a restriction was provided that the contractor had to make a demand for arbitration within 90 days of receiving of intimation from the Corporation of the bill being ready for payment failing which it would be deemed to have been waived. (6)Insofar as the first aspect is concerned, it would be relevant to consider some of the dates. It is the case of the petitioner that the contract was entered into on with the stipulated date of commencement of work as

3 21/ and stipulated date of completion was 21/ The work actually commenced only on and was completed on The total delay was of 640 days, out of which the petitioner found that 273 days were attributable to the contractor and 367 days were attributable to the petitioner. The arbitrator has taken note of the fact that the petitioner extended the time period for completion of the contract on account of there being primary delays on the part of the petitioner which continued to be extended. Damages were sought to be imposed by the letter dated The imposition of the damages/penalty was thus held to be highly belated and an afterthought only to adjust the claims due to the respondent. (7)I find no infirmity with the aforesaid finding of the arbitrator. (8)The arbitrator has found that under the garb of liquidited damages, what was sought to be imposed was the penalty. Be that as it may, it is an undisputed position that almost 60 per cent of the delay was attributable to the petitioner while the remaining 40 per cent of the delay was attributable to the respondent. Where the petitioner himself is responsible for a substantive part of the delay, it can hardly be said that the petitioner is entitled to recovery of liquidated damages or penalty. (9)Learned counsel for the petitioner did seek to contend that the delay on the part of the respondent was not in pursuance to the delay of the petitioner but was independent of it. (10)In my considered view this is purely a matter of appreciation of evidence. Even otherwise, if there is a certain delay on the part of the petitioner, it is not necessary that there has to be corresponding fixed delay by the respondent. In the present case, the delay on the part of the petitioner is much more than the delay on the part of the respondent. (11)The arbitrator, conscious of the delay on the part of both the parties, has not just disallowed the damages/penalty imposed by the petitioner, but has rejected even the claim of the respondent in this behalf on various accounts. The arbitrator has only awarded the amount as per the running bills and the amount detained by the petitioner which was sought to be adjusted against the claim for damages for such adjustment would in any case have been payable. These are really in the nature of undisputed amounts.

4 (12)Apart from the aforesaid amount, the only amount directed to be paid is under Clause 10C for delays attributable to the petitioner. It is true that the Clause 10C talks about the loss caused by the delay and such loss has been found by the arbitrator. This Court cannot be expected to sit as a court of appeal over the adjudication of the said amount. (13)The last contention of learned counsel for the petitioner arises from Clause 25 of the Agreement which has been held to be violative of Section 28 of the Contract Act, This aspect, in fact, is no more res integra in view of the judgment of this Court in M/s Pandit Construction Company v. DDA; 143 (2007) Delhi Law Times 270 wherein it was held that in view of the provisions of Section 28(b) of the Contract Act, as amended, an agreement in restraint of legal proceedings contrary to the mandate of Article 137 of the Limitation Act, 1963 would be void and any clause extinguishing right of a party or discharging any party from liability in respect of any contract on expiry of specific period so as to restrict the time period would be void. This is also the view taken by the arbitrator, which cannot be faulted. (14)Learned counsel for the petitioner did seek to rely upon the judgment of the Supreme Court in Food Corporation of India v. Surendra, Devendra and Mahendra Transport Company; AIR 2003 Supreme Court In my considered view, the said judgment would have no application in the present case as the same relates to the jurisdiction of the arbitrator in respect of a claim regarding transit loss, demurrage and wharfage charges, which are specifically barred and thus are not part of contemplated disputes under the arbitration clause. (15)It may be noted in the end that the judgment of the Apex Court in Oil and Natural Gas Corporation Ltd. v. Saw Pipes Ltd., AIR 2003 SC 2629 only expanded the scope of scrutiny by the Court under the phrase?public policy of India? as appearing in Section 34(2)(b)(ii) of the said Act. Instead of a narrow meaning it was held that the Court can set aside an award if it is contrary to the fundamental policy of Indian law, interest of India, justice or morality, is patently illegal or is so unfair and unreasonable that it shocks the conscience of the Court. However, illegality of a trivial nature was held liable to be ignored. 16)I find that no part of the objections of the petitioner fall within the ambit of the aforesaid description as given in Oil and Natural Gas Corporation Ltd.

5 v. Saw Pipes Ltd (Supra). The Award is in accordance with the settled legal position. The petitioner cannot deny the liability to make payment by adjusting admitted amounts against the alleged damages/penalty when a substantive part of the delay is found attributable to the petitioner and there is a smaller part of the delay attributable to the respondent. In fact, if a calculation had been made of damages on a daily basis for delay, amount payable to the respondent would have been more than that payable by the respondent as the delay on the part of the petitioner is of 367 days and on the part of the respondent is of 273 days. (17)The arbitrator applied general equitable principles and deemed it appropriate not to direct any payments for delay to be made to either of the two parties except as provided for in the contract in respect of Clause 10C for delays on the part of the petitioner and such a course has been more beneficial to the petitioner than to the respondent. (18)There is no merit in the two petitions and both of them are dismissed with costs quantified at Rs 7,500/-. (19)At this stage, learned counsel for the petitioner states that in OMP No.358/2005 there is a clerical mistake inasmuch as in specifying the amount in para 50 under claim 3, the amount has been mentioned as Rs 32,56,110/- while the amount is Rs 29,56,110/- in para 38 of the Award dealing with claim no.3 as a result of which the total is also incorrectly mentioned as Rs 3 lakh more at Rs 69,36,252/- which should read as Rs 66,36,252/-. This position is not disputed by learned counsel for the respondent though he states that same being a typographical error could have been got corrected before the arbitrator. Be that as it may, it is directed that in view of the aforesaid being a typographical error, principal amount under the said Award should read as Rs 66,36,252/-. Sd/- SANJAY KISHAN KAUL, J.

6

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : ARBITRATION AND CONCILIATION ACT, 1996 FAO No.8/2010 DATE OF DECISION : 2nd January, 2014

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : ARBITRATION AND CONCILIATION ACT, 1996 FAO No.8/2010 DATE OF DECISION : 2nd January, 2014 IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : ARBITRATION AND CONCILIATION ACT, 1996 FAO No.8/2010 DATE OF DECISION : 2nd January, 2014 MUNICIPAL CORPORATION OF DELHI Through: Ms. Mini Pushkarna, Advocate....Appellant

More information

IN THE SUPREME COURT OF INDIA CIVIL APPELLATE JURISDICTION CIVIL APPEAL NO.3349 OF M/s. J.G.Engineers Pvt. Ltd.

IN THE SUPREME COURT OF INDIA CIVIL APPELLATE JURISDICTION CIVIL APPEAL NO.3349 OF M/s. J.G.Engineers Pvt. Ltd. Reportable IN THE SUPREME COURT OF INDIA CIVIL APPELLATE JURISDICTION CIVIL APPEAL NO.3349 OF 2005 M/s. J.G.Engineers Pvt. Ltd. Appellant Vs. Union of India & Anr. Respondents J U D G M E N T R.V.RAVEENDRAN,

More information

IN THE HIGH COURT OF DELHI AT NEW DELHI. AA No.396/2007. Date of decision: December 3, Vs.

