FILED: NEW YORK COUNTY CLERK 11/06/ :59 PM INDEX NO /2016 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 11/06/2016
|
|
- Myles Shaw
- 6 years ago
- Views:
Transcription
1 FILED: NEW YORK COUNTY CLERK 11/06/ :59 PM INDEX NO /2016 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 11/06/2016 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK X COLOSSEO DEVELOPMENT GROUP, INC., Index No. Plaintiff, -against- SUMMONS LIFTECH ELEVATOR, LLC, Defendant X TO THE ABOVE NAMED DEFENDANT: PLEASE TAKE NOTICE THAT YOU ARE HEREBY SUMMONED and required to answer the Complaint in this action and to serve a copy of your Answer on the Plaintiff s attorney at the address set forth below within twenty (20) days after the service of this Summons, exclusive of the day of service, or within thirty (30) days after service is complete if this Summons is not personally delivered to you within the State of New York. YOU ARE HEREBY NOTIFIED THAT should you fail to appear or answer the Complaint, JUDGMENT WILL BE TAKEN AGAINST YOU BY DEFAULT FOR THE RELIEF DEMANDED HEREIN. Plaintiff designates New York County as the place of venue. The basis of venue is CPLR sections 301 and 302. Dated: New York, New York November 6, 2016 GIORDANO HALLERAN & CIESLA, P.C. TO: By: TIMOTHY J. DEHAUT Attorneys for Plaintiff Colosseo Development Group, Inc Broadway, 36th Floor New York, NY (646) LIFTECH ELEVATOR, LLC 11 Fessenden Place, Newark, New Jersey of 8
2 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK X COLOSSEO DEVELOPMENT GROUP, INC., Index No. Plaintiff, -against- COMPLAINT LIFTECH ELEVATOR, LLC, Defendant X Plaintiff Colosseo Development Group, Inc., ( Colosseo ), by and through its attorneys, Giordano, Halleran & Ciesla, PC, alleges for its complaint against defendant Liftech Elevator, LLC ( Liftech ) as follows: Nature of Action 1. This is an action for breach of contract and related equitable claims against Liftech, an entity that entered into a subcontract with Colosseo, a general contractor, to recover substantial monetary damages resulting from Liftech s failure to comply with the terms of the subcontract between Colosseo and Liftech. 2. As alleged more fully below, Liftech entered into an agreement with Colosseo to perform elevator installation and service work at the building located at 432 West 58 th Street, New York, New York, but Liftech unlawfully failed to fulfill its contractual obligations and breached its contract with Colosseo, causing Colosseo to suffer significant damages. 2 2 of 8
3 The Parties and Jurisdiction 3. Colosseo is a domestic Corporation organized in and existing pursuant to the laws of the State of New York with its principal place of business located at 244 Madison Avenue, Suite 2910, New York, New York Upon information and belief, Liftech is a New Jersey Limited Liability Company with principal place of business of 11 Fessenden Place, Newark, New Jersey Liftech does business in the State of New York. 6. The contract that forms the basis of this claim was made with a New York Corporation contemplated work and services to be performed at 432 West 58 th Street, New York, New York. 7. The acts giving rise to the claims herein occurred in the State of New York. 8. Jurisdiction is proper in New York pursuant to CPLR 301 and for 302. The Facts 9. Colosseo is the general contractor for the construction project located at 432 West 58 th Street, New York, New York (the Project ). 10. On or about August 9, 2016, Colosseo entered into a written agreement with Liftech pursuant to which Liftech, as a subcontractor, was required to provide certain labor, services and materials to furnish and install two 12 stop passenger elevators at 432 West 58 th Street, New York, New York (the Subcontract ). 11. As set forth in the Subcontract, Liftech was required, among other things, to install the two (2) elevators in accordance with accepted manufacturer s directions and ANSI A17.1 and all City and State applicable codes. 3 3 of 8
4 12. Pursuant to the terms of the Subcontract, the man power and services to be provided by Liftech were to include project planning and scheduling in order that the performance of the elevator installation work could proceed when the Project was advanced to the stage for such installation. 13. Pursuant to the terms of the Subcontract Colosseo was to pay Liftech a total contract price of $100, in exchange for Liftech performance of the work, payable pursuant to a payment schedule set forth in the Subcontract. 14. The Subcontract payment schedule provided that a $30, deposit was due from Colosseo to Liftech upon the signing of the Subcontract. 15. By check dated August 12, 2016 Colosseo paid a $30, deposit to Liftech. 16. Liftech deposited Colosseo s check in the amount of $30, on or about the date it was received from Colosseo. 17. Colosseo notified Liftech that Liftech should have personnel present at the Project in order to schedule its work and coordinate its work in conjunction with the other construction trades. 18. Liftech failed and refused to send any personnel to the Project and failed to provide a schedule of coordinated work. 19. During August 2016, Colosseo continued to request a schedule and manpower for installation work. 20. Liftech failed and refused to send any Liftech personnel to the Project in order to begin the installation process and remained non-responsive. 21. Colosseo advised Liftech that the work on the elevators needed to proceed and that if there was a delay there was a risk the Project could not be completed timely. 4 4 of 8
