FILED: NEW YORK COUNTY CLERK 02/18/ :03 PM INDEX NO /2015 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 02/18/2015
|
|
- Dustin Wade
- 5 years ago
- Views:
Transcription
1 FILED: NEW YORK COUNTY CLERK 02/18/ :03 PM INDEX NO /2015 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 02/18/2015 SUPREME COURT OF THE STATE OF NEW YORK Index No.: COUNTY OF NEW YORK X Plaintiff designates New York THOMAS D AGOSTINO, JR. : County as the place of trial. : The basis of the venue is : where both parties reside and Plaintiff, : where the contract was : executed. -against- : : SUMMONS : QUINN-ONELLI INC., D/B/A UNLIMITED DESIGN : : Defendant. : X TO THE ABOVE-NAMED DEFENDANT: YOU ARE HEREBY SUMMONED to appear in the Supreme Court of the City of New York, County of New York, at the office of the Clerk of said Court at 60 Centre Street, in the County of New York, City and State of New York within the time provided by law as noted below and to file your answer to the annexed complaint with the Clerk. In case of your failure to appear or answer, judgment will be taken against you by default for the relief demanded in the Complaint, together with the costs of this action. Dated: February 11, 2014 New York, New York Very truly yours, J. R. Cardenas J. ROBERTO CARDENAS Cardenas Law Office Attorneys for the Plaintiff 119 West 57th Street, Suite 1215 New York, New York (212) TO: Quinn-Onelli Inc. d/b/a Unlimited Designs 132 Waverly Avenue Mamaroneck, New York NOTE: The law provides that: (a) If this summons is served by its delivery to you personally within the City of New York, you must appear and answer within TWENTY days after such service; or (b) if this summons is served by delivery to any person other than you personally, or is served outside the City of New York, or by publication, or by any means other than personal delivery to you within the City of New York, you are allowed THIRTY days after the proof of service thereof is filed with the Clerk of this Court within which to appear and answer.
2 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK X THOMAS D AGOSTINO, JR. -against- Plaintiff, QUINN-ONELLI INC., D/B/A UNLIMITED DESIGN Index No.: VERIFIED COMPLAINT Defendant X Plaintiff, THOMAS D AGOSTINO, JR., by his attorney, J. Roberto Cardenas as and for his complaint against Defendant QUINN-ONELLI, INC. d/b/a UNLIMITED DESIGN hereby alleges as follows: INTRODUCTION 1. This is an action for breach of contract and a declaratory judgment arising out of a contract for renovations and construction work done to Plaintiff s apartment located at 179 East 70 th Street, Penthouse and 21 st Floor, New York, New York By this complaint Plaintiff alleges that Defendant is in breach of contract for failure to tender the Premises in a timely manner as agreed to in the contract and for failure to deliver a workmanlike and professional finished product. 3. Plaintiff further seeks a judgment declaring that no further monies are owed to Defendant under the terms of the contract. PARTIES 4. At all times set forth herein, Plaintiff Thomas D Agostino, Jr. (hereinafter D Agostino or Plaintiff) was and is an individual with a residence of 179 East 70 th Street, Penthouse, New York New York (hereinafter Premises ). 1
3 5. Upon information and belief, at all times set forth herein, Defendant Quinn- Onelli, Inc. d/b/a Unlimited Design (hereinafter Unlimited or Defendant) was, and is, a corporation organized under New York Law, having an office at 132 Waverly Avenue, Mamaroneck, New York. FACTS 6. On or about June 17, 2013, D Agostino entered into a contract with Unlimited for which Unlimited acted as the General Contractor for various renovation and construction work as agreed to and defined in Paragraph 6.3 of the Contract. (Please see a copy of the Contract attached hereto as Exhibit A ). The Premises Were Not Tendered in a Timely Manner 7. The Work began on or about June 17, As per the terms of the Contract, Unlimited agreed to achieve Substantial Completion of the entire Work no later than 5 months from the date of commencement or on or about November 17, (See Paragraph 2.3 of Exhibit A ). 9. As defined in the Contract, Substantial Completion is the stage in the progress of the Work when the Work or designated portion thereof is sufficiently complete in accordance with the Contract Documents so that the Owner can occupy or utilize the Work for its intended use. (See Paragraph of Exhibit A.) 10. Work continued well into 2014 with Defendant sending a completion schedule on or about April 22, 2014, which set forth that in fact the work would be completed on, or about May 2, The Work was substantially completed on or about June 10, As such the Premises were tendered approximately 195 days beyond the 2
4 completion date anticipated in the contract. 13. As per the terms of the Contract; if the General Contractor fails to achieve Substantial Completion of all the Work within the Contract Time, the Owner shall be entitled to retain from any sums due or to become due to the General Contractor or recover from the General Contractor, as liquidated damages and not as a penalty, the following per diem amounts commencing the first day following expiration of the contract time and continuing for each calendar day until actual date of Substantial Completion: $250.00/ calendar day. (See Paragraph 2.4 of Exhibit A ). 14. Thus, as per the Contract, Unlimited owes Plaintiff at least $48, as liquidated damages plus statutory damages from on or about June 10, Further, since Plaintiff was expecting to move in on or about December 1, 2013, he was forced to seek alternate housing while awaiting substantial completion off the apartment. 16. Plaintiff remained in alternate living arrangements until on or about March 2013 when, not withstanding that the apartment was still not substantially complete, he moved in and slept on a mattress on the floor. 17. As such, from on or about December 1, 2013 until on or about March 2014, Plaintiff expended monies in seeking and maintaining alternate living accommodations because the apartment was not substantially complete. Work Completed in an Unworkmanlike Fashion 18. The scope of the renovation and construction work to be completed by Unlimited is set forth in Paragraph of the Contract. 19. However, contrary to the representations made by Unlimited in its contract, Plaintiff found that once the Premises was eventually turned over, it contained numerous 3
5 material defects and was not completed in a manner consistent with the construction documents, the Contract Documents, acceptable industry standards and oral representations made to Plaintiff by Unlimited. 20. Specifically, the defects caused by the Defendant include, but are not limited to: a. improperly installed hardwood floors such that the floor is lifting, damaged and is inconsistently stained; b. unfinished exterior HVAC duct work that is currently secured with duct tape; c. incomplete service entrance; d. failure to construct and/or install a hidden access door for the electrical panel; e. improperly installed, damaged or scratched door hardware; f. incomplete and damaged millwork in various locations including the master closet and entry foyer; g. improperly installed full-length mirrors of which one ultimately fell; h. scratches to the antique mirror bar back; i. permanent and unfixable damage to the new sliding terrace doors caused by the hot metal sparks from machining the metal studs which pock marked the glass doors; j. incorrect installation of marble shower floor with improper drainage; k. failure to provide architect plumber sign-off l. failure to provide architect electrician sign-off and pay the electrician s amount owed; and m. failure to pay the HVAC sub-contractor. 21. On numerous occasions, Plaintiff discussed with Defendant his dissatisfaction with the renovation work, to no avail. 22. On or about June 10, 2014, Plaintiff received a final invoice from Defendant in 4