IN THE HIGH COURT OF DELHI AT NEW DELHI. AA No.396/2007. Date of decision: December 3, Vs. IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : Arbitration and Conciliation Act, 1996 AA No.396/2007 Date of decision: December 3, 2007 AKG Associates Through: Mr.Rajiv Kumar, Advocate....Petitioner

More information

* IN THE HIGH COURT OF DELHI AT NEW DELHI. % Judgment pronounced on: 20 th April, versus. Advocates who appeared in this case:

* IN THE HIGH COURT OF DELHI AT NEW DELHI. % Judgment pronounced on: 20 th April, versus. Advocates who appeared in this case: * IN THE HIGH COURT OF DELHI AT NEW DELHI % Judgment pronounced on: 20 th April, 2017 + W.P.(C) 7850/2014 M/S. IRITECH INC versus... Petitioner THE CONTROLLER OF PATENTS... Respondents Advocates who appeared

More information

M/S. Iritech Inc vs The Controller Of Patents on 20 April, % Judgment pronounced on: 20th April, 2017

M/S. Iritech Inc vs The Controller Of Patents on 20 April, % Judgment pronounced on: 20th April, 2017 Delhi High Court M/S. Iritech Inc vs The Controller Of Patents on 20 April, 2017 * IN THE HIGH COURT OF DELHI AT NEW DELHI % Judgment pronounced on: 20th April, 2017 + W.P.(C) 7850/2014 M/S. IRITECH INC

More information

THE HIGH COURT OF DELHI AT NEW DELHI

THE HIGH COURT OF DELHI AT NEW DELHI THE HIGH COURT OF DELHI AT NEW DELHI % Judgment delivered on: 06.01.2016 + W.P.(C) 2927/2013 AGSON GLOBAL PVT LTD & ORS... Petitioners versus INCOME TAX SETTLEMENT COMMISSION AND ORS... Respondents Advocates

More information

* IN THE HIGH COURT OF DELHI AT NEW DELHI. + ARB.A. 5/2015 & IA 2340/2015 (for stay) versus

* IN THE HIGH COURT OF DELHI AT NEW DELHI. + ARB.A. 5/2015 & IA 2340/2015 (for stay) versus * IN THE HIGH COURT OF DELHI AT NEW DELHI + ARB.A. 5/2015 & IA 2340/2015 (for stay) Judgment reserved on February 05, 2015 Judgment delivered on February 13, 2015 M/S VARUN INDUSTRIES LTD & ORS... Appellants

More information

IN THE HIGH COURT OF DELHI AT NEW DELHI. Date of Decision : March 14, A.A. No.23/2007. Versus. Versus

IN THE HIGH COURT OF DELHI AT NEW DELHI. Date of Decision : March 14, A.A. No.23/2007. Versus. Versus IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : Arbitration and Conciliation Act, 1996 Date of Decision : March 14, 2008 A.A. No.23/2007 Sh. Rajesh Kumar Garg Through: Mr. B.P. Singh, Advocate... Petitioner

More information

+OMP 191/2009 % M/s Delhi Apartments Pvt. Ltd. Through: Mr. Sandeep Sethi, Sr. Advocate with Mr. D. Moitra, Advocates

+OMP 191/2009 % M/s Delhi Apartments Pvt. Ltd. Through: Mr. Sandeep Sethi, Sr. Advocate with Mr. D. Moitra, Advocates * IN THE HIGH COURT OF DELHI AT NEW DELHI Date of Reserve: September 09, 2009 Date of Order: October 12, 2009 +OMP 191/2009 % 12.10.2009 M/s Delhi Apartments Pvt. Ltd....Petitioner Through: Mr. Sandeep

More information

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : EXCISE ACT, 1944 CENTRAL EXCISE ACT CASE NOS. 48/2012 & 49/2012 Date of decision: 2nd August, 2013

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : EXCISE ACT, 1944 CENTRAL EXCISE ACT CASE NOS. 48/2012 & 49/2012 Date of decision: 2nd August, 2013 IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : EXCISE ACT, 1944 CENTRAL EXCISE ACT CASE NOS. 48/2012 & 49/2012 Date of decision: 2nd August, 2013 HINDUSTAN INSECTICIEDES LTD.... Appellant Through Mr.

More information

Bar & Bench (www.barandbench.com)

Bar & Bench (www.barandbench.com) IN THE HIGH COURT OF UTTARAKHAND AT NAINITAL Arbitration Petition No. 21 of 2017 KLA Const. Technologies Private Limited..Petitioner Versus Kajima India Private Limited Respondent Present:- Dr. Amit George,

More information

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : SERVICE MATTER. Reserved on: Date of decision:

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : SERVICE MATTER. Reserved on: Date of decision: IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : SERVICE MATTER Reserved on: 02.04.2009 Date of decision: 15.04.2009 WP (C) No.8365 of 2008 JAY THAREJA & ANR. PETITIONERS Through: Mr. C. Hari Shankar,

More information

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : ARBITRATION & CONCILIATION ACT. Date of decision: 8th March, 2013 EFA(OS) 34/2012

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : ARBITRATION & CONCILIATION ACT. Date of decision: 8th March, 2013 EFA(OS) 34/2012 IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : ARBITRATION & CONCILIATION ACT Date of decision: 8th March, 2013 EFA(OS) 34/2012 HOUSING & URBAN DEVELOPMENT CORPORATION LTD.... Appellant Through: Mr.

More information

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : SERVICE MATTER ARB P. 180/2003. Judgment delivered on: versus

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : SERVICE MATTER ARB P. 180/2003. Judgment delivered on: versus IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : SERVICE MATTER ARB P. 180/2003 Judgment delivered on: 03.07.2006 ESS VEE TRADERS & OTHERS... Petitioners versus M/S AMBUJA CEMENT RAJASTHAN LIMITED...

More information

* IN THE HIGH COURT OF DELHI AT NEW DELHI

* IN THE HIGH COURT OF DELHI AT NEW DELHI * IN THE HIGH COURT OF DELHI AT NEW DELHI Date of Reserve: July 01, 2009 Date of Order: July 03, 2009 + OMP 338/2009 % 03.07.2009 SAMHO GUNYOUNG CO. LTD.... Petitioner Through : Mr. Debo K. Deori, Adv.

More information

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : CODE OF CIVIL PROCEDURE Date of Judgment: FAO (OS) 298/2010

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : CODE OF CIVIL PROCEDURE Date of Judgment: FAO (OS) 298/2010 IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : CODE OF CIVIL PROCEDURE Date of Judgment: 17.01.2013 FAO (OS) 298/2010 SHIROMANI GURUDWARA PRABHANDHAK COMMITTEE AND ANR... Appellants Through Mr. H.S.

More information

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : INDIAN COMPANIES ACT, 1956 Date of Judgment: W.P.(C) 8432/2011

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : INDIAN COMPANIES ACT, 1956 Date of Judgment: W.P.(C) 8432/2011 IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : INDIAN COMPANIES ACT, 1956 Date of Judgment:20.3.2013 W.P.(C) 8432/2011 PUNJAB NATIONAL BANK... Petitioner Through: Mr.Dhruv Mehta, Sr. Adv. with Mr. Ashim

More information

HINDUSTAN CONSTRUCTION COMPANY LTD... Petitioner Through Mr.Dherainder Negi, Adv. with Ms.Smita Bhargava, Adv.