5 22. Liftech failed to advise Colosseo if or when it would send any Liftech personnel to the Project to proceed with the elevator installation work, notwithstanding Liftech s obligation to do so pursuant to the terms of the Subcontract. 23. At all relevant time since the Subcontract was signed, Liftech failed and refused to send any personnel to the Project. 24. Liftech failed to even explain the reasons why it refused to fulfill the terms of the Subcontract. 25. As a result of Liftech s failure and refusal to fulfill the terms of the Subcontract, Colosseo has been required to divert its own employee manpower, to perform the installation work that was to be performed by Liftech pursuant to the Subcontract. 26. As a direct and proximate result of the acts of Liftech described above. Colosseo has been damaged in an amount not less than $30, First Cause of Action (Breach of Contract) 27. Colosseo repeats and realleges the allegations set forth in paragraphs 1-26 as if fully set forth herein. 28. Pursuant to the Subcontract, Liftech was required to perform elevator installation and maintenance services in connection with the Project. 29. Liftech has failed and/or refused to provide the services it was required to provide under the Subcontract, which conduct has resulted in damage to Colosseo. 30. Colosseo has at all times pertinent to this action satisfied all of its contractual obligations under the Subcontract, including the payment of a $30, deposit. 5 5 of 8
6 31. Liftech has neither performed the work called for under the Subcontract nor returned the $30, deposit made by Colosseo. 32. Liftech is in breach of its obligations under the Subcontract. 33. By reason of the foregoing, Colosseo has suffered compensatory damages in an amount to be determined at trial, but not less than $30,000.00, as well as impact costs, delay damages and consequential damages in an amount to be determined at trial. Second Cause of Action (Unjust Enrichment) 34. Colosseo repeats and realleges the allegations set forth in paragraphs 1-33 as if fully set forth herein. 35. As a direct and proximate result of the aforesaid wrongful acts of Liftech, Liftech has received a benefit at the expense and to the detriment of Colosseo. 36. It would be unjust and inequitable, as well as against equity and good conscience for Liftech to retain the aforesaid benefit, including but not limited to the $30, deposit, without paying Colosseo due compensation therefore. 37. Liftech has been unjustly enriched. 38. By reason of the foregoing, Liftech is indebted to Colosseo, and Colosseo has been damaged in an amount to be determined at trial, but not less than $30, Third Cause of Action (Good Faith and Fair Dealing) 39. Colosseo repeats and realleges the allegations set forth in paragraphs 1-38 as if fully set forth herein 6 6 of 8
7 40. There is included in the Subcontract an implied duty of good faith and fair dealing owed by Liftech to Colosseo. 41. As a direct and proximate result of the wrongful conduct of Liftech described herein, Liftech acted to realize gains under the Subcontract to which it was not entitled and deprived Colosseo of the fruit of its bargain. 42. Liftech has breached the implied duty of good faith and fair dealing that it owed to Colosseo. 43. By reason of the foregoing, Liftech is indebted to Colosseo and Colosseo has been damaged in amount to be determined at trial, but not less than $30, WHEREFORE, Colosseo demands judgment against Liftech as follows: A. On the First Cause of Action, damages in amount to be determined at trial, but not less than $30,000.00; B. On the Second Cause of Action, damages in amount to be determined at trial, but not less than $30,000.00; C. On the Third Cause of Action, damages in amount to be determined at trial, but not less than $30,000.00; D. Court costs and disbursements; E. Attorneys fees reasonably incurred by Colosseo in connection with this action; and F. Such other and further relief as the Court deems just and appropriate. 7 7 of 8
8 Dated: New York, New York November 6, 2016 GIORDANO HALLERAN & CIESLA, P.C. By: TIMOTHY J. DEHAUT Attorneys for Plaintiff Colosseo Development Group, Inc Broadway, 36th Floor New York, NY (646) TO: LIFTECH ELEVATOR, LLC 11 Fessenden Place, Newark, New Jersey Docs # v1 8 8 of 8
FILED: NEW YORK COUNTY CLERK 06/14/ :52 AM INDEX NO /2016 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 06/14/2016
FILED: NEW YORK COUNTY CLERK 06/14/2016 10:52 AM INDEX NO. 154973/2016 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 06/14/2016 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK - - - - - - - - - - - - -
More informationFILED: NEW YORK COUNTY CLERK 02/06/2014 INDEX NO /2014 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 02/06/2014
FILED: NEW YORK COUNTY CLERK 02/06/2014 INDEX NO. 650412/2014 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 02/06/2014 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK --------------------------------------------------------------------)(
More informationFILED: ERIE COUNTY CLERK 09/19/ :42 PM INDEX NO /2014 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 09/19/2014
FILED: ERIE COUNTY CLERK 09/19/2014 03:42 PM INDEX NO. 810780/2014 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 09/19/2014 STATE OF NEW YORK SUPREME COURT: COUNTY OF ERIE WILL FOODS, LLC 1 07 5 William Street Buffalo,
More informationFILED: KINGS COUNTY CLERK 03/28/ :51 PM INDEX NO /2016 NYSCEF DOC. NO. 25 RECEIVED NYSCEF: 03/28/2017
, EXHIBITE [FILED: KINGS COUNTY CLERK 02/21/2017 04:12 PM] SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF KINGS SELVIN ESPINAL RODRJGUEZ, -against- Plaintiff, 91 & 95 28TH STREET, JACKSON HEIGHTS, IN
More informationFILED: NEW YORK COUNTY CLERK 09/13/ :43 PM INDEX NO /2015 NYSCEF DOC. NO. 47 RECEIVED NYSCEF: 09/13/2016. Exhibit 1
FILED: NEW YORK COUNTY CLERK 09/13/2016 07:43 PM INDEX NO. 651052/2015 NYSCEF DOC. NO. 47 RECEIVED NYSCEF: 09/13/2016 Exhibit 1 FILED: NEW YORK COUNTY CLERK 03/31/2015 06:03 PM INDEX NO. 651052/2015 NYSCEF
More informationFILED: KINGS COUNTY CLERK 06/08/ /30/ :11 03:00 PM INDEX NO /2015 NYSCEF DOC. NO. 13 RECEIVED NYSCEF: 06/08/2015