6 the amount of $43,755.33, ostensibly to cover monies due on the Contract for work that was allegedly completed. 23. On or about August 22, 2014, Plaintiff through the undersigned sent Defendant a letter in an effort to try and resolve this matter amicably and fairly and to mitigate damages. 24. On or about August 27, 2014, Plaintiff was served with a mechanics lien filed by Defendant on the Premises in the amount $43, for monies allegedly owed by Plaintiff. 25. Upon information and belief, the amount necessary to be paid by Plaintiff to repair and correct that for which Unlimited was contracted is in excess of $100, Despite Plaintiff s numerous attempts to try and fix the various deficiencies caused by the unprofessional and unworkmanlike practices carried out by Defendant, Unlimited has made no effort to correct the deficiencies in its work or mitigate damages incurred by the Plaintiff. 27. Plaintiff commenced this action thereafter. AS AND FOR A FIRST CAUSE OF ACTION (Based Upon a Breach of Contract) 28. Plaintiff repeats and realleges each of the foregoing allegations thereby incorporating them into this cause of action by reference. 29. Defendant contracted to deliver to Plaintiff the premises having achieved substantial completion of the scope of work as agreed to in the Contract by on or about November 17, Instead, the Premises were turned over to Plaintiff on or about June 10, 2014, more than 6 months beyond the date agreed to in the Contract at which time the Plaintiff discovered that the work was done in a shoddy and unworkmanlike manner as more fully set forth above. 5
7 31. Therefore, Defendant is in breach of contract and/or warranty to Plaintiff. 32. Wherefore Defendant is liable to Plaintiff for the costs to repair and place the Premises in the condition it should have been in had the contract not been breached which, upon information and belief, will cost in excess of $100, to repair and correct. AS AND FOR A SECOND CAUSE OF ACTION (Based Upon a Breach of Contract, Seeking Consequential and Incidental Damages) 33. Contrary to Defendant s promise to deliver the premises to Plaintiff substantially completed by on or about November 17, 2013, the Premises were turned over to Plaintiff on or about June 10, 2014, more 6 months beyond the date agreed to in the Contract Documents. 34. As such, and per the explicit terms of the Contract, Plaintiff in entitled to $ per day from the agreed upon day of substantial completion to the day the apartment was tendered substantially completed which totals approximately $48, Further Plaintiff expended additional living expenses for three months while waiting for Defendant to substantially complete the premises. 36. Wherefore Defendant is liable to Plaintiff, as consequential and incidental damages, $48, plus statutory interest in per diem charges as well as reimbursement of Plaintiff s reasonable alternate living expenses for Defendant s breach of contract and its failure to substantially complete the agreed upon scope of work by the date as set forth in the Contract. AS AND FOR A THIRD CAUSE OF ACTION (For a Declaratory Judgment as Against Defendants) 37. Plaintiff repeats and realleges each of the foregoing allegations thereby incorporating them into this cause of action by reference. 38. Plaintiff was prompt in making any and all progress payments owed to Defendant as per Paragraph 4.1 of the Contract. 6
8 39. The final payment of $43, was for the delivery of a substantially complete renovation to the Premises, which the Plaintiff has not received. 40. Instead, Plaintiff is now burdened with the costs associated with the extensive repair work required to fix that for which the Defendant was contracted but failed to complete. 41. Plaintiff is therefore entitled to a Declaratory Judgment declaring that nothing is further owed to Defendant. 42. Wherefore Plaintiff seeks a Declaratory Judgment that it owes nothing further to the defendant. WHEREFORE, Plaintiff Thomas D Agostino, Jr. demands judgment against the above-named Defendant Quinn-Onelli, Inc. d/b/a Unlimited Designs as follows: (a) On the First Cause of Action for breach of contract, a judgment against Defendant in an amount in excess of $100,000.00, the exact amount to be determined at trial; (b) On the Second Cause of Action for breach of Contract seeking consequential and incidental damages, a Judgment against Defendant in an amount to include $48, in liquidated damages plus statutory interest as well as reasonable living expense the exact amount to be determined at trial; (c) On the Third Cause of Action against Defendant a Judgment declaring that no further monies are owed to Defendant under the terms of the Contract; and 7
9 (d) For the costs and disbursements of this action, together with such other and Dated: New York, New York February 11, 2015 further relief as this Court may deem just and proper. CARDENAS LAW OFFICE Attorney for the Plaintiff By: J. R. Cardenas J. ROBERTO CARDENAS 119 W. 57 th Street, Suite 1217 New York, New York T: (212) F: (212)
10 ATTORNEY'S VERIFICATION STATE OF NEW YORK ) ) SS.: COUNTY OF NEW YORK ) J. Roberto Cardenas under penalties of perjury, affirms that he is the attorney for Plaintiff in this action and that the foregoing complaint is true to his own knowledge, except as to matters therein stated to be alleged on information and belief and as to those matters he believes them to be true. The grounds of such belief as to all matters not stated upon his knowledge are correspondence and other writings furnished to him by the Plaintiff. This verification is made by Plaintiff s counsel and not Plaintiff because the Plaintiff is not within the county where deponent maintains his office. Dated: February 11, 2015 New York, New York J. R. Cardenas J. ROBERTO CARDENAS 9
FILED: NEW YORK COUNTY CLERK 06/14/ :52 AM INDEX NO /2016 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 06/14/2016
FILED: NEW YORK COUNTY CLERK 06/14/2016 10:52 AM INDEX NO. 154973/2016 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 06/14/2016 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK - - - - - - - - - - - - -
More informationFILED: ERIE COUNTY CLERK 09/19/ :42 PM INDEX NO /2014 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 09/19/2014
FILED: ERIE COUNTY CLERK 09/19/2014 03:42 PM INDEX NO. 810780/2014 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 09/19/2014 STATE OF NEW YORK SUPREME COURT: COUNTY OF ERIE WILL FOODS, LLC 1 07 5 William Street Buffalo,
More informationFILED: NEW YORK COUNTY CLERK 04/15/ :21 PM INDEX NO /2014 NYSCEF DOC. NO. 23 RECEIVED NYSCEF: 04/15/2016
FILED: NEW YORK COUNTY CLERK 04/15/2016 01:21 PM INDEX NO. 150270/2014 NYSCEF DOC. NO. 23 RECEIVED NYSCEF: 04/15/2016 PXC/1654028 BU-13-06-04-09-001 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW
More informationFILED: NEW YORK COUNTY CLERK 07/26/2013 INDEX NO /2013 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 07/26/2013
FILED: NEW YORK COUNTY CLERK 07/26/2013 INDEX NO. 156836/2013 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 07/26/2013 CONSUMER CREDIT TRANSACTION ------------------------------------------------------------x Index
More informationFILED: NEW YORK COUNTY CLERK 07/20/ :42 AM INDEX NO /2013 NYSCEF DOC. NO. 67 RECEIVED NYSCEF: 07/20/2015. Exhibit A
FILED: NEW YORK COUNTY CLERK 07/20/2015 11:42 AM INDEX NO. 158552/2013 NYSCEF DOC. NO. 67 RECEIVED NYSCEF: 07/20/2015 Exhibit A FILED: NEW YORK COUNTY CLERK 09/18/2013 INDEX NO. 158552/2013 NYSCEF DOC.