HINDUSTAN CONSTRUCTION COMPANY LTD... Petitioner Through Mr.Dherainder Negi, Adv. with Ms.Smita Bhargava, Adv. IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : ARBITRATION AND CONCILIATION ACT, 1996 Judgment Reserved on: May 24, 2013 Judgment delivered on: July 01, 2013 Arb.P.No.31/2013 HINDUSTAN CONSTRUCTION

More information

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : ARBITRATION AND CONCILIATION ACT, Date of Judgment :

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : ARBITRATION AND CONCILIATION ACT, Date of Judgment : IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : ARBITRATION AND CONCILIATION ACT, 1996 Date of Judgment : 16.02.2012 CRP 128/2004 and CM No. 85/2012 M/S R.S. BUILDERS & ENGINEERS LTD. Through Mr. Prabhjit

More information

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : ARBITRATION & CONCILIATION ACT, 1996 Judgement delivered on: O.M.P.

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : ARBITRATION & CONCILIATION ACT, 1996 Judgement delivered on: O.M.P. IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : ARBITRATION & CONCILIATION ACT, 1996 Judgement delivered on: 04.12.2014 O.M.P. 412/2012 HARYANA STATE SMALL INDUSTRIES & EXPORT CORPORATION LTD. Through:

More information

* IN THE HIGH COURT OF DELHI AT NEW DELHI. % Date of decision: WP(C) No. 416 of 2011 and CM Nos /2011. Versus

* IN THE HIGH COURT OF DELHI AT NEW DELHI. % Date of decision: WP(C) No. 416 of 2011 and CM Nos /2011. Versus * IN THE HIGH COURT OF DELHI AT NEW DELHI % Date of decision: 21.01.2011 + WP(C) No. 416 of 2011 and CM Nos.839-840/2011 DINESH KUMAR & ANR. PETITIONERS Through: Mr.S.N.Khanna, Advocate Versus DELHI COOPERATIVE

More information

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : ALLOTMENT OF FLAT. W.P.(C) No.5180/2011. Decided on:

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : ALLOTMENT OF FLAT. W.P.(C) No.5180/2011. Decided on: IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : ALLOTMENT OF FLAT W.P.(C) No.5180/2011 Decided on: 16.01.2012 IN THE MATTER OF PITAMBER DUTT Through : Mr. V. Sridhar Reddy, Adv.... Petitioner versus

More information

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : SUIT FOR DECLARATION. Date of Reserve: January 14, Date of Order: January 21, 2009

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : SUIT FOR DECLARATION. Date of Reserve: January 14, Date of Order: January 21, 2009 IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : SUIT FOR DECLARATION Date of Reserve: January 14, 2008 Date of Order: January 21, 2009 CS(OS) No.2582/2008 and IA No.425/2009 M/S DRISHTICON PROPERTIES

More information

THE HIGH COURT OF DELHI AT NEW DELHI. % Judgment delivered on: M/S MITSUBISHI CORPORATION INDIA P. LTD Petitioner.

THE HIGH COURT OF DELHI AT NEW DELHI. % Judgment delivered on: M/S MITSUBISHI CORPORATION INDIA P. LTD Petitioner. THE HIGH COURT OF DELHI AT NEW DELHI % Judgment delivered on: 30.07.2010 + WP (C) 11932/2009 M/S MITSUBISHI CORPORATION INDIA P. LTD Petitioner - versus THE VALUE ADDED TAX OFFICER & ANR... Respondent

More information

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : SUIT FOR POSSESSION. Date of Decision: W.P.(C) 7097/2010

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : SUIT FOR POSSESSION. Date of Decision: W.P.(C) 7097/2010 IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : SUIT FOR POSSESSION Date of Decision: 10.02.2012 W.P.(C) 7097/2010 USHA KUMAR... Petitioner Through: Mr. A.B.Dial, Senior Advocate with Ms. Sumati Anand,

More information

* IN THE HIGH COURT OF DELHI AT NEW DELHI. % Judgment pronounced on: 27 th January, ARB. P. No.373/2015. versus

* IN THE HIGH COURT OF DELHI AT NEW DELHI. % Judgment pronounced on: 27 th January, ARB. P. No.373/2015. versus * IN THE HIGH COURT OF DELHI AT NEW DELHI % Judgment pronounced on: 27 th January, 2016 + ARB. P. No.373/2015 CONCEPT INFRACON PVT. LTD... Petitioner Through: Mr.Balaji Subramanium, Adv. with Mr.Samar

More information

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : RECOVERY OF DAMAGES. C.R.P. No.365/2006 RESERVED ON : DATE OF DECISION:

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : RECOVERY OF DAMAGES. C.R.P. No.365/2006 RESERVED ON : DATE OF DECISION: IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : RECOVERY OF DAMAGES C.R.P. No.365/2006 RESERVED ON : 27-02-2007 DATE OF DECISION: 05-03-2007 TRISTAR CONSULTANTS... Petitioner through: Mr.M.S.Ganesh,

More information

THE BLACK MONEY (UNDISCLOSED FOREIGN INCOME AND ASSETS) AND IMPOSITION OF TAX BILL, 2015

THE BLACK MONEY (UNDISCLOSED FOREIGN INCOME AND ASSETS) AND IMPOSITION OF TAX BILL, 2015 AS PASSED BY LOK SABHA ON 11 MAY, Bill No. 84-C of THE BLACK MONEY (UNDISCLOSED FOREIGN INCOME AND ASSETS) AND IMPOSITION OF TAX BILL, ARRANGEMENT OF CLAUSES CHAPTER I CLAUSES PRELIMINARY 1. Short title,

More information

M/S. SAIPEM TRIUNE ENGINEERING PVT. LTD. Plaintiff. - versus - INDIAN OIL PETRONAS PVT. LTD.

M/S. SAIPEM TRIUNE ENGINEERING PVT. LTD. Plaintiff. - versus - INDIAN OIL PETRONAS PVT. LTD. IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : ARBITRATION AND CONCILIATION ACT, 1996 Judgment Reserved on: January 07, 2011 Judgment Pronounced on: January 10, 2011 CS(OS) No. 2340/2008 & I.A. No.

More information

IN THE SUPREME COURT OF INDIA CIVIL APPELLATE JURISDICTION. CIVIL APPEAL No of versus J U D G M E N T

IN THE SUPREME COURT OF INDIA CIVIL APPELLATE JURISDICTION. CIVIL APPEAL No of versus J U D G M E N T Reportable IN THE SUPREME COURT OF INDIA CIVIL APPELLATE JURISDICTION CIVIL APPEAL No.10863 of 2017 ABDULRASAKH.Appellant versus K.P. MOHAMMED & ORS... Respondents J U D G M E N T SANJAY KISHAN KAUL, J.

More information

$~ * IN THE HIGH COURT OF DELHI AT NEW DELHI REHABILITATION MINISTRY EMPLOYEES CO-OPERATIVE. versus

$~ * IN THE HIGH COURT OF DELHI AT NEW DELHI REHABILITATION MINISTRY EMPLOYEES CO-OPERATIVE. versus $~ * IN THE HIGH COURT OF DELHI AT NEW DELHI + W.P.(C) 8444/2011 Date of Decision: 29 th September, 2015 REHABILITATION MINISTRY EMPLOYEES CO-OPERATIVE HOUSE BUILDING SOCIETY... Petitioner Through Mr.