FILED: KINGS COUNTY CLERK 06/08/2015 10/30/2015 05:11 03:00 PM INDEX NO. 507018/2015 NYSCEF DOC. NO. 13 RECEIVED NYSCEF: 06/08/2015 10/30/2015 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF KINGS -----------------------------------------------------------------------------------X
More informationThird-Party Plaintiff, Third-Party Defendant x YOU ARE HEREBY SUMMONED, to answer the Complaint of the
FILED: NEW YORK COUNTY CLERK 02/17/2016 04:37 PM INDEX NO. 156590/2013 NYSCEF DOC. NO. 30 RECEIVED NYSCEF: 02/17/2016 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK MICHAEL ROSSANI, Index No.:
More informationFILED: NASSAU COUNTY CLERK 12/14/ :53 PM INDEX NO /2018 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 12/14/2018
SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NASSAU... ------X Index No. PRACTICE PROVIDER CORPORATION, Date of Purchase: Plaintiff, SUMMONS - against - Plaintiff designates Nassau County as the place
More informationFILED: NEW YORK COUNTY CLERK 10/08/ :47 PM INDEX NO /2015 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 10/08/2015
FILED NEW YORK COUNTY CLERK 10/08/2015 1247 PM INDEX NO. 653360/2015 NYSCEF DOC. NO. 1 RECEIVED NYSCEF 10/08/2015 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK x GFI INSURANCE BROKERAGE, INC.,
More informationFILED: NEW YORK COUNTY CLERK 07/26/2013 INDEX NO /2013 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 07/26/2013
FILED: NEW YORK COUNTY CLERK 07/26/2013 INDEX NO. 156836/2013 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 07/26/2013 CONSUMER CREDIT TRANSACTION ------------------------------------------------------------x Index
More informationFILED: NEW YORK COUNTY CLERK 09/30/ :55 PM INDEX NO /2016 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 09/30/2016
FILED: NEW YORK COUNTY CLERK 09/30/2016 01:55 PM INDEX NO. 158275/2016 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 09/30/2016 SUPREME DAVID COURT B. ROSENBAUM, OF THE STATE an OF attorney NEW YORK duly admitted
More informationFILED: NEW YORK COUNTY CLERK 10/09/ :53 PM
FILED: NEW YORK COUNTY CLERK 10/09/2015 03:53 PM INDEX NO. 158764/2015 NYSCEF DOC. NO. 13 RECEIVED NYSCEF: 10/09/2015 Exhibit B to the Affirmation of Howard I. Elman, Esq. in Support of Defendants Motion
More informationFILED: NEW YORK COUNTY CLERK 06/05/ :59 PM INDEX NO /2015 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 06/05/2015
FILED: NEW YORK COUNTY CLERK 06/05/2015 05:59 PM INDEX NO. 651993/2015 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 06/05/2015 SUPREME COURT OF THE STATE OF NEW YORK NEW YORK COUNTY YYSB TRUST against Plaintiff,
More informationFILED: NEW YORK COUNTY CLERK 06/02/ /15/ :56 02:55 AM PM INDEX NO /2015 NYSCEF DOC. NO. 149 RECEIVED NYSCEF: 06/02/2015
FILED: NEW YORK COUNTY CLERK 06/02/2015 09/15/2016 10:56 02:55 AM PM INDEX NO. 651899/2015 NYSCEF DOC. NO. 149 RECEIVED NYSCEF: 06/02/2015 09/15/2016 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW
More informationFILED: NEW YORK COUNTY CLERK 11/04/ :33 PM INDEX NO /2016 NYSCEF DOC. NO. 10 RECEIVED NYSCEF: 11/04/2016
FILED: NEW YORK COUNTY CLERK 11/04/2016 02:33 PM INDEX NO. 654790/2016 NYSCEF DOC. NO. 10 RECEIVED NYSCEF: 11/04/2016 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK ---------------------------------------------------------X
More informationFILED: NEW YORK COUNTY CLERK 10/20/ :37 PM INDEX NO /2014 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 10/20/2014
FILED: NEW YORK COUNTY CLERK 10/20/2014 02:37 PM INDEX NO. 160251/2014 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 10/20/2014 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK ------------------------------------------------------------------------)(
More informationFILED: NEW YORK COUNTY CLERK 09/28/ :27 PM INDEX NO /2016 NYSCEF DOC. NO. 7 RECEIVED NYSCEF: 09/28/2016
FILED NEW YORK COUNTY CLERK 09/28/2016 0627 PM INDEX NO. 653609/2016 NYSCEF DOC. NO. 7 RECEIVED NYSCEF 09/28/2016 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK --------------------------------------------------------------------
More informationFILED: NEW YORK COUNTY CLERK 03/11/ :59 PM INDEX NO /2015 NYSCEF DOC. NO. 9 RECEIVED NYSCEF: 03/11/2015 EXHIBIT A
FILED: NEW YORK COUNTY CLERK 03/11/2015 04:59 PM INDEX NO. 151211/2015 NYSCEF DOC. NO. 9 RECEIVED NYSCEF: 03/11/2015 EXHIBIT A FILED: NEW YORK COUNTY CLERK 02/05/2015 12:03 PM INDEX NO. 151211/2015 NYSCEF
More informationFILED: NEW YORK COUNTY CLERK 01/09/ :26 PM INDEX NO /2016
FILED: NEti YORK COUNTY CLERK INDEX 10/12/2016 NO. NYSCEF DOC. NO. 16 07:Ž$ 158568/;016 AM RECEIVED NYSCEF: 01/09/2018 NYSCEF DOC. NC. 1 RECEIVED NYSCEF: 10/12/'016 SUPREME COURT OF THE STATE OF NEW YORK
More informationFILED: NEW YORK COUNTY CLERK 12/27/ :44 PM INDEX NO /2016 NYSCEF DOC. NO. 2 RECEIVED NYSCEF: 12/27/2016
FILED: NEW YORK COUNTY CLERK 12/27/2016 03:44 PM INDEX NO. 656740/2016 NYSCEF DOC. NO. 2 RECEIVED NYSCEF: 12/27/2016 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK Index No.: Date Purchased:
More informationFILED: NEW YORK COUNTY CLERK 08/02/ /18/ :27 06:12 PM INDEX NO /2016 NYSCEF DOC. NO. 18 RECEIVED NYSCEF: 08/02/2016
FILED: NEW YORK COUNTY CLERK 08/02/2016 11/18/2016 11:27 06:12 PM INDEX NO. 654066/2016 NYSCEF DOC. NO. 18 RECEIVED NYSCEF: 08/02/2016 11/18/2016 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK
More informationFILED: NEW YORK COUNTY CLERK 02/17/ :37 PM INDEX NO /2016 NYSCEF DOC. NO. 23 RECEIVED NYSCEF: 02/17/2017
FILED NEW YORK COUNTY CLERK 02/17/2017 0337 PM INDEX NO. 159897/2016 NYSCEF DOC. NO. 23 RECEIVED NYSCEF 02/17/2017 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK X M & E CHRISTOPHER LLC, Plaintiff,
More informationFILED: NEW YORK COUNTY CLERK 01/23/2012 INDEX NO /2011 NYSCEF DOC. NO. 3 RECEIVED NYSCEF: 01/23/2012. Plaintiff, Defendants.
FILED: NEW YORK COUNTY CLERK 01/23/2012 INDEX NO. 105989/2011 NYSCEF DOC. NO. 3 RECEIVED NYSCEF: 01/23/2012 MIN-WDF-Supelemental Summons 2. SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK...