More informationFILED: NEW YORK COUNTY CLERK 01/23/2012 INDEX NO /2011 NYSCEF DOC. NO. 3 RECEIVED NYSCEF: 01/23/2012. Plaintiff, Defendants.
FILED: NEW YORK COUNTY CLERK 01/23/2012 INDEX NO. 105989/2011 NYSCEF DOC. NO. 3 RECEIVED NYSCEF: 01/23/2012 MIN-WDF-Supelemental Summons 2. SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK...
More informationFILED: NEW YORK COUNTY CLERK 07/26/ :03 PM INDEX NO /2016 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 07/26/2016
FILED: NEW YORK COUNTY CLERK 07/26/2016 03:03 PM INDEX NO. 653911/2016 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 07/26/2016 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK LINEN DEPOT DIRECT, INC.,
More informationThird-Party Plaintiff, Third-Party Defendant x YOU ARE HEREBY SUMMONED, to answer the Complaint of the
FILED: NEW YORK COUNTY CLERK 02/17/2016 04:37 PM INDEX NO. 156590/2013 NYSCEF DOC. NO. 30 RECEIVED NYSCEF: 02/17/2016 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK MICHAEL ROSSANI, Index No.:
More informationFILED: NEW YORK COUNTY CLERK 09/28/ :27 PM INDEX NO /2016 NYSCEF DOC. NO. 7 RECEIVED NYSCEF: 09/28/2016
FILED NEW YORK COUNTY CLERK 09/28/2016 0627 PM INDEX NO. 653609/2016 NYSCEF DOC. NO. 7 RECEIVED NYSCEF 09/28/2016 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK --------------------------------------------------------------------
More informationALL STATE INTERIOR DEMOLITION INC. WITH CROSS-CLAIMS
FILED: NEW YORK COUNTY CLERK 11/03/2016 11:45 AM INDEX NO. 157522/2016 NYSCEF DOC. NO. 45 RECEIVED NYSCEF: 11/03/2016 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK Index No.: 157522/2016 ---------------------_._-------------------------------------------)(
More informationFILED: BRONX COUNTY CLERK 02/06/2013 INDEX NO /2013E NYSCEF DOC. NO. 3 RECEIVED NYSCEF: 02/06/2013
FILED: BRONX COUNTY CLERK 02/06/2013 INDEX NO. 20392/2013E NYSCEF DOC. NO. 3 RECEIVED NYSCEF: 02/06/2013 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF BRONX ---------------------------------------------------------------)(
More informationFILED: NASSAU COUNTY CLERK 11/09/ :17 PM INDEX NO /2016 NYSCEF DOC. NO. 33 RECEIVED NYSCEF: 11/09/2016
FILED: NASSAU COUNTY CLERK 11/09/2016 03:17 PM INDEX NO. 600893/2016 NYSCEF DOC. NO. 33 RECEIVED NYSCEF: 11/09/2016 1 of 51 2 of 51 3 of 51 4 of 51 5 of 51 6 of 51 7 of 51 8 of 51 9 of 51 FILED: NASSAU
More informationFILED: KINGS COUNTY CLERK 10/26/ :38 PM INDEX NO /2015 NYSCEF DOC. NO. 22 RECEIVED NYSCEF: 10/26/2016 EXHIBIT A
FILED: KINGS COUNTY CLERK 10/26/2016 03:38 PM INDEX NO. 512876/2015 NYSCEF DOC. NO. 22 RECEIVED NYSCEF: 10/26/2016 EXHIBIT A FILED: KINGS COUNTY CLERK 10/21/2015 02:58 PM INDEX NO. 512876/2015 NYSCEF DOC.