More information

IN THE HIGH COURT OF KARNATAKA AT BANGALORE BEFORE THE HON BLE MR.JUSTICE B.S.PATIL. W.P.Nos.50029/2013 & 51586/2013 (CS-RES)

IN THE HIGH COURT OF KARNATAKA AT BANGALORE BEFORE THE HON BLE MR.JUSTICE B.S.PATIL. W.P.Nos.50029/2013 & 51586/2013 (CS-RES) 1 IN THE HIGH COURT OF KARNATAKA AT BANGALORE DATED THIS THE 5 TH DAY OF APRIL, 2014 BEFORE THE HON BLE MR.JUSTICE B.S.PATIL W.P.Nos.50029/2013 & 51586/2013 (CS-RES) BETWEEN 1. SRI H RAGHAVENDRA RAO S/O

More information

Settlement of Tax Cases

Settlement of Tax Cases CHAPTER 22 Settlement of Tax Cases Some Key Points : Recent Amendments Substantial interest to be determined on the basis of beneficial ownership of shares carrying not less than 20% voting power/ beneficial

More information

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : CHANGE OF LAND USE MATTER Date of Decision: W.P.(C) 5180/2012

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : CHANGE OF LAND USE MATTER Date of Decision: W.P.(C) 5180/2012 IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : CHANGE OF LAND USE MATTER Date of Decision: 25.04.2013 W.P.(C) 5180/2012 NEERA SHARMA... Petitioner Through: Mr S.K. Rungta, Sr. Adv. with Mr. Prashant

More information

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : CONSUMER PROTECTION ACT, Date of Decision: W.P.(C) 8285/2010 & C.M. No.

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : CONSUMER PROTECTION ACT, Date of Decision: W.P.(C) 8285/2010 & C.M. No. IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : CONSUMER PROTECTION ACT, 1986 Date of Decision: 06.02.2012 W.P.(C) 8285/2010 & C.M. No.21319/2010 JK MITTAL... Petitioner Through: Petitioner in person

More information

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : ARBITRATION ACT, 1940 Reserved on : Decided on: FAO(OS) 89/2009

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : ARBITRATION ACT, 1940 Reserved on : Decided on: FAO(OS) 89/2009 IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : ARBITRATION ACT, 1940 Reserved on : 07.02.2013 Decided on: 13.03.2013 FAO(OS) 89/2009 M/S. NATIONAL PROJECTS CONSTRUCTION CORPORATION LTD..... Appellant

More information

IN THE SUPREME COURT OF INDIA CIVIL ORIGINAL JURISDICTION. Special Leave Petition (C) No.of 2016 (Diary No of 2016) Versus

IN THE SUPREME COURT OF INDIA CIVIL ORIGINAL JURISDICTION. Special Leave Petition (C) No.of 2016 (Diary No of 2016) Versus IN THE SUPREME COURT OF INDIA CIVIL ORIGINAL JURISDICTION Special Leave Petition (C) No.of 2016 (Diary No. 36526 of 2016) NOIDA Toll Bridge Company Ltd. Versus... Petitioner(s) Federation of NOIDA Residents

More information

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : SUIT FOR PARTITION Judgment delivered on: CS(OS) 2318/2006

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : SUIT FOR PARTITION Judgment delivered on: CS(OS) 2318/2006 IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : SUIT FOR PARTITION Judgment delivered on: 14.08.2012 CS(OS) 2318/2006 MR. CHETAN DAYAL Through: Ms Yashmeet Kaur, Adv.... Plaintiff versus MRS. ARUNA MALHOTRA

More information

IN THE SUPREME COURT OF INDIA ORIGINAL CIVIL JURISDICTION ARBITRATION PETITION NO. 20 OF Vs. DEVAS MULTIMEDIA P. LTD...

IN THE SUPREME COURT OF INDIA ORIGINAL CIVIL JURISDICTION ARBITRATION PETITION NO. 20 OF Vs. DEVAS MULTIMEDIA P. LTD... 1 REPORTABLE IN THE SUPREME COURT OF INDIA ORIGINAL CIVIL JURISDICTION ARBITRATION PETITION NO. 20 OF 2011 ANTRIX CORP. LTD....PETITIONER Vs. DEVAS MULTIMEDIA P. LTD....RESPONDENT J U D G M E N T ALTAMAS

More information

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : CODE OF CIVIL PROCEDURE Date of Decision : December 3, 2012 CS(OS) 1785/2010

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : CODE OF CIVIL PROCEDURE Date of Decision : December 3, 2012 CS(OS) 1785/2010 IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : CODE OF CIVIL PROCEDURE Date of Decision : December 3, 2012 CS(OS) 1785/2010 HOUSING DEVELOPMENT FINANCE CORPORATION LTD.... Plaintiff Through: Mr. Ajay

More information

Salem Advocate Bar Association,... vs Union Of India on 25 October, 2002

Salem Advocate Bar Association,... vs Union Of India on 25 October, 2002 Supreme Court of India Salem Advocate Bar Association,... vs Union Of India on 25 October, 2002 Bench: B.N. Kirpal Cj, Y.K. Sabharwal, Arijit Passayat CASE NO.: Writ Petition (civil) 496 of 2002 PETITIONER:

More information

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : INCOME TAX MATTER. Judgment delivered on: WP (C) 4642/2008

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : INCOME TAX MATTER. Judgment delivered on: WP (C) 4642/2008 IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : INCOME TAX MATTER Judgment delivered on: 02.07.2008 WP (C) 4642/2008 M/S KESHAV SHARES and STOCKS LIMITED... Petitioner - versus - INCOME TAX OFFICER AND

More information

IN THE HIGH COURT OF JUDICATURE AT BOMBAY O. O. C. J. ARBITRATION PETITION NO.174 OF 2006

IN THE HIGH COURT OF JUDICATURE AT BOMBAY O. O. C. J. ARBITRATION PETITION NO.174 OF 2006 1 IN THE HIGH COURT OF JUDICATURE AT BOMBAY O. O. C. J. ARBITRATION PETITION NO.174 OF 2006 Western Maharashtra Development Corpn.Ltd., having its registered office at 2 nd Fllor, Kubera Chambers, Dr.Rajendra

More information

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : PROPERTY DISPUTE. LPA of Date of decision:

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : PROPERTY DISPUTE. LPA of Date of decision: IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : PROPERTY DISPUTE LPA 577-580 of 2006 Date of decision: 20.01.2009 INDERJEET SINGH (SINCE DECEASED) and OTHERS APPELLANTS Through: Mr.R.K.Saini, Mr.Nikhil

More information

IN THE SUPREME COURT OF INDIA CIVIL APPELLATE JURISDICTION. CIVIL APPEAL NO OF 2015 (Arising out of SLP(C) No of 2011) :Versus:

IN THE SUPREME COURT OF INDIA CIVIL APPELLATE JURISDICTION. CIVIL APPEAL NO OF 2015 (Arising out of SLP(C) No of 2011) :Versus: 1 REPORTABLE IN THE SUPREME COURT OF INDIA CIVIL APPELLATE JURISDICTION CIVIL APPEAL NO. 4043 OF 2015 (Arising out of SLP(C) No.10173 of 2011) Central Bank of India Appellant :Versus: C.L. Vimla & Ors.