More informationFILED: NEW YORK COUNTY CLERK 03/08/ :32 PM INDEX NO /2016 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 03/08/2016
FILED: NEW YORK COUNTY CLERK 03/08/2016 02:32 PM INDEX NO. 151976/2016 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 03/08/2016 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK -------------------------------------x
More informationFILED: NEW YORK COUNTY CLERK 10/03/ :34 AM INDEX NO /2014 NYSCEF DOC. NO. 34 RECEIVED NYSCEF: 10/03/2014
FILED: NEW YORK COUNTY CLERK 10/03/2014 09:34 AM INDEX NO. 151547/2014 NYSCEF DOC. NO. 34 RECEIVED NYSCEF: 10/03/2014 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK MILERVA SANTOS, Index No.:
More informationFILED: NEW YORK COUNTY CLERK 07/10/ :25 PM INDEX NO /2016 NYSCEF DOC. NO. 14 RECEIVED NYSCEF: 07/10/2018
. UNAS S I GNE D NYSCEF DOC. NO. 141 RECEIVED NYSCEF: 07/10/2018 09/21/2016 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK ---------------------------------------------------------------------X
More informationFILED: KINGS COUNTY CLERK 10/26/ :38 PM INDEX NO /2015 NYSCEF DOC. NO. 22 RECEIVED NYSCEF: 10/26/2016 EXHIBIT A
FILED: KINGS COUNTY CLERK 10/26/2016 03:38 PM INDEX NO. 512876/2015 NYSCEF DOC. NO. 22 RECEIVED NYSCEF: 10/26/2016 EXHIBIT A FILED: KINGS COUNTY CLERK 10/21/2015 02:58 PM INDEX NO. 512876/2015 NYSCEF DOC.
More informationFILED: NEW YORK COUNTY CLERK 07/26/ :03 PM INDEX NO /2016 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 07/26/2016
FILED: NEW YORK COUNTY CLERK 07/26/2016 03:03 PM INDEX NO. 653911/2016 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 07/26/2016 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK LINEN DEPOT DIRECT, INC.,
More informationFILED: NEW YORK COUNTY CLERK 07/20/ :42 AM INDEX NO /2013 NYSCEF DOC. NO. 67 RECEIVED NYSCEF: 07/20/2015. Exhibit A
FILED: NEW YORK COUNTY CLERK 07/20/2015 11:42 AM INDEX NO. 158552/2013 NYSCEF DOC. NO. 67 RECEIVED NYSCEF: 07/20/2015 Exhibit A FILED: NEW YORK COUNTY CLERK 09/18/2013 INDEX NO. 158552/2013 NYSCEF DOC.
More informationYOU ARE HEREBY SUMMONED to answer the Complaint in this action and to serve a
FILED: NEW YORK COUNTY CLERK 06/22/2016 03:50 PM INDEX NO. 653311/2016 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 06/22/2016 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK ---------------------------------------------------------------)(
More informationFILED: NEW YORK COUNTY CLERK 01/12/ :05 PM INDEX NO /2016 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 01/12/2016
FILED: NEW YORK COUNTY CLERK 01/12/2016 03:05 PM INDEX NO. 150270/2016 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 01/12/2016 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK --------------------------------------------------------------------X
More informationFILED: NEW YORK COUNTY CLERK 12/28/2011 INDEX NO /2011 NYSCEF DOC. NO. 4 RECEIVED NYSCEF: 12/28/2011
FILED: NEW YORK COUNTY CLERK 12/28/2011 INDEX NO. 652831/2011 NYSCEF DOC. NO. 4 RECEIVED NYSCEF: 12/28/2011 Supreme Court of the State of New York County of New York -------------------------------------------------
More informationFILED: NEW YORK COUNTY CLERK 08/30/ :20 AM INDEX NO /2016 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 08/30/2016
FILED: NEW YORK COUNTY CLERK 08/30/2016 11:20 AM INDEX NO. 654560/2016 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 08/30/2016 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK SUNSHINE DIAMONDS LLC, SHINE
More information$700,000 against defendants Monadnock Construction Inc. (hereinafter "Monadnock"),
FILED: NEW YORK COUNTY CLERK 05/07/2015 12:34 PM INDEX NO. 651547/2015 NYSCEF DOC. NO. 2 RECEIVED NYSCEF: 05/07/2015 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK ---------------------------------------------------------------------------)(
More informationFILED: NEW YORK COUNTY CLERK 11/04/ :40 PM INDEX NO /2016 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 11/04/2016
FILED: NEW YORK COUNTY CLERK 11/04/2016 02:40 PM INDEX NO. 159321/2016 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 11/04/2016 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK ------------------------------------------------------------------------X
More informationFILED: NASSAU COUNTY CLERK 11/09/ :17 PM INDEX NO /2016 NYSCEF DOC. NO. 33 RECEIVED NYSCEF: 11/09/2016
FILED: NASSAU COUNTY CLERK 11/09/2016 03:17 PM INDEX NO. 600893/2016 NYSCEF DOC. NO. 33 RECEIVED NYSCEF: 11/09/2016 1 of 51 2 of 51 3 of 51 4 of 51 5 of 51 6 of 51 7 of 51 8 of 51 9 of 51 FILED: NASSAU
More informationFILED: NEW YORK COUNTY CLERK 01/18/ :40 PM INDEX NO /2014 NYSCEF DOC. NO. 66 RECEIVED NYSCEF: 01/18/2018
FILED : NEW µyork COUNTY CLERK 10/24 /2014 04 : 5 4 INDEX NO. at ~ PM NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 10/24/2014 NEW' SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK ----------------------------------------------------X
More informationFILED: NEW YORK COUNTY CLERK 10/19/ :37 PM INDEX NO /2018 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 10/19/2018
SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK Index No. /2018 -------------------------------------X Filing Date: October, 2018 CLARITY LLC, SUMMONS Plaintry Plaintiff designate New York County
More informationFILED: NEW YORK COUNTY CLERK 01/17/ :08 PM INDEX NO /2017 NYSCEF DOC. NO. 2 RECEIVED NYSCEF: 01/17/2017
FILED: NEW YORK COUNTY CLERK 01/17/2017 05:08 PM INDEX NO. 650263/2017 NYSCEF DOC. NO. 2 RECEIVED NYSCEF: 01/17/2017! SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK ---------------------------------------------------X
More informationFILED: NEW YORK COUNTY CLERK 04/15/ :21 PM INDEX NO /2014 NYSCEF DOC. NO. 23 RECEIVED NYSCEF: 04/15/2016
FILED: NEW YORK COUNTY CLERK 04/15/2016 01:21 PM INDEX NO. 150270/2014 NYSCEF DOC. NO. 23 RECEIVED NYSCEF: 04/15/2016 PXC/1654028 BU-13-06-04-09-001 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW
More informationFILED: NEW YORK COUNTY CLERK 08/17/2011 INDEX NO /2011 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 08/17/2011
FILED: NEW YORK COUNTY CLERK 08/17/2011 INDEX NO. 652300/2011 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 08/17/2011 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK LEVETT ROCKWOOD P.C. and PULLMAN &
More informationFILED: NEW YORK COUNTY CLERK 08/12/ :45 AM INDEX NO /2015 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 08/12/2015