More informationFILED: NEW YORK COUNTY CLERK 02/11/ :59 AM INDEX NO /2016 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 02/11/2016
FILED: NEW YORK COUNTY CLERK 02/11/2016 11:59 AM INDEX NO. 650705/2016 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 02/11/2016 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK ----------------------------------------------------------------------X
More informationFILED: NEW YORK COUNTY CLERK 11/09/ :16 PM INDEX NO /2016 NYSCEF DOC. NO. 6 RECEIVED NYSCEF: 11/09/2016
FILED: NEW YORK COUNTY CLERK 11/09/2016 12:16 PM INDEX NO. 655053/2016 NYSCEF DOC. NO. 6 RECEIVED NYSCEF: 11/09/2016 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK x BELLE LIGHTING LLC, Index
More informationFILED: NEW YORK COUNTY CLERK 04/09/2013 INDEX NO /2013 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 04/09/2013
FILED: NEW YORK COUNTY CLERK 04/09/2013 INDEX NO. 153197/2013 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 04/09/2013 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK ---------------------------------------------------------------------
More informationPlaintiff, Yonkers Contracting Company, Inc. ("Yonkers"), and Zurich American Insurance Company
FILED: WESTCHESTER COUNTY CLERK 05/20/2013 INDEX NO. 54272/2013 NYSCEF DOC. NO. 4 RECEIVED NYSCEF: 05/20/2013 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF WESTCHESTER ---------------------------------------------------------------------)(
More informationFILED: KINGS COUNTY CLERK 03/28/ :51 PM INDEX NO /2016 NYSCEF DOC. NO. 25 RECEIVED NYSCEF: 03/28/2017
, EXHIBITE [FILED: KINGS COUNTY CLERK 02/21/2017 04:12 PM] SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF KINGS SELVIN ESPINAL RODRJGUEZ, -against- Plaintiff, 91 & 95 28TH STREET, JACKSON HEIGHTS, IN
More informationFILED: NEW YORK COUNTY CLERK 12/31/ :45 PM INDEX NO /2014 NYSCEF DOC. NO. 2 RECEIVED NYSCEF: 12/31/2014
FILED: NEW YORK COUNTY CLERK 12/31/2014 02:45 PM INDEX NO. 162875/2014 NYSCEF DOC. NO. 2 RECEIVED NYSCEF: 12/31/2014 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK DEBORAH J. DRUCKER, Index
More informationFILED: NEW YORK COUNTY CLERK 01/23/2012 INDEX NO /2011 NYSCEF DOC. NO. 2 RECEIVED NYSCEF: 01/23/2012. Minelli Cons
FILED: NEW YORK COUNTY CLERK 01/23/2012 INDEX NO. 105989/2011 NYSCEF DOC. NO. 2 RECEIVED NYSCEF: 01/23/2012 \ MIN-WDF-Summons SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK I II MINELLI CONSTRUCTION
More informationFILED: NEW YORK COUNTY CLERK 02/06/2014 INDEX NO /2014 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 02/06/2014
FILED: NEW YORK COUNTY CLERK 02/06/2014 INDEX NO. 650412/2014 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 02/06/2014 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK --------------------------------------------------------------------)(
More informationFILED: NEW YORK COUNTY CLERK 08/04/ :53 PM INDEX NO /2016 NYSCEF DOC. NO. 17 RECEIVED NYSCEF: 08/04/2016
FILED: NEW YORK COUNTY CLERK 08/04/2016 12:53 PM INDEX NO. 190187/2016 NYSCEF DOC. NO. 17 RECEIVED NYSCEF: 08/04/2016 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK ANGELO C. ABRUZZINO and BARBARA
More informationFILED: NEW YORK COUNTY CLERK 09/30/ :55 PM INDEX NO /2016 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 09/30/2016
FILED: NEW YORK COUNTY CLERK 09/30/2016 01:55 PM INDEX NO. 158275/2016 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 09/30/2016 SUPREME DAVID COURT B. ROSENBAUM, OF THE STATE an OF attorney NEW YORK duly admitted
More informationFILED: NEW YORK COUNTY CLERK 07/11/ :31 PM INDEX NO /2017 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 07/11/2017
SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK PB 151 GRAND LLC, Index No.: Petitioner, VERIFIED PETITION -against- 9 CROSBY, LLC, Respondent. Petitioner PB 151 Grand, LLC, by its attorneys,
More informationFILED: SUFFOLK COUNTY CLERK 11/30/ :45 PM INDEX NO /2015 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 11/30/2015
FILED: SUFFOLK COUNTY CLERK 11/30/2015 03:45 PM INDEX NO. 612564/2015 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 11/30/2015 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF SUFFOLK U.S. NONWOVENS CORP. -against-
More informationFILED: NEW YORK COUNTY CLERK 07/18/ :49 PM INDEX NO /2016 NYSCEF DOC. NO. 42 RECEIVED NYSCEF: 07/18/2018
SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK --------------------------------------------------------------------X CATHERINE SANTIAGO, Plaintiff, - against - THIRD-PARTY SUMMONS Index No.:
More informationFILED: NEW YORK COUNTY CLERK 11/06/ :59 PM INDEX NO /2016 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 11/06/2016
FILED: NEW YORK COUNTY CLERK 11/06/2016 04:59 PM INDEX NO. 655826/2016 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 11/06/2016 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK --------------------------------------------------------------------X
More informationFILED: NEW YORK COUNTY CLERK 07/06/ :22 PM INDEX NO /2017 NYSCEF DOC. NO. 52 RECEIVED NYSCEF: 07/06/2018
SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK GREEN UNIVERSAL MECHANICAL INCORPORATED Plaintiff, FIRST AMENDED VERIFIED COMPLAINT Index No. 150536/2017 KEL-MAR INTERIORS, INC., AIRREFCO, CORP.,
More informationFILED: NEW YORK COUNTY CLERK 12/06/2010 INDEX NO /2010
FILED: NEW YORK COUNTY CLERK 12/06/2010 INDEX NO. 107442/2010... NYSCEF DON 61712010 DOC. NO. 1 RECEIVED NYSCEF: 12/06/2010 -against- Plaintiff@), LIFE FTTNESS, A DIVISION OF BRUNSWICK CORPORATION and
More informationFILED: NEW YORK COUNTY CLERK 02/01/ :52 PM INDEX NO /2016 NYSCEF DOC. NO. 50 RECEIVED NYSCEF: 02/01/2017
FILED NEW YORK COUNTY CLERK 02/01/2017 0452 PM INDEX NO. 190138/2016 NYSCEF DOC. NO. 50 RECEIVED NYSCEF 02/01/2017 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK In Re NEW YORK CITY ASBESTOS
More informationFILED: KINGS COUNTY CLERK 05/03/ :03 PM INDEX NO /2016 NYSCEF DOC. NO. 39 RECEIVED NYSCEF: 05/03/2018