More information

HONOURABLE MR.JUSTICE D.A.MEHTA HONOURABLE MS.JUSTICE H.N.DEVANI. KANUBHAI M PATEL HUF - Petitioner(s) Versus

HONOURABLE MR.JUSTICE D.A.MEHTA HONOURABLE MS.JUSTICE H.N.DEVANI. KANUBHAI M PATEL HUF - Petitioner(s) Versus IN THE HIGH COURT OF GUJARAT AT AHMEDABAD SPECIAL CIVIL APPLICATION No. 5295 of 2010 WITH SPECIAL CIVIL APPLICATION NO.5296 OF 2010 AND SPECIAL CIVIL APPLICATION NO.5297 OF 2010 HONOURABLE MR.JUSTICE D.A.MEHTA

More information

640 KNOWLEDGE RESOURCE [Vol. 49 First of all let us go through this amended Section 35F of Central Excise Act, It reads as under: Section 35F. T

640 KNOWLEDGE RESOURCE [Vol. 49 First of all let us go through this amended Section 35F of Central Excise Act, It reads as under: Section 35F. T Amended Section 35F of C. Ex. Act, some judicial interpretations and some circulars for clarification A Study Sagar Mal Pareek* The issue of mandatory deposit of certain per cent of amount of dispute at

More information

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : SUIT FOR POSSESSION Date of Judgment: RSA No.251/2008 & CM Nos.17860/2008 & 11828/2010

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : SUIT FOR POSSESSION Date of Judgment: RSA No.251/2008 & CM Nos.17860/2008 & 11828/2010 IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : SUIT FOR POSSESSION Date of Judgment: 28.4.2011 RSA No.251/2008 & CM Nos.17860/2008 & 11828/2010 UNITED INDIA INSURANCE CO.LTD..Appellant Through: Mr.P.K.Seth,

More information

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : LAND ACQUISITION ACT, Date of decision: WP(C) No. 3595/2011 and CM Nos.

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : LAND ACQUISITION ACT, Date of decision: WP(C) No. 3595/2011 and CM Nos. IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : LAND ACQUISITION ACT, 1894 Date of decision: 24.05.2011 WP(C) No. 3595/2011 and CM Nos.7523/2011 YUDHVIR SINGH Versus Through: PETITIONER Mr.N.S.Dalal,

More information

IN THE HIGH COURT OF DELHI AT NEW DELHI. SUBJECT : Negotiable Instruments Act. Judgement reserved on: January 07, 2009

IN THE HIGH COURT OF DELHI AT NEW DELHI. SUBJECT : Negotiable Instruments Act. Judgement reserved on: January 07, 2009 (1) Crl.M.C. No. 3011/2008 IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : Negotiable Instruments Act Judgement reserved on: January 07, 2009 Judgement delivered on: January 13, 2009 (2) Crl.M.C. No.

More information

IN THE GAUHATI HIGH COURT

IN THE GAUHATI HIGH COURT IN THE GAUHATI HIGH COURT (THE HIGH COURT OF ASSAM, NAGALAND, MIZORAM AND ARUNACHAL PRADESH) PRINCIPAL SEAT AT GUWAHATI (CIVIL REVISIONAL JURISDICTION) CRP No. 380 of 2014 M/S Shriram Transport Finance

More information

SLP(C) No. 3052/08 etc. ITEM NO.66 COURT NO.10 SECTION XVII SUPREME COURT OF INDIA RECORD OF PROCEEDINGS

SLP(C) No. 3052/08 etc. ITEM NO.66 COURT NO.10 SECTION XVII SUPREME COURT OF INDIA RECORD OF PROCEEDINGS SLP(C) No. 3052/08 etc. ITEM NO.66 COURT NO.10 SECTION XVII SUPREME COURT OF INDIA RECORD OF PROCEEDINGS Petition(s) for Special Leave to Appeal (Civil) No(s).3052/2008 (From the judgement and order dated

More information

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : ARBITRATION AND CONCILIATION ACT, Date of Reserve: Date of Order:

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : ARBITRATION AND CONCILIATION ACT, Date of Reserve: Date of Order: IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : ARBITRATION AND CONCILIATION ACT, 1996 Date of Reserve: 27.1..2009 Date of Order: 05.02.2009 OMP No. 36/2009 Competent Investment Limited... Petitioner

More information

* IN THE HIGH COURT OF DELHI AT NEW DELHI. + W.P.(C) 4784/2014 and CM No.9529/2014 (Stay)

* IN THE HIGH COURT OF DELHI AT NEW DELHI. + W.P.(C) 4784/2014 and CM No.9529/2014 (Stay) * IN THE HIGH COURT OF DELHI AT NEW DELHI + W.P.(C) 4784/2014 and CM No.9529/2014 (Stay) Pronounced on: December 11, 2015 M/S IMS MERCANTILES PVT. LTD.... Petitioner Through: Mr.Bharat Gupta with Mr.Saurabh

More information

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : CODE OF CIVIL PROCEDURE FAO.No.301/2010 Reserved on: Decided on:

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : CODE OF CIVIL PROCEDURE FAO.No.301/2010 Reserved on: Decided on: IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : CODE OF CIVIL PROCEDURE FAO.No.301/2010 Reserved on:09.02.2011 Decided on: 18.02.2011 WOLLAQUE VENTILATION & CONDITIONING PVT LTD. Appellant Through: Mr.

More information

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : THE ARCHITECTS ACT, 1972 Date of decision: 4th January, 2012 WP(C) NO.8653/2008

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : THE ARCHITECTS ACT, 1972 Date of decision: 4th January, 2012 WP(C) NO.8653/2008 IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : THE ARCHITECTS ACT, 1972 Date of decision: 4th January, 2012 WP(C) NO.8653/2008 INSTITUTE OF TOWN PLANNERS, INDIA... Petitioner Through: Mr. Rakesh Kumar

More information

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT: EXEMPTION FROM PAYING TOLL OR FEE. Judgment delivered on : WP(C) No /2006.

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT: EXEMPTION FROM PAYING TOLL OR FEE. Judgment delivered on : WP(C) No /2006. IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT: EXEMPTION FROM PAYING TOLL OR FEE Judgment delivered on :06.03.2007 WP(C) No.5686-87/2006 COL. T. PRASAD & ANOTHER...Petitioners versus UNION OF INDIA &

More information

NO COMPENDSATION FOR DELAY IN CONSTRUCTION CONTRACTS

NO COMPENDSATION FOR DELAY IN CONSTRUCTION CONTRACTS An Open Access Journal from The Law Brigade (Publishing) Group 192 NO COMPENDSATION FOR DELAY IN CONSTRUCTION CONTRACTS Written by Surabhi Vats 4th Year BA LLB Student, Jindal Global Law School We can

More information

* IN THE HIGH COURT OF DELHI AT NEW DELHI. + CS(OS) No.2524A/1995 & IA No.515/1996

* IN THE HIGH COURT OF DELHI AT NEW DELHI. + CS(OS) No.2524A/1995 & IA No.515/1996 * IN THE HIGH COURT OF DELHI AT NEW DELHI + CS(OS) No.2524A/1995 & IA No.515/1996 Date of Decision: January 08, 2010 M/S. SCANDIA SHIPBROKERING & AGENCY LTD...Plaintiff Through: Mr.Prashant Pratap and

More information

1) LPA 561/2010. versus 2) LPA 562/2010. versus 3) LPA 563/2010

1) LPA 561/2010. versus 2) LPA 562/2010. versus 3) LPA 563/2010 IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : PATENTS ACT LPA No.561 of 2010, LPA No.562 of 2010, LPA No.563 of 2010 & LPA No.564 of 2010 Reserved on: February 02, 2012 Pronounced on: April 20, 2012

More information

IN THE SUPREME COURT OF INDIA CIVIL ORIGINAL JURISDICTION

IN THE SUPREME COURT OF INDIA CIVIL ORIGINAL JURISDICTION IN THE SUPREME COURT OF INDIA CIVIL ORIGINAL JURISDICTION Special Leave Petition (C) No.of 2016 (Diary No. 36526 of 2016) NOIDA Toll Bridge Company Ltd. Versus... Petitioner(s) Federation of NOIDA Residents