FILED: NEW YORK COUNTY CLERK 08/12/2015 08:45 AM INDEX NO. 158311/2015 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 08/12/2015 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK ------------------------------------------------------------------X
More informationFILED: NEW YORK COUNTY CLERK 08/25/ :18 PM INDEX NO /2016 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 08/25/2016
FILED: NEW YORK COUNTY CLERK 08/25/2016 05:18 PM INDEX NO. 654495/2016 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 08/25/2016 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK DCF CAPITAL, LLC, Index No.:
More informationFILED: NEW YORK COUNTY CLERK 08/17/ :58 AM INDEX NO /2016 NYSCEF DOC. NO. 5 RECEIVED NYSCEF: 08/17/2016 SUPREME COURT OF THE STATE OF NEW
FILED: NEW YORK COUNTY CLERK 08/17/2016 10:58 AM INDEX NO. 654332/2016 NYSCEF DOC. NO. 5 RECEIVED NYSCEF: 08/17/2016 SUPREME COURT OF THE STATE OF NEW COUNTY OF NEW YORK COBY EMPIRE, LLC x - Plaintiff/Petition
More informationFILED: KINGS COUNTY CLERK 06/16/ :02 PM INDEX NO /2017 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 06/16/2017
Supreme Court of the State of New York County of Kings ---------------------------------------------------------------X Zofia Zebzda, Plaintiff, Donna Rhodes, - - against - - Defendants. ---------------------------------------------------------------X
More informationFILED: SUFFOLK COUNTY CLERK 11/30/ :45 PM INDEX NO /2015 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 11/30/2015
FILED: SUFFOLK COUNTY CLERK 11/30/2015 03:45 PM INDEX NO. 612564/2015 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 11/30/2015 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF SUFFOLK U.S. NONWOVENS CORP. -against-
More informationFILED: NEW YORK COUNTY CLERK 02/18/ :03 PM INDEX NO /2015 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 02/18/2015
FILED: NEW YORK COUNTY CLERK 02/18/2015 03:03 PM INDEX NO. 650487/2015 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 02/18/2015 SUPREME COURT OF THE STATE OF NEW YORK Index No.: COUNTY OF NEW YORK -----------------------------------------------------------------------X
More informationFILED: NEW YORK COUNTY CLERK 03/21/ :25 PM INDEX NO /2016 NYSCEF DOC. NO. 13 RECEIVED NYSCEF: 03/21/2017 EXHIBIT E
EXHIBIT E Case 114-cv-08406-VSB Document 40 Filed 03/20/15 Page 1 of 20 UNITED STATES DISTRICT COURT SOUTHERN DISTRICT OF NEW YORK DEMOND MOORE and MICHAEL KIMMELMAN, P.C. v. Plaintiffs, IOD INCORPORATED
More informationFILED: NEW YORK COUNTY CLERK 05/01/ :07 PM INDEX NO /2014 NYSCEF DOC. NO. 3 RECEIVED NYSCEF: 05/01/2015
FILED: NEW YORK COUNTY CLERK 05/01/2015 05:07 PM INDEX NO. 158289/2014 NYSCEF DOC. NO. 3 RECEIVED NYSCEF: 05/01/2015 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK REPWEST INSURANCE COMPANY,
More informationFILED: NEW YORK COUNTY CLERK 02/06/ :34 PM INDEX NO /2017 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 02/06/2017
SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK -----------------------------------------------------------------------X PAUL KRUG, v. Plaintiff, NICHOLAS J. STONE and JONATHAN KRIEGER, Individually,
More informationFILED: NEW YORK COUNTY CLERK 10/18/2012 INDEX NO /2012 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 10/18/2012
FILED: NEW YORK COUNTY CLERK 10/18/2012 INDEX NO. 653645/2012 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 10/18/2012 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK --------------------------------------------------------------
More informationFILED: NEW YORK COUNTY CLERK 02/03/ :53 PM INDEX NO /2015 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 02/03/2015
FILED: NEW YORK COUNTY CLERK 02/03/2015 05:53 PM INDEX NO. 151151/2015 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 02/03/2015 Defendants Addresses: KEITH De SANTO 511 West Bay Street, Suite 350 Tampa, FL 33606
More informationFILED: NIAGARA COUNTY CLERK 05/15/ :01 PM INDEX NO. E156010/2015 NYSCEF DOC. NO. 71 RECEIVED NYSCEF: 05/15/2018 EXHIBIT
EXHIBIT INDEX NO. E156010/2015 FILED: NIAGARA COUNTY CLERK 05/29/2015 09:59 AM NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 05/29/2015 STATE OF NEW YORK SUPREME COURT : COUNTY OF NIAGARA STEPHEN D. VICKI and NICOLE
More informationFILED: NEW YORK COUNTY CLERK 01/23/2012 INDEX NO /2011 NYSCEF DOC. NO. 2 RECEIVED NYSCEF: 01/23/2012. Minelli Cons
FILED: NEW YORK COUNTY CLERK 01/23/2012 INDEX NO. 105989/2011 NYSCEF DOC. NO. 2 RECEIVED NYSCEF: 01/23/2012 \ MIN-WDF-Summons SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK I II MINELLI CONSTRUCTION
More informationFILED: KINGS COUNTY CLERK 06/30/ :11 PM INDEX NO /2015 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 06/30/2015
FILED: KINGS COUNTY CLERK 06/30/2015 02:11 PM INDEX NO. 508062/2015 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 06/30/2015 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF KINGS -------------------------------------------------------------------------X
More informationFILED: NEW YORK COUNTY CLERK 11/07/ :58 PM INDEX NO /2014 NYSCEF DOC. NO. 34 RECEIVED NYSCEF: 11/07/2016
FILED: NEW YORK COUNTY CLERK 11/07/2016 03:58 PM INDEX NO. 161157/2014 NYSCEF DOC. NO. 34 RECEIVED NYSCEF: 11/07/2016 SUPRE~IE COURT OF THE STATE OF NEW YORK COUNTY OF CROWN CONTAINER CO., INC., PlamtifD
More informationFILED: BRONX COUNTY CLERK 07/16/2014 INDEX NO /2013E NYSCEF DOC. NO. 42 RECEIVED NYSCEF: 07/16/2014
FILED: BRONX COUNTY CLERK 07/16/2014 INDEX NO. 23643/2013E NYSCEF DOC. NO. 42 RECEIVED NYSCEF: 07/16/2014 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF BRONX ----------------------------------------------------------------------X
More informationFILED: NEW YORK COUNTY CLERK 11/11/ :48 PM INDEX NO /2015 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 11/11/2015
FILED: NEW YORK COUNTY CLERK 11/11/2015 05:48 PM INDEX NO. 161586/2015 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 11/11/2015 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK TRUSTEES OF THE NEW YORK CITY
More informationFILED: BRONX COUNTY CLERK 01/08/2014 INDEX NO /2012E NYSCEF DOC. NO. 11 RECEIVED NYSCEF: 01/08/2014
FILED: BRONX COUNTY CLERK 01/08/2014 INDEX NO. 21865/2012E NYSCEF DOC. NO. 11 RECEIVED NYSCEF: 01/08/2014 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF BRONX ------------------------------------------------------------------------------X
More informationX Index No. Date Purchased: Plaintiff, Defendants.