NYSCEF DOC. NO. 39 RECEIVED NYSCEF: 05/03/2018 IN DEX NO. 5014 4 FILED: KINGS COUNTY CLERK 08/23/2017 01:39 5/2016 PH NYSCEF DOC. NO. 39 RECEIVED NYSCEF: 05/03/2018 No.' SUPREME COURT OF THE STATE OF NEW
More informationFILED: NEW YORK COUNTY CLERK 01/12/ :05 PM INDEX NO /2016 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 01/12/2016
FILED: NEW YORK COUNTY CLERK 01/12/2016 03:05 PM INDEX NO. 150270/2016 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 01/12/2016 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK --------------------------------------------------------------------X
More informationFILED: NEW YORK COUNTY CLERK 07/09/ :06 PM
EDON71812011 FILED: NEW YORK COUNTY CLERK 07/09/2015 11:06 PM INDEX NO. 850229/2014 NYSCEF DOC. NO. 51 RECEIVED NYSCEF: 07/09/2015 a Supreme Court of the State of New York County of New York WINSTON CAPITAL,
More informationFILED: NEW YORK COUNTY CLERK 05/21/2014 INDEX NO /2014 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 05/21/2014
FILED: NEW YORK COUNTY CLERK 05/21/2014 INDEX NO. 154975/2014 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 05/21/2014 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK -------------------x GABRIELLE DONAGHY,
More informationFILED: NEW YORK COUNTY CLERK 10/08/2013 INDEX NO /2012 NYSCEF DOC. NO. 47 RECEIVED NYSCEF: 10/08/2013
FILED: NEW YORK COUNTY CLERK 10/08/2013 INDEX NO. 151360/2012 NYSCEF DOC. NO. 47 RECEIVED NYSCEF: 10/08/2013 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK STEPHEN MOLINARI, Index No.: 151360/12
More informationFILED: KINGS COUNTY CLERK 01/29/ :48 PM INDEX NO /2016 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 01/29/2016
FILED: KINGS COUNTY CLERK 01/29/2016 02:48 PM INDEX NO. 501194/2016 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 01/29/2016 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF KINGS --------------------------------------------------------------------)(
More informationTERMS AND CONDITIONS OF TRADE
BONEDA PTY LTD TRADING AS GROOVE TILES & STONE A.B.N 252 484 506 27 TERMS AND CONDITIONS OF TRADE 1. INTERPRETATION 1.1 Unless otherwise inconsistent with the context the word person shall include a corporation;
More informationFILED: NEW YORK COUNTY CLERK 10/03/ :34 AM INDEX NO /2014 NYSCEF DOC. NO. 34 RECEIVED NYSCEF: 10/03/2014
FILED: NEW YORK COUNTY CLERK 10/03/2014 09:34 AM INDEX NO. 151547/2014 NYSCEF DOC. NO. 34 RECEIVED NYSCEF: 10/03/2014 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK MILERVA SANTOS, Index No.:
More informationFILED: NEW YORK COUNTY CLERK 12/27/ :44 PM INDEX NO /2016 NYSCEF DOC. NO. 2 RECEIVED NYSCEF: 12/27/2016
FILED: NEW YORK COUNTY CLERK 12/27/2016 03:44 PM INDEX NO. 656740/2016 NYSCEF DOC. NO. 2 RECEIVED NYSCEF: 12/27/2016 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK Index No.: Date Purchased:
More informationFILED: NEW YORK COUNTY CLERK 08/30/ :20 AM INDEX NO /2016 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 08/30/2016
FILED: NEW YORK COUNTY CLERK 08/30/2016 11:20 AM INDEX NO. 654560/2016 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 08/30/2016 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK SUNSHINE DIAMONDS LLC, SHINE
More informationFILED: NEW YORK COUNTY CLERK 10/28/ :04 PM INDEX NO /2016 NYSCEF DOC. NO. 55 RECEIVED NYSCEF: 10/28/2016
FILED: NEW YORK COUNTY CLERK 10/28/2016 05:04 PM INDEX NO. 190293/2016 NYSCEF DOC. NO. 55 RECEIVED NYSCEF: 10/28/2016 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK X VINCENT ASCIONE, v. ALCOA,
More informationFILED: NEW YORK COUNTY CLERK 10/09/ :53 PM
FILED: NEW YORK COUNTY CLERK 10/09/2015 03:53 PM INDEX NO. 158764/2015 NYSCEF DOC. NO. 13 RECEIVED NYSCEF: 10/09/2015 Exhibit B to the Affirmation of Howard I. Elman, Esq. in Support of Defendants Motion
More informationFILED: NEW YORK COUNTY CLERK 08/21/2013 INDEX NO /2013 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 08/21/2013
FILED: NEW YORK COUNTY CLERK 08/21/2013 INDEX NO. 652945/2013 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 08/21/2013 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK --------------------------------------------------------------------------X
More informationFILED: NEW YORK COUNTY CLERK 10/16/ :13 PM INDEX NO /2018 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 10/16/2018
SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK RESIDENTIAL BOARD OF TRUMP TOWER Index No. CONDOMINIUM, /18 Plaintiff, SUMMONS -against- Plaintiff designates AARON BRASSNER, AS EXECUTOR OF THE
More informationFILED: NEW YORK COUNTY CLERK 04/27/ :04 PM INDEX NO /2016 NYSCEF. DOC. NO. 13 RECEIVED NYSCEF: 04/27/2018
NYSCEF. DOC. NO. 13 RECEIVED NYSCEF: 04/27/2018 SUPREME COURT STATE OF NEW YORK COUNTY OF NEW YORK -------------------------------------------------------------X FRANCISCA PAGUADA RODRIGUEZ, Index No.:
More informationFILED: BRONX COUNTY CLERK 11/03/ :59 PM INDEX NO /2016E NYSCEF DOC. NO. 18 RECEIVED NYSCEF: 11/03/2016
FILED: BRONX COUNTY CLERK 11/03/2016 03:59 PM INDEX NO. 25545/2016E NYSCEF DOC. NO. 18 RECEIVED NYSCEF: 11/03/2016 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF BRONX ------------------------------------------------------x
More informationFILED: NEW YORK COUNTY CLERK 09/11/2013 INDEX NO /2013 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 09/11/2013
FILED: NEW YORK COUNTY CLERK 09/11/2013 INDEX NO. 158295/2013 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 09/11/2013 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK -X ANTONIO URQUIZA a/k/a ANTONIO PELAGIO
More informationFILED: SUFFOLK COUNTY CLERK 12/16/ :24 PM INDEX NO /2016 NYSCEF DOC. NO. 17 RECEIVED NYSCEF: 12/16/2016
FILED: SUFFOLK COUNTY CLERK 12/16/2016 04:24 PM INDEX NO. 610229/2016 NYSCEF DOC. NO. 17 RECEIVED NYSCEF: 12/16/2016 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF SUFFOLK DAWN KENNEY-NEWKIRK, EOF FILE
More informationX Index No. Date Purchased: Plaintiff, Defendants.