More information

IN THE HIGH COURT OF GUJARAT AT AHMEDABAD Special Civil Application No of 2015 AUTOMARK INDUSTRIES (I) LTD Vs STATE OF GUJARAT AND 3 Harsha Deva

IN THE HIGH COURT OF GUJARAT AT AHMEDABAD Special Civil Application No of 2015 AUTOMARK INDUSTRIES (I) LTD Vs STATE OF GUJARAT AND 3 Harsha Deva IN THE HIGH COURT OF GUJARAT AT AHMEDABAD Special Civil Application No.13641 of 2015 AUTOMARK INDUSTRIES (I) LTD Vs STATE OF GUJARAT AND 3 Harsha Devani & A G Uraizee, JJ Appellants Rep by: Mr SN Soparkar,

More information

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : RIGHT TO INFORMATION ACT, Date of Decision: W.P.(C) 12210/2009

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : RIGHT TO INFORMATION ACT, Date of Decision: W.P.(C) 12210/2009 IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : RIGHT TO INFORMATION ACT, 2005 Date of Decision: 16.01.2012 W.P.(C) 12210/2009 NORTHERN ZONE RAILWAY EMPLOYEES CO-OPERATIVE THRIFT AND CREDIT SOCIETY LTD...

More information

IN THE HIGH COURT OF DELHI AT NEW DELHI. SUBJECT : Delhi Sales Tax Act, Judgment reserved on : Judgment delivered on :

IN THE HIGH COURT OF DELHI AT NEW DELHI. SUBJECT : Delhi Sales Tax Act, Judgment reserved on : Judgment delivered on : IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : Delhi Sales Tax Act, 1975 Judgment reserved on : 19.08.2008 Judgment delivered on : 09.01.2009 STR Nos. 5/1989 THE COMMISSIONER OF SALES TAX... Appellant

More information

IN THE HIGH COURT OF DELHI AT NEW DELHI. CS(OS) No.2397/2006 and IA No.7807/07 (S.151 CPC by Def.1and2 ) Date of decision:

IN THE HIGH COURT OF DELHI AT NEW DELHI. CS(OS) No.2397/2006 and IA No.7807/07 (S.151 CPC by Def.1and2 ) Date of decision: IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : SUIT FOR SPECIFIC PERFORMANCE CS(OS) No.2397/2006 and IA No.7807/07 (S.151 CPC by Def.1and2 ) Date of decision: 06.11.2007 SUKHBIR SHOKEN... PLAINTIFF

More information

IN THE GAUHATI HIGH COURT (THE HIGH COURT OF ASSAM, NAGALAND, MEGHALAYA, MANIPUR,

IN THE GAUHATI HIGH COURT (THE HIGH COURT OF ASSAM, NAGALAND, MEGHALAYA, MANIPUR, IN THE GAUHATI HIGH COURT (THE HIGH COURT OF ASSAM, NAGALAND, MEGHALAYA, MANIPUR, TRIPURA, MIZORAM AND ARUNACHAL PRADESH) WP (C) No. 3522/2000 1. Dhansiri Valley Project Oil and Natural Gas Commission

More information

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : CONTRACT ACT. Judgment reserved on : October 15, Judgment delivered on : November 04, 2008

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : CONTRACT ACT. Judgment reserved on : October 15, Judgment delivered on : November 04, 2008 IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : CONTRACT ACT Judgment reserved on : October 15, 2008 Judgment delivered on : November 04, 2008 RFA 303/1997 SMT. LAJYA WANTI... Through: Appellant Mr.

More information

Review Petition No.116/2015 In Arb. Pet. No.17/2013 (D/O). 1. The Gauhati Municipal Corporation. Panbazar, Guwahati.

Review Petition No.116/2015 In Arb. Pet. No.17/2013 (D/O). 1. The Gauhati Municipal Corporation. Panbazar, Guwahati. IN THE GAUHATI HIGH COURT (HIGH COURT OF ASSAM, NAGALAND, MIZORAM AND ARUNACHAL PRADESH) Review Petition No.116/2015 In Arb. Pet. No.17/2013 (D/O). 1. The Gauhati Municipal Corporation Panbazar, Guwahati,

More information

IN THE HIGH COURT OF JUDICATURE AT BOMBAY ORDINARY ORIGINAL CIVIL JURISDICTION

IN THE HIGH COURT OF JUDICATURE AT BOMBAY ORDINARY ORIGINAL CIVIL JURISDICTION IN THE HIGH COURT OF JUDICATURE AT BOMBAY ORDINARY ORIGINAL CIVIL JURISDICTION INCOME TAX APPEAL NO.2012 OF 2011 The Commissioner of Income Tax 10, Aayakar Bhavan, M. K. Road, Mumbai-400020...Appellant.

More information

.. IN HIGH COURT OF DELHI:AT NEW DELHI SUBJECT : CODE OF CIVIL PROCEDURE. I.A. No /2006 in C.S.(OS) No.795/2004

.. IN HIGH COURT OF DELHI:AT NEW DELHI SUBJECT : CODE OF CIVIL PROCEDURE. I.A. No /2006 in C.S.(OS) No.795/2004 .. IN HIGH COURT OF DELHI:AT NEW DELHI SUBJECT : CODE OF CIVIL PROCEDURE I.A. No. 11454/2006 in C.S.(OS) No.795/2004 Judgment Reserved on: 09.08.2011 Judgment Pronounced on: 02.11.2011 MADAN LAL KHANNA

More information

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT :CODE OF CIVIL PROCEDURE. FAO (OS) No.178/2008. Judgment Reserved on : 30th September, 2008

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT :CODE OF CIVIL PROCEDURE. FAO (OS) No.178/2008. Judgment Reserved on : 30th September, 2008 IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT :CODE OF CIVIL PROCEDURE FAO (OS) No.178/2008 Judgment Reserved on : 30th September, 2008 Judgment pronounced on : 9th January, 2009 Ms. Jyotika Kumar...

More information

* IN THE HIGH COURT OF DELHI AT NEW DELHI + CRL.M.C. 5096/2015 & Crl.M.A /2015 Date of Decision : January 13 th, 2016.

* IN THE HIGH COURT OF DELHI AT NEW DELHI + CRL.M.C. 5096/2015 & Crl.M.A /2015 Date of Decision : January 13 th, 2016. * IN THE HIGH COURT OF DELHI AT NEW DELHI + CRL.M.C. 5096/2015 & Crl.M.A. 18348/2015 Date of Decision : January 13 th, 2016 ANGLE INFRASTRUCTURE P.LTD.... Petitioner Through Mr.Akhil Sibal,Ms.Bina Gupta,

More information

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : CODE OF CIVIL PROCEDURE. CS(OS)No.1307/2006. Date of decision:16th January, 2009

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : CODE OF CIVIL PROCEDURE. CS(OS)No.1307/2006. Date of decision:16th January, 2009 IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : CODE OF CIVIL PROCEDURE CS(OS)No.1307/2006 Date of decision:16th January, 2009 SMT. TARAN JEET KAUR... Through: Plaintiff Mr. Rajeev Awasthi, Advocate

More information

$~ * IN THE HIGH COURT OF DELHI AT NEW DELHI % Reserved on: 29 th November, 2017 Pronounced on: 08 th December versus

$~ * IN THE HIGH COURT OF DELHI AT NEW DELHI % Reserved on: 29 th November, 2017 Pronounced on: 08 th December versus $~ * IN THE HIGH COURT OF DELHI AT NEW DELHI % Reserved on: 29 th November, 2017 Pronounced on: 08 th December 2017 + ARB.P. 9/2017 CVS INSURANCE AND INVESTMENTS... Petitioner Through : Ms.Pritha Srikumar