FILED: NEW YORK COUNTY CLERK 06/21/2016 01:54 PM INDEX NO. 653281/2016 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 06/21/2016 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK -------------------------------X
More informationFILED: NEW YORK COUNTY CLERK 04/05/ :33 PM INDEX NO /2016 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 04/05/2016
FILED: NEW YORK COUNTY CLERK 04/05/2016 03:33 PM INDEX NO. 651814/2016 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 04/05/2016 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK SAKS & COMPANY LLC, Plaintiff',
More informationFILED: NEW YORK COUNTY CLERK 03/08/ :56 PM INDEX NO /2017 NYSCEF DOC. NO. 50 RECEIVED NYSCEF: 03/08/2018
/FILED: NWR1WORIrO1QQ05WITHICLERE (0f8t/1Nh2WC/ 09 ± 50 ANj INDEX NO. 157407/2017 NYSCEF DocCQtøNT1Y OF NEW YORK RECEIVED NYSCEF: 08/18/2017 MARIA E. DIAZ,. Plaintiff designates New York County as the
More informationFILED: NEW YORK COUNTY CLERK 12/02/ :13 AM INDEX NO /2016 NYSCEF DOC. NO. 14 RECEIVED NYSCEF: 12/02/2016
FILED: NEW YORK COUNTY CLERK 12/02/2016 11:13 AM INDEX NO. 157868/2016 NYSCEF DOC. NO. 14 RECEIVED NYSCEF: 12/02/2016 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK ------------------------------------------------------------------------------x
More informationFILED: NEW YORK COUNTY CLERK 08/21/2013 INDEX NO /2013 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 08/21/2013
FILED: NEW YORK COUNTY CLERK 08/21/2013 INDEX NO. 652945/2013 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 08/21/2013 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK --------------------------------------------------------------------------X
More informationFILED: NEW YORK COUNTY CLERK 12/24/2009 INDEX NO /2009 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 12/24/2009
FILED: NEW YORK COUNTY CLERK 12/24/2009 INDEX NO. 603782/2009 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 12/24/2009 t -1 I *- SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK NEW MILLENNIUM CAPITAL PARTNERS
More informationCase 1:16-cv LTS Document 5 Filed 08/08/16 Page 1 of 9. Plaintiff, Defendants.
Case 1:16-cv-06236-LTS Document 5 Filed 08/08/16 Page 1 of 9 UNITED STATES DISTRICT COURT SOUTHERN DISTRICT OF NEW YORK -------------------------------------------------------------------------x KEVIN
More informationFILED: NEW YORK COUNTY CLERK 10/03/ :58 PM INDEX NO /2016 NYSCEF DOC. NO. 9 RECEIVED NYSCEF: 10/03/2016
FILED: NEW YORK COUNTY CLERK 10/03/2016 05:58 PM INDEX NO. 654871/2016 NYSCEF DOC. NO. 9 RECEIVED NYSCEF: 10/03/2016 Case 1:16-cv-07734 Document 1 Filed 10/03/16 Page 1 of 7 Anne B. Sekel, Esq. FOLEY &
More informationFILED: NEW YORK COUNTY CLERK 12/18/ :16 AM INDEX NO /2014 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 12/18/2014. Plaintiffs, Deadline.