FILED: NEW YORK COUNTY CLERK 06/21/2016 01:54 PM INDEX NO. 653281/2016 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 06/21/2016 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK -------------------------------X
More informationFILED: NEW YORK COUNTY CLERK 12/19/ :21 PM INDEX NO /2016 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 12/19/2016
FILED: NEW YORK COUNTY CLERK 12/19/2016 04:21 PM INDEX NO. 190383/2016 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 12/19/2016 SUPREME COURT OF THE STATE OF NEW YORK AVON PRODUCTS, INC., CLEVELAND NA INVESTOR LLC
More informationFILED: NEW YORK COUNTY CLERK 03/15/ :24 AM INDEX NO /2016 NYSCEF DOC. NO. 12 RECEIVED NYSCEF: 03/15/2016
FILED: NEW YORK COUNTY CLERK 03/15/2016 11:24 AM INDEX NO. 190043/2016 NYSCEF DOC. NO. 12 RECEIVED NYSCEF: 03/15/2016 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK X JOHN D. FIEDERLEIN AND
More informationFILED: KINGS COUNTY CLERK 05/25/ /09/ :37 12:27 PM INDEX NO /2016 NYSCEF DOC. NO. 10 RECEIVED NYSCEF: 05/25/2016
FILED: KINGS COUNTY CLERK 05/25/2016 06/09/2017 12:37 12:27 PM INDEX NO. 508697/2016 NYSCEF DOC. NO. 10 RECEIVED NYSCEF: 05/25/2016 06/09/2017 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF KINGS ----------------------------------------------------------------------X
More informationFILED: NEW YORK COUNTY CLERK 02/09/ :18 PM INDEX NO /2014 NYSCEF DOC. NO. 25 RECEIVED NYSCEF: 02/09/2015
FILED: NEW YORK COUNTY CLERK 02/09/2015 04:18 PM INDEX NO. 154070/2014 NYSCEF DOC. NO. 25 RECEIVED NYSCEF: 02/09/2015 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK -------------------------------------x
More informationROGERS CORPORATION - TERMS AND CONDITIONS OF PURCHASE
ROGERS CORPORATION - TERMS AND CONDITIONS OF PURCHASE THE FOLLOWING TERMS AND CONDITIONS, AND THOSE SPECIFIED ON THE FACE OF THIS PURCHASE ORDER, SHALL EXCLUSIVELY GOVERN THE PURCHASE OF ALL MATERIALS
More informationFILED: QUEENS COUNTY CLERK 08/14/ :01 PM INDEX NO /2017 NYSCEF DOC. NO. 125 RECEIVED NYSCEF: 08/14/2018
SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF QUEENS â â ----------- â - â ------ â - â â â -- â, Index No. 710002/2017 Plaintiff, CARLOS RODRIGUEZ and ARTURO PAREDES, 3402(b) NOTICE PURSUANT TO CPLR
More informationFILED: NEW YORK COUNTY CLERK 10/19/ :37 PM INDEX NO /2018 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 10/19/2018
SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK Index No. /2018 -------------------------------------X Filing Date: October, 2018 CLARITY LLC, SUMMONS Plaintry Plaintiff designate New York County
More informationFILED: NEW YORK COUNTY CLERK 11/04/ :33 PM INDEX NO /2016 NYSCEF DOC. NO. 10 RECEIVED NYSCEF: 11/04/2016
FILED: NEW YORK COUNTY CLERK 11/04/2016 02:33 PM INDEX NO. 654790/2016 NYSCEF DOC. NO. 10 RECEIVED NYSCEF: 11/04/2016 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK ---------------------------------------------------------X
More informationFILED: NEW YORK COUNTY CLERK 03/10/ :54 PM INDEX NO /2016 NYSCEF DOC. NO. 15 RECEIVED NYSCEF: 03/10/2016
FILED: NEW YORK COUNTY CLERK 03/10/2016 02:54 PM INDEX NO. 190047/2016 NYSCEF DOC. NO. 15 RECEIVED NYSCEF: 03/10/2016 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK X NORMAN DOIRON AND ELAINE
More informationFILED: NEW YORK COUNTY CLERK 08/05/ :48 PM INDEX NO /2013 NYSCEF DOC. NO. 40 RECEIVED NYSCEF: 08/05/2016. Exhibit 1
FILED: NEW YORK COUNTY CLERK 08/05/2016 04:48 PM INDEX NO. 450633/2013 NYSCEF DOC. NO. 40 RECEIVED NYSCEF: 08/05/2016 Exhibit 1 NYSCEF DOC. NO. 1,,, RECEIVED NYSCEF: 02/08/20lc SUPREME COURT OF THE STATE
More informationFILED: NEW YORK COUNTY CLERK 03/08/ :32 PM INDEX NO /2016 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 03/08/2016
FILED: NEW YORK COUNTY CLERK 03/08/2016 02:32 PM INDEX NO. 151976/2016 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 03/08/2016 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK -------------------------------------x
More informationFILED: SUFFOLK COUNTY CLERK 09/15/ :46 PM INDEX NO /2015 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 09/15/2015. Plaintiffs,
FILED: SUFFOLK COUNTY CLERK 09/15/2015 05:46 PM INDEX NO. 609895/2015 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 09/15/2015. SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF SUFFOLK ----------------------------------------------------------------------------------)(
More informationFILED: NEW YORK COUNTY CLERK 08/17/2011 INDEX NO /2011 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 08/17/2011
FILED: NEW YORK COUNTY CLERK 08/17/2011 INDEX NO. 652300/2011 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 08/17/2011 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK LEVETT ROCKWOOD P.C. and PULLMAN &
More informationYOU ARE HEREBY SUMMONED to answer the Complaint in this action and to serve a
FILED: NEW YORK COUNTY CLERK 06/22/2016 03:50 PM INDEX NO. 653311/2016 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 06/22/2016 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK ---------------------------------------------------------------)(
More informationFILED: NEW YORK COUNTY CLERK 05/21/ :43 PM INDEX NO /2016
FILED : NEW YORK COUNTY CLERK 10 /13 2017 0 6 : 18 PM) NYSCEF NYSCEF DOC. DOC. 10/13/2017 NO. NO. 18 58 RECEIVED NYSCEF: 05/21/2018 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK TYRONE McGANN
More informationFILED: BRONX COUNTY CLERK 02/26/ :59 PM INDEX NO /2015E