More information

order imposes the following restrictions on the petitioner:-

order imposes the following restrictions on the petitioner:- THE HIGH COURT OF DELHI AT NEW DELHI % Judgment delivered on: 22.01.2010 + WP(C) 14152/2009 & CM 16314/2009 VINAY WIRES AND POLY PRODUCTS PVT LTD THROUGH ITS AUTHORISED SIGNATORY H P KANODIA... Petitioner

More information

II (2013) CPJ 10A (NC) (CN) NATIONAL CONSUMER DISPUTES REDRESSAL COMMISSION, NEW DELHI Hon ble Mr. Justice V.B. Gupta, Presiding Member PARMOD KUMAR

II (2013) CPJ 10A (NC) (CN) NATIONAL CONSUMER DISPUTES REDRESSAL COMMISSION, NEW DELHI Hon ble Mr. Justice V.B. Gupta, Presiding Member PARMOD KUMAR II (2013) CPJ 10A (NC) (CN) NATIONAL CONSUMER DISPUTES REDRESSAL COMMISSION, NEW DELHI Hon ble Mr. Justice V.B. Gupta, Presiding Member PARMOD KUMAR MALIK Petitioner versus HARYANA URBAN DEVELOPMENT AUTHORITY

More information

IN THE SUPREME COURT OF INDIA CIVIL ORIGINAL JURISDICTION WRIT PETITION (CIVIL) NO.631 OF 2016

IN THE SUPREME COURT OF INDIA CIVIL ORIGINAL JURISDICTION WRIT PETITION (CIVIL) NO.631 OF 2016 IN THE SUPREME COURT OF INDIA CIVIL ORIGINAL JURISDICTION WRIT PETITION (CIVIL) NO.631 OF 2016 REPORTABLE UNITED AIR TRAVEL SERVICES Through ITS PROPRIETOR A.D.M. ANWAR KHAN.PETITIONER Versus UNION OF

More information

BIHAR ELECTRICITY REGULATORY COMMISSION, PATNA FEES, FINES AND CHARGES REGULATIONS,

BIHAR ELECTRICITY REGULATORY COMMISSION, PATNA FEES, FINES AND CHARGES REGULATIONS, fuca/ku la0 ih0 Vh0&40 fcgkj xtv vlk/kkj.k vad fcgkj ljdkj }kjk izdkf kr 21TH MAGHA 1927(S) (NO. PATNA 95) PATNA, FRIDAY, 10th FEBRUARY, 2006 BIHAR ELECTRICITY REGULATORY COMMISSION, PATNA FEES, FINES

More information

* IN THE HIGH COURT OF DELHI AT NEW DELHI + W.P.(C) 7262/2014

* IN THE HIGH COURT OF DELHI AT NEW DELHI + W.P.(C) 7262/2014 * IN THE HIGH COURT OF DELHI AT NEW DELHI + W.P.(C) 7262/2014 Pronounced on: 03.02.2015 PRINCE KUMAR & ORS.... Appellant Through: Mr.Anil Sapra, Sr.Adv. with Mr.Tarun Kumar Tiwari, Mr.Mukesh Sukhija, Ms.Rupali

More information

IN THE HIGH COURT OF DELHI AT NEW DELHI COMPANY JURISDICTION COMPANY PETITION NO. 406 OF 2009

IN THE HIGH COURT OF DELHI AT NEW DELHI COMPANY JURISDICTION COMPANY PETITION NO. 406 OF 2009 IN THE HIGH COURT OF DELHI AT NEW DELHI COMPANY JURISDICTION COMPANY PETITION NO. 406 OF 2009 Reserved on : 11-05-2010 Date of pronouncement: 04-06-2010 M/s Kesinga Paper Mills Private Limited..Petitioner

More information

$~21 to 34 * IN THE HIGH COURT OF DELHI AT NEW DELHI % Date of Decision: W.P.(C) 4304/2018 & CM APPL.16759/2018

$~21 to 34 * IN THE HIGH COURT OF DELHI AT NEW DELHI % Date of Decision: W.P.(C) 4304/2018 & CM APPL.16759/2018 $~21 to 34 * IN THE HIGH COURT OF DELHI AT NEW DELHI % Date of Decision: 01.10.2018 + W.P.(C) 4304/2018 & CM APPL.16759/2018 SURENDRA KUMAR JAIN 22 + W.P.(C) 4305/2018 & CM APPL.16760/2018 SURENDRA KUMAR

More information

IN THE GAUHATI HIGH COURT (THE HIGH COURT OF ASSAM, NAGALAND, MIZORAM AND ARUNACHAL PRADESH)

IN THE GAUHATI HIGH COURT (THE HIGH COURT OF ASSAM, NAGALAND, MIZORAM AND ARUNACHAL PRADESH) IN THE GAUHATI HIGH COURT (THE HIGH COURT OF ASSAM, NAGALAND, MIZORAM AND ARUNACHAL PRADESH) WP(C) No. 2882/2005 M/s. Ladi Steel Industries Pvt. Limited, a private limited company duly incorporated under

More information

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : ARBITRATION & CONCILIATION ACT, OMP No. 658 of Date of order: November 21, 2011.

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : ARBITRATION & CONCILIATION ACT, OMP No. 658 of Date of order: November 21, 2011. IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : ARBITRATION & CONCILIATION ACT, 1996 OMP No. 658 of 2011 Date of order: November 21, 2011 VF SERVICES (UK) LIMITED... Petitioner Through: Mr. Neeraj Kishan

More information

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : CONTRACT ACT. FAO(OS) No.240/2008. Date of Hearing : August 11, 2011

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : CONTRACT ACT. FAO(OS) No.240/2008. Date of Hearing : August 11, 2011 IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : CONTRACT ACT FAO(OS) No.240/2008 Date of Hearing : August 11, 2011 Date of Decision: August 30, 2011 GAIL(INDIA) LIMITED...Appellant through Mr. Jagjit

More information

CONTENTS. Industrial Employment (Standing Orders) Act, Preamble

CONTENTS. Industrial Employment (Standing Orders) Act, Preamble CONTENTS Industrial Employment (Standing Orders) Act, 1946 Sections Preamble 1. Short title, extent and application 2. Interpretation 3. Submission of draft standing orders 4. Conditions for certification

More information

IN THE HIGH COURT OF DELHI AT NEW DELHI

IN THE HIGH COURT OF DELHI AT NEW DELHI IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : Sections 13(2) of the Securitisation and Reconstruction of Financial Assets and Enforcement of Securities Interest Ordinance (II) 2002 W.P.(C) 191/2008

More information

$~ * IN THE HIGH COURT OF DELHI AT NEW DELHI % Reserved on: 22 nd November, 2017 Pronounced on: 11 th December, 2017 POWER GRID CORPORATION

$~ * IN THE HIGH COURT OF DELHI AT NEW DELHI % Reserved on: 22 nd November, 2017 Pronounced on: 11 th December, 2017 POWER GRID CORPORATION $~ * IN THE HIGH COURT OF DELHI AT NEW DELHI % Reserved on: 22 nd November, 2017 Pronounced on: 11 th December, 2017 + O.M.P.(COMM.) 397/2016 POWER GRID CORPORATION OF INDIA LTD.... Petitioner Through

More information

THE PAYMENT OF WAGES ACT, 1936

THE PAYMENT OF WAGES ACT, 1936 THE PAYMENT OF WAGES ACT, 1936 An Act to regulate the payment of wages to all classes of employed persons. WHEREAS it is expedient to regulate the payment of wages to all classes of employed persons Responsibility

More information

IN THE SUPREME COURT OF INDIA CIVIL APPELLATE JURISDICTION CIVIL APPEAL NO. 210 OF 2007 STATE BANK OF PATIALA APPELLANT MUKESH JAIN & ANR.