FILED: NEW YORK COUNTY CLERK 12/18/2014 10:16 AM INDEX NO. 162501/2014 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 12/18/2014 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK RICHARD CARDEN, individually
More informationFILED: NEW YORK COUNTY CLERK 08/05/ :48 PM INDEX NO /2013 NYSCEF DOC. NO. 40 RECEIVED NYSCEF: 08/05/2016. Exhibit 1
FILED: NEW YORK COUNTY CLERK 08/05/2016 04:48 PM INDEX NO. 450633/2013 NYSCEF DOC. NO. 40 RECEIVED NYSCEF: 08/05/2016 Exhibit 1 NYSCEF DOC. NO. 1,,, RECEIVED NYSCEF: 02/08/20lc SUPREME COURT OF THE STATE
More informationFILED: RICHMOND COUNTY CLERK 03/17/ :14 AM INDEX NO /2016 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 03/17/2016
FILED: RICHMOND COUNTY CLERK 03/17/2016 04:14 AM INDEX NO. 150318/2016 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 03/17/2016 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF RICHMOND ----------------------------------------------------------------------X
More informationFILED: KINGS COUNTY CLERK 05/25/ /09/ :37 12:27 PM INDEX NO /2016 NYSCEF DOC. NO. 10 RECEIVED NYSCEF: 05/25/2016
FILED: KINGS COUNTY CLERK 05/25/2016 06/09/2017 12:37 12:27 PM INDEX NO. 508697/2016 NYSCEF DOC. NO. 10 RECEIVED NYSCEF: 05/25/2016 06/09/2017 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF KINGS ----------------------------------------------------------------------X
More informationFILED: NEW YORK COUNTY CLERK 12/19/ :21 PM INDEX NO /2016 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 12/19/2016
FILED: NEW YORK COUNTY CLERK 12/19/2016 04:21 PM INDEX NO. 190383/2016 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 12/19/2016 SUPREME COURT OF THE STATE OF NEW YORK AVON PRODUCTS, INC., CLEVELAND NA INVESTOR LLC
More informationFILED: NEW YORK COUNTY CLERK 05/21/ :43 PM INDEX NO /2016
FILED : NEW YORK COUNTY CLERK 10 /13 2017 0 6 : 18 PM) NYSCEF NYSCEF DOC. DOC. 10/13/2017 NO. NO. 18 58 RECEIVED NYSCEF: 05/21/2018 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK TYRONE McGANN
More informationFILED: KINGS COUNTY CLERK 08/02/ :23 AM INDEX NO /2016 NYSCEF DOC. NO. 7 RECEIVED NYSCEF: 08/02/2016
FILED: KINGS COUNTY CLERK 08/02/2016 11:23 AM INDEX NO. 505521/2016 NYSCEF DOC. NO. 7 RECEIVED NYSCEF: 08/02/2016 JFC/dra/168105 TA-2015-06-17-0003-001 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF
More informationFILED: KINGS COUNTY CLERK 09/22/ :49 PM INDEX NO /2016 NYSCEF DOC. NO. 23 RECEIVED NYSCEF: 09/22/2016. Exhibit D {N
FILED: KINGS COUNTY CLERK 09/22/2016 12:49 PM INDEX NO. 504403/2016 NYSCEF DOC. NO. 23 RECEIVED NYSCEF: 09/22/2016 Exhibit D {N0194821.1 } SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF KINGS x THE BOARD
More informationFILED: NEW YORK COUNTY CLERK 06/19/ :05 PM INDEX NO /2015 NYSCEF DOC. NO. 3 RECEIVED NYSCEF: 06/19/2015
FILED: NEW YORK COUNTY CLERK 06/19/2015 12:05 PM INDEX NO. 651388/2015 NYSCEF DOC. NO. 3 RECEIVED NYSCEF: 06/19/2015 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK ----------------------------------------------------------------------X
More informationFILED: NEW YORK COUNTY CLERK 09/08/ :05 PM INDEX NO /2016 NYSCEF DOC. NO. 3 RECEIVED NYSCEF: 09/08/2016
FILED NEW YORK COUNTY CLERK 09/08/2016 1205 PM INDEX NO. 654752/2016 NYSCEF DOC. NO. 3 RECEIVED NYSCEF 09/08/2016 SUPREME COURT OF NEW YORK COUNTY OF NEW YORK - - - - - - - - - - - - - - - - - - - - -
More informationFILED: NEW YORK COUNTY CLERK 11/26/ :25 PM INDEX NO /2016 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 11/26/2016
FILED NEW YORK COUNTY CLERK 11/26/2016 0425 PM INDEX NO. 656160/2016 NYSCEF DOC. NO. 1 RECEIVED NYSCEF 11/26/2016 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK PH-105 Realty Corp, 12 Whitwell
More informationFILED: NEW YORK COUNTY CLERK 06/25/ :22 PM INDEX NO /2014 NYSCEF DOC. NO. 186 RECEIVED NYSCEF: 08/01/2015
FILED: NEW YORK COUNTY CLERK 06/25/2015 05:22 PM INDEX NO. 653038/2014 NYSCEF DOC. NO. 186 RECEIVED NYSCEF: 08/01/2015 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK HAMILTON HEIGHTS CLUSTER
More informationFILED: NEW YORK COUNTY CLERK 09/11/2013 INDEX NO /2013 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 09/11/2013
FILED: NEW YORK COUNTY CLERK 09/11/2013 INDEX NO. 158295/2013 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 09/11/2013 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK -X ANTONIO URQUIZA a/k/a ANTONIO PELAGIO
More informationFILED: NEW YORK COUNTY CLERK 07/06/ :22 PM INDEX NO /2017 NYSCEF DOC. NO. 52 RECEIVED NYSCEF: 07/06/2018
SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK GREEN UNIVERSAL MECHANICAL INCORPORATED Plaintiff, FIRST AMENDED VERIFIED COMPLAINT Index No. 150536/2017 KEL-MAR INTERIORS, INC., AIRREFCO, CORP.,
More informationCourthouse News Service
ELECTRONICALLY FILED 6/15/2009 4:12 PM CV-2009-900370.00 CIRCUIT COURT OF TUSCALOOSA COUNTY, ALABAMA MAGARIA HAMNER BOBO, CLERK IN THE CIRCUIT COURT OF TUSCALOOSA COUNTY, ALABAMA JACK MEADOWS, on behalf
More informationPLAINTIFFS SECOND AMENDED COMPLAINT 2 AND DEMAND FOR JURY TRIAL. Makovsky, and as Agent for Keith Makovsky, Kurt Makovsky, and William Makovsky, as
IN THE CIRCUIT COURT OF THE 15 TH JUDICIAL CIRCUIT, IN AND FOR PALM BEACH COUNTY, FLORIDA KARL MAKOVSKY, as Personal Representative of the Estate of JEAN IRENE MAKOVSKY, and as Agent for KEITH MAKOVSKY,
More informationFILED: NASSAU COUNTY CLERK 06/12/ :54 PM INDEX NO /2015 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 06/12/2015
FILED: NASSAU COUNTY CLERK 06/12/2015 12:54 PM INDEX NO. 603813/2015 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 06/12/2015 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NASSAU ---------------------------------------------------------------)(
More informationFILED: NEW YORK COUNTY CLERK 03/15/ :24 AM INDEX NO /2016 NYSCEF DOC. NO. 12 RECEIVED NYSCEF: 03/15/2016
FILED: NEW YORK COUNTY CLERK 03/15/2016 11:24 AM INDEX NO. 190043/2016 NYSCEF DOC. NO. 12 RECEIVED NYSCEF: 03/15/2016 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK X JOHN D. FIEDERLEIN AND
More informationFILED: WESTCHESTER COUNTY CLERK 05/07/2012 INDEX NO /2012 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 05/07/2012
FILED: WESTCHESTER COUNTY CLERK 05/07/2012 INDEX NO. 57527/2012 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 05/07/2012 SUPREME COURT OF TI-IE STATE OF NEW YORK COUNTY OF WESTCHESTER -------------------------------------------------------------------------)(
More informationFILED: NEW YORK COUNTY CLERK 02/09/ :18 PM INDEX NO /2014 NYSCEF DOC. NO. 25 RECEIVED NYSCEF: 02/09/2015
FILED: NEW YORK COUNTY CLERK 02/09/2015 04:18 PM INDEX NO. 154070/2014 NYSCEF DOC. NO. 25 RECEIVED NYSCEF: 02/09/2015 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK -------------------------------------x
More informationFILED: NEW YORK COUNTY CLERK 10/08/2013 INDEX NO /2012 NYSCEF DOC. NO. 47 RECEIVED NYSCEF: 10/08/2013
FILED: NEW YORK COUNTY CLERK 10/08/2013 INDEX NO. 151360/2012 NYSCEF DOC. NO. 47 RECEIVED NYSCEF: 10/08/2013 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK STEPHEN MOLINARI, Index No.: 151360/12
More informationFILED: NEW YORK COUNTY CLERK 06/22/ :39 PM INDEX NO /2016 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 06/22/2016
FILED: NEW YORK COUNTY CLERK 06/22/2016 01:39 PM INDEX NO. 155249/2016 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 06/22/2016 BAKER, LESHKO, SALINE & DRAPEAU, LLP Attorneys for Plaintiffs One North Lexington Avenue
More informationFILED: KINGS COUNTY CLERK 03/24/ :05 PM INDEX NO /2017 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 03/24/2017. Plaintiff, SUMMONS
SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF KINGS CRYE PRECISION LLC, Index No. _ -against- Plaintiff, SUMMONS ORANGE CdUNTY CHOPPERS EAST COAST WEST COAST LLC and ORANGE COUNTY CHOPPERS, INC. Defendants.