FILED: BRONX COUNTY CLERK 02/26/2016 02:59 PM INDEX NO. 20208/2015E NYSCEF DOC. NO. 73 RECEIVED IFILED: BRONX COUNTY CLERK 12/23/2015 04:10 pij INDEXNYSCEF: NO. 27059/2015E 02/26/2016 NYSCEF DOC. NO. 1
More informationFILED: NEW YORK COUNTY CLERK 10/08/ :47 PM INDEX NO /2015 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 10/08/2015
FILED NEW YORK COUNTY CLERK 10/08/2015 1247 PM INDEX NO. 653360/2015 NYSCEF DOC. NO. 1 RECEIVED NYSCEF 10/08/2015 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK x GFI INSURANCE BROKERAGE, INC.,
More informationFILED: NEW YORK COUNTY CLERK 02/07/ :51 PM
Exhibit G FILED: NEW YORK COUNTY CLERK 10/25/2016 02/07/2017 04:42 02:51 PM INDEX NO. 156798/2015 NYSCEF DOC. NO. 22 38 RECEIVED NYSCEF: 10/25/2016 02/07/2017 SUPREME COURT OF THE STATE OF NEW YORK COUNTY
More informationFILED: NEW YORK COUNTY CLERK 10/20/ :37 PM INDEX NO /2014 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 10/20/2014
FILED: NEW YORK COUNTY CLERK 10/20/2014 02:37 PM INDEX NO. 160251/2014 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 10/20/2014 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK ------------------------------------------------------------------------)(
More informationEXHIBIT F-1 (I) FORM OF DESIGN-BUILD LETTER OF CREDIT VIRGINIA DEPARTMENT OF TRANSPORTATION 1401 EAST BROAD STREET RICHMOND, VA ATTN: [ ]
EXHIBIT F-1 (I) FORM OF DESIGN-BUILD LETTER OF CREDIT IRREVOCABLE STANDBY DESIGN-BUILD LETTER OF CREDIT ISSUER PLACE FOR PRESENTATION OF DRAFT APPLICANT BENEFICIARY [ ] [Name and address of banking institution
More informationFILED: NEW YORK COUNTY CLERK 03/30/ :06 PM INDEX NO /2017 NYSCEF DOC. NO. 60 RECEIVED NYSCEF: 03/30/2017
SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK -------------------------------------------------------------------x LEROY BAKER, Index No.: 190058/2017 Plaintiff, -against- AF SUPPLY USA INC.,
More informationFILED: NEW YORK COUNTY CLERK 01/23/ /09/ :34 PM INDEX NO /2013 NYSCEF DOC. NO RECEIVED NYSCEF: 01/23/2014
FILED: NEW YORK COUNTY CLERK 01/23/2014 06/09/2016 02:34 PM INDEX NO. 160662/2013 NYSCEF DOC. NO. 26 62 RECEIVED NYSCEF: 01/23/2014 06/09/2016 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK
More informationCONSTRUCTION GUARANTEE AGREEMENT
CONSTRUCTION GUARANTEE AGREEMENT THIS AGREEMENT is made and entered into as of this day of, 20, by and between, whose address is, hereinafter referred to as Developer, and the Town of Fraser, a municipal
More informationFILED: KINGS COUNTY CLERK 06/16/ :02 PM INDEX NO /2017 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 06/16/2017
Supreme Court of the State of New York County of Kings ---------------------------------------------------------------X Zofia Zebzda, Plaintiff, Donna Rhodes, - - against - - Defendants. ---------------------------------------------------------------X
More informationFILED: NEW YORK COUNTY CLERK 11/01/ :57 PM INDEX NO /2016 NYSCEF DOC. NO. 5 RECEIVED NYSCEF: 11/01/2016
FILED: NEW YORK COUNTY CLERK 11/01/2016 06:57 PM INDEX NO. 654956/2016 NYSCEF DOC. NO. 5 RECEIVED NYSCEF: 11/01/2016 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK JEREMY WIESEN, Index No: 654956/2016
More informationFILED: NEW YORK COUNTY CLERK 06/02/ /15/ :56 02:55 AM PM INDEX NO /2015 NYSCEF DOC. NO. 149 RECEIVED NYSCEF: 06/02/2015
FILED: NEW YORK COUNTY CLERK 06/02/2015 09/15/2016 10:56 02:55 AM PM INDEX NO. 651899/2015 NYSCEF DOC. NO. 149 RECEIVED NYSCEF: 06/02/2015 09/15/2016 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW
More informationFILED: NEW YORK COUNTY CLERK 12/02/ :13 AM INDEX NO /2016 NYSCEF DOC. NO. 14 RECEIVED NYSCEF: 12/02/2016
FILED: NEW YORK COUNTY CLERK 12/02/2016 11:13 AM INDEX NO. 157868/2016 NYSCEF DOC. NO. 14 RECEIVED NYSCEF: 12/02/2016 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK ------------------------------------------------------------------------------x
More informationATTACHMENT B: SAMPLE CONTRACT (AGREEMENT)
ATTACHMENT B: SAMPLE CONTRACT (AGREEMENT) CITY OF PLACERVILLE PAVEMENT REHABILITATION PROJECT PROJECT NO. xxxx THIS AGREEMENT ( Agreement ) approved by the City Council this 26th day of June, in the year
More informationFILED: NEW YORK COUNTY CLERK 02/17/ :37 PM INDEX NO /2016 NYSCEF DOC. NO. 23 RECEIVED NYSCEF: 02/17/2017
FILED NEW YORK COUNTY CLERK 02/17/2017 0337 PM INDEX NO. 159897/2016 NYSCEF DOC. NO. 23 RECEIVED NYSCEF 02/17/2017 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK X M & E CHRISTOPHER LLC, Plaintiff,
More informationFILED: NEW YORK COUNTY CLERK 06/05/ :59 PM INDEX NO /2015 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 06/05/2015
FILED: NEW YORK COUNTY CLERK 06/05/2015 05:59 PM INDEX NO. 651993/2015 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 06/05/2015 SUPREME COURT OF THE STATE OF NEW YORK NEW YORK COUNTY YYSB TRUST against Plaintiff,
More informationPrufrex USA, Inc. TERMS AND CONDITIONS OF PURCHASE
Prufrex USA, Inc. TERMS AND CONDITIONS OF PURCHASE 1 Contract Formation: These Terms and Conditions of Purchase (the "Terms and Conditions") apply to any purchases by Prufrex USA, Inc., its subsidiaries,
More informationFILED: NEW YORK COUNTY CLERK 03/19/ :45 PM INDEX NO /2016 NYSCEF DOC. NO. 168 RECEIVED NYSCEF: 03/19/2018
SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK ---------------------------------------------------------------------X PRIME HOMES LLC, Plaintiff Index No.: 151308l2016 -against- Verified Answer
More informationFILED: NEW YORK COUNTY CLERK 08/26/ :23 PM INDEX NO /2015 NYSCEF DOC. NO. 18 RECEIVED NYSCEF: 08/26/2015