IN THE SUPREME COURT OF INDIA CIVIL APPELLATE JURISDICTION CIVIL APPEAL NO. 210 OF 2007 STATE BANK OF PATIALA APPELLANT MUKESH JAIN & ANR. 1 REPORTABLE IN THE SUPREME COURT OF INDIA CIVIL APPELLATE JURISDICTION CIVIL APPEAL NO. 210 OF 2007 STATE BANK OF PATIALA APPELLANT VERSUS MUKESH JAIN & ANR. RESPONDENTS J U D G M E N T ANIL R. DAVE,

More information

PARLIAMENT OF THE DEMOCRATIC SOCIALIST REPUBLIC OF SRI LANKA ARBITRATION ACT NO. 11 OF 1995

PARLIAMENT OF THE DEMOCRATIC SOCIALIST REPUBLIC OF SRI LANKA ARBITRATION ACT NO. 11 OF 1995 PARLIAMENT OF THE DEMOCRATIC SOCIALIST REPUBLIC OF SRI LANKA ARBITRATION ACT NO. 11 OF 1995 (Certified on 30 th June-1995) Arbitration Act. No. 11 of 1995 1 (Certified on 30 th June-1995) L.D. O.10/93

More information

THE HIGH COURT OF DELHI AT NEW DELHI % Judgment delivered on: versus

THE HIGH COURT OF DELHI AT NEW DELHI % Judgment delivered on: versus THE HIGH COURT OF DELHI AT NEW DELHI % Judgment delivered on: 20.04.2010 + WP (C) 13338/2009 APOLLO TYRES LTD, KOCHI Petitioner - versus UNION OF INDIA... Respondent Advocates who appeared in this case:-

More information

TNT India Private Limited } Petitioner versus Principal Commissioner of } Customs (II) and Ors. } Respondents

TNT India Private Limited } Petitioner versus Principal Commissioner of } Customs (II) and Ors. } Respondents IN THE HIGH COURT OF JUDICATURE AT BOMBAY ORDINARY ORIGINAL CIVIL JURISDICTION WRIT PETITION (L) NO. 2876 OF 2015 TNT India Private Limited } Petitioner versus Principal Commissioner of } Customs (II)

More information

IN THE SUPREME COURT OF INDIA CIVIL APPELLATE JURISDICTION CIVIL APPEAL NO OF 2018 RAMESHWAR PRASAD SHRIVASTAVA AND ORS.

IN THE SUPREME COURT OF INDIA CIVIL APPELLATE JURISDICTION CIVIL APPEAL NO OF 2018 RAMESHWAR PRASAD SHRIVASTAVA AND ORS. 1 Reportable IN THE SUPREME COURT OF INDIA CIVIL APPELLATE JURISDICTION CIVIL APPEAL NO. 5802 OF 2018 RAMESHWAR PRASAD SHRIVASTAVA AND ORS. Appellants VERSUS DWARKADHIS PROJECTS PVT. LTD. AND ORS.... Respondents

More information

*IN THE HIGH COURT OF DELHI AT NEW DELHI. % Date of decision:1 st December, 2009 M/S ANSAL PROPERTIES & INFRASTRUCTURE. Versus

*IN THE HIGH COURT OF DELHI AT NEW DELHI. % Date of decision:1 st December, 2009 M/S ANSAL PROPERTIES & INFRASTRUCTURE. Versus *IN THE HIGH COURT OF DELHI AT NEW DELHI + CM(M) No.807/2008. % Date of decision:1 st December, 2009 M/S ANSAL PROPERTIES & INFRASTRUCTURE LTD & ANR. Petitioner Through: Mr Prem Kumar and Mr Sharad C.

More information

IN THE SUPREME COURT OF INDIA CIVIL APPELLATE JURISDICTION. CIVIL APPEAL NO Of 2011 SRI MAHABIR PROSAD CHOUDHARY...APPELLANT(S) VERSUS

IN THE SUPREME COURT OF INDIA CIVIL APPELLATE JURISDICTION. CIVIL APPEAL NO Of 2011 SRI MAHABIR PROSAD CHOUDHARY...APPELLANT(S) VERSUS 1 IN THE SUPREME COURT OF INDIA REPORTABLE CIVIL APPELLATE JURISDICTION CIVIL APPEAL NO. 8320 Of 2011 SRI MAHABIR PROSAD CHOUDHARY...APPELLANT(S) VERSUS M/S. OCTAVIUS TEA AND INDUSTRIES LTD. AND ANR....RESPONDENT(S)

More information

IN THE HIGH COURT OF JUDICATURE AT BOMBAY ORDINARY ORIGINAL CIVIL JURISDICTION WRIT PETITION NO.1374 OF 2008

IN THE HIGH COURT OF JUDICATURE AT BOMBAY ORDINARY ORIGINAL CIVIL JURISDICTION WRIT PETITION NO.1374 OF 2008 Chittewan 1/9 1. WP 1374-08.odt IN THE HIGH COURT OF JUDICATURE AT BOMBAY ORDINARY ORIGINAL CIVIL JURISDICTION WRIT PETITION NO.1374 OF 2008 Sea Face Park Co operative Housing Societies Petitioner Versus

More information

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : SERVICE MATTER. WP (C) No.4604/1996. Reserved on: Date of decision:

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : SERVICE MATTER. WP (C) No.4604/1996. Reserved on: Date of decision: IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : SERVICE MATTER WP (C) No.4604/1996 Reserved on: 11.07.2008 Date of decision: 11.08.2008 SOHAN LAL KAPOOR Through: Major K.Ramesh, Advocate..PETITIONER

More information

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : CODE OF CIVIL PROCEDURE. Writ Petition (Civil) No of 2008 and CM No.

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : CODE OF CIVIL PROCEDURE. Writ Petition (Civil) No of 2008 and CM No. IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : CODE OF CIVIL PROCEDURE Writ Petition (Civil) No. 7230 of 2008 and CM No.13974 of 2008 Decided on: October 03, 2008 1. The Secretary Ministry of Home Affairs

More information

Through Mr.Prabhjit Jauhar Adv. with Ms.Anupama Kaul, Adv.

Through Mr.Prabhjit Jauhar Adv. with Ms.Anupama Kaul, Adv. IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : ARBITRATION AND CONCILIATION ACT, 1996 Judgment Reserved on: February 19, 2013 Judgment Pronounced on: July 01, 2013 O.M.P. No.9/2012 DARPAN KATYAL...

More information

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : SUIT FOR PERPETUAL, MANDATORY INJUNCTION. Date of Judgment: CM(M) No.

IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : SUIT FOR PERPETUAL, MANDATORY INJUNCTION. Date of Judgment: CM(M) No. IN THE HIGH COURT OF DELHI AT NEW DELHI SUBJECT : SUIT FOR PERPETUAL, MANDATORY INJUNCTION Date of Judgment: 14.02.2012 CM(M) No.557/2008 DALMIA CEMENT (BHARAT) LTD. Through: Mr. D.K. Malhotra, Advocate....

More information