More informationFILED: QUEENS COUNTY CLERK 03/06/ :01 PM INDEX NO /2017 NYSCEF DOC. NO. 12 RECEIVED NYSCEF: 03/06/2018
NYSCEF DOC. NO. 12.. NYSCEF FILED DOC. : QUEENS NO. 12 COUNTY CLERK 03 / 0 1/2 017 12 : 12 PM) SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF QUEENS ------------------------------------------------------------------------X
More informationFILED: NEW YORK COUNTY CLERK 10/28/ :04 PM INDEX NO /2016 NYSCEF DOC. NO. 55 RECEIVED NYSCEF: 10/28/2016
FILED: NEW YORK COUNTY CLERK 10/28/2016 05:04 PM INDEX NO. 190293/2016 NYSCEF DOC. NO. 55 RECEIVED NYSCEF: 10/28/2016 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK X VINCENT ASCIONE, v. ALCOA,
More informationFILED: NEW YORK COUNTY CLERK 03/10/ :54 PM INDEX NO /2016 NYSCEF DOC. NO. 15 RECEIVED NYSCEF: 03/10/2016
FILED: NEW YORK COUNTY CLERK 03/10/2016 02:54 PM INDEX NO. 190047/2016 NYSCEF DOC. NO. 15 RECEIVED NYSCEF: 03/10/2016 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK X NORMAN DOIRON AND ELAINE
More informationSEP 29. S.P.A., SAN PAOLO LEASINT S.P,A. and : theparties INTESA LEASING S.P.A.,
lned ON 912912009 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK 1111 1 1 ------------------------- X : IndexNo.: NORTH AMERICAN AIRLINES, INC., : Date Filed: September 29,2009 Plaintiff, :
More informationFILED: NEW YORK COUNTY CLERK 07/15/ :18 PM INDEX NO /2015 NYSCEF DOC. NO. 50 RECEIVED NYSCEF: 07/15/2016 EXHIBIT C
FILED: NEW YORK COUNTY CLERK 07/15/2016 12:18 PM INDEX NO. 653976/2015 NYSCEF DOC. NO. 50 RECEIVED NYSCEF: 07/15/2016 EXHIBIT C .. [FILED: NEW YORK COUNTY CLERK 05/20/2016 06:46 PMI INDEX NO. 653976/2015
More informationALL STATE INTERIOR DEMOLITION INC. WITH CROSS-CLAIMS
FILED: NEW YORK COUNTY CLERK 11/03/2016 11:45 AM INDEX NO. 157522/2016 NYSCEF DOC. NO. 45 RECEIVED NYSCEF: 11/03/2016 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK Index No.: 157522/2016 ---------------------_._-------------------------------------------)(
More informationCase JMC-7A Doc 2929 Filed 09/13/18 EOD 09/13/18 15:09:05 Pg 1 of 9
Case 16-07207-JMC-7A Doc 2929 Filed 09/13/18 EOD 09/13/18 15:09:05 Pg 1 of 9 UNITED STATES BANKRUPTCY COURT SOUTHERN DISTRICT OF INDIANA INDIANAPOLIS DIVISION IN RE: ITT EDUCATIONAL SERVICES, INC., et
More informationFILED: KINGS COUNTY CLERK 05/06/ :00 PM INDEX NO /2013 NYSCEF DOC. NO. 44 RECEIVED NYSCEF: 05/06/2015
FILED: KINGS COUNTY CLERK 05/06/2015 12:00 PM INDEX NO. 008409/2013 NYSCEF DOC. NO. 44 RECEIVED NYSCEF: 05/06/2015 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF KINGS -------------------------------------------------------------------X
More informationFILED: NEW YORK COUNTY CLERK 11/18/ :03 PM INDEX NO /2016 NYSCEF DOC. NO. 59 RECEIVED NYSCEF: 11/18/2016
FILED: NEW YORK COUNTY CLERK 11/18/2016 02:03 PM INDEX NO. 157522/2016 NYSCEF DOC. NO. 59 RECEIVED NYSCEF: 11/18/2016 SUPREME COURT OF THE STATE NEW YORK COUNTY OF NEW YORK -----------------------------------------------------------------------)(
More informationFILED: BRONX COUNTY CLERK 02/26/ :59 PM INDEX NO /2015E
FILED: BRONX COUNTY CLERK 02/26/2016 02:59 PM INDEX NO. 20208/2015E NYSCEF DOC. NO. 73 RECEIVED IFILED: BRONX COUNTY CLERK 12/23/2015 04:10 pij INDEXNYSCEF: NO. 27059/2015E 02/26/2016 NYSCEF DOC. NO. 1
More information