FILED: NEW YORK COUNTY CLERK 08/26/2015 01:23 PM INDEX NO. 190245/2015 NYSCEF DOC. NO. 18 RECEIVED NYSCEF: 08/26/2015 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK ---------------------------------------------------------------------X
More informationFILED: NEW YORK COUNTY CLERK 01/18/ :40 PM INDEX NO /2014 NYSCEF DOC. NO. 66 RECEIVED NYSCEF: 01/18/2018
FILED : NEW µyork COUNTY CLERK 10/24 /2014 04 : 5 4 INDEX NO. at ~ PM NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 10/24/2014 NEW' SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK ----------------------------------------------------X
More informationFILED: BRONX COUNTY CLERK 01/08/2014 INDEX NO /2012E NYSCEF DOC. NO. 11 RECEIVED NYSCEF: 01/08/2014
FILED: BRONX COUNTY CLERK 01/08/2014 INDEX NO. 21865/2012E NYSCEF DOC. NO. 11 RECEIVED NYSCEF: 01/08/2014 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF BRONX ------------------------------------------------------------------------------X
More informationFILED: KINGS COUNTY CLERK 08/02/ :23 AM INDEX NO /2016 NYSCEF DOC. NO. 7 RECEIVED NYSCEF: 08/02/2016
FILED: KINGS COUNTY CLERK 08/02/2016 11:23 AM INDEX NO. 505521/2016 NYSCEF DOC. NO. 7 RECEIVED NYSCEF: 08/02/2016 JFC/dra/168105 TA-2015-06-17-0003-001 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF
More informationSample STATE OF NEW YORK CREDITOR. ,, SUMMONS Plaintiff, Index No. -vs- Date Filed: DEBTOR d/b/a. ,, Defendant. TO THE ABOVE-NAMED DEFENDANT:
STATE OF NEW YORK SUPREME COURT COUNTY OF CREDITOR,, SUMMONS Plaintiff, Index No. -vs- DEBTOR d/b/a,, Defendant. TO THE ABOVE-NAMED DEFENDANT: Date Filed: YOU ARE HEREBY SUMMONED and required to submit
More informationRequest For Proposals Hwy 124 E ADA Door Opener Hallsville City Hall
Request For Proposals 2018-1 202 Hwy 124 E ADA Door Opener Hallsville City Hall The City of Hallsville, Missouri (the City ) seeks bids from qualified contractors for all materials and labor to install
More informationFILED: NEW YORK COUNTY CLERK 07/06/ :18 PM INDEX NO /2006 NYSCEF DOC. NO. 32 RECEIVED NYSCEF: 07/06/2016. Exhibit 21
FILED: NEW YORK COUNTY CLERK 07/06/2016 06:18 PM INDEX NO. 111768/2006 NYSCEF DOC. NO. 32 RECEIVED NYSCEF: 07/06/2016 Exhibit 21 SCAf.r.EllONWIOl11l1,---------------------- SUPREME COURT OF THE STATE OF
More informationFILED: NASSAU COUNTY CLERK 12/14/ :53 PM INDEX NO /2018 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 12/14/2018
SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NASSAU... ------X Index No. PRACTICE PROVIDER CORPORATION, Date of Purchase: Plaintiff, SUMMONS - against - Plaintiff designates Nassau County as the place
More informationFILED: NEW YORK COUNTY CLERK 01/17/ :26 PM INDEX NO /2015 NYSCEF DOC. NO. 55 RECEIVED NYSCEF: 01/17/2016
FILED NEW YORK COUNTY CLERK 01/17/2016 1226 PM INDEX NO. 156305/2015 NYSCEF DOC. NO. 55 RECEIVED NYSCEF 01/17/2016 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK --------------------------------------------------------------------x
More informationFILED: NEW YORK COUNTY CLERK 05/20/ :40 AM INDEX NO /2016 NYSCEF DOC. NO. 6 RECEIVED NYSCEF: 05/20/2016
FILED NEW YORK COUNTY CLERK 05/20/2016 1040 AM INDEX NO. 152848/2016 NYSCEF DOC. NO. 6 RECEIVED NYSCEF 05/20/2016 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK ZOE DENISON, Plaintiff, INDEX
More informationFILED: QUEENS COUNTY CLERK 10/02/ :40 PM INDEX NO /2016 NYSCEF DOC. NO. 16 RECEIVED NYSCEF: 10/02/2016
FILED: QUEENS COUNTY CLERK 10/02/2016 01:40 PM INDEX NO. 708148/2016 NYSCEF DOC. NO. 16 RECEIVED NYSCEF: 10/02/2016 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF QUEENS -------------------------------------------------------------------X
More informationFILED: NEW YORK COUNTY CLERK 12/18/ :16 AM INDEX NO /2014 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 12/18/2014. Plaintiffs, Deadline.
FILED: NEW YORK COUNTY CLERK 12/18/2014 10:16 AM INDEX NO. 162501/2014 NYSCEF DOC. NO. 1 RECEIVED NYSCEF: 12/18/2014 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK RICHARD CARDEN, individually
More informationCAUSE NO. INTERNATIONAL CENTER IN THE DISTRICT COURT OF DEVELOPMENT, IX, LTD., VS DALLAS COUNTY, TEXAS. Defendant JUDICIAL DISTRICT
CAUSE NO. Filed 11 December 16 P12:12 Gary Fitzsimmons District Clerk Dallas District INTERNATIONAL CENTER IN THE DISTRICT COURT OF DEVELOPMENT, IX, LTD., Plaintiff VS DALLAS COUNTY, TEXAS BOKA POWELL,
More informationFILED: NEW YORK COUNTY CLERK 02/19/ :38 AM INDEX NO /2016 NYSCEF DOC. NO. 14 RECEIVED NYSCEF: 02/19/2016
FILED: NEW YORK COUNTY CLERK 02/19/2016 11:38 AM INDEX NO. 805036/2016 NYSCEF DOC. NO. 14 RECEIVED NYSCEF: 02/19/2016 SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF NEW YORK LACHANDA WHITE, as Mother
More informationFILED: KINGS COUNTY CLERK 08/10/ :35 PM INDEX NO /2015 NYSCEF DOC. NO. 70 RECEIVED NYSCEF: 08/10/2018 EXHIBIT 4
EXHIBIT 4 FILED: KINGS COUNTY CLERK 05/08/2018 04;47 PM WATER STREET REALTY GROUP LLC and YARON HERSHCO, Defendants,....----X -- â â ----- â WATER STREET REALTY GROUP LLC and YARON HERSHCO, Third-Party
More informationNon-Recourse Dealer Agreement
This Non-Recourse Dealer Agreement ( Agreement ) is entered into between Freedom Truck Finance, LLC ( FTF ), a Texas limited liability corporation, and the undersigned dealership ( Dealer ) effective as
More informationFILED: NEW YORK COUNTY CLERK 09/13/ :43 PM INDEX NO /2015 NYSCEF DOC. NO. 47 RECEIVED NYSCEF: 09/13/2016. Exhibit 1
FILED: NEW YORK COUNTY CLERK 09/13/2016 07:43 PM INDEX NO. 651052/2015 NYSCEF DOC. NO. 47 RECEIVED NYSCEF: 09/13/2016 Exhibit 1 FILED: NEW YORK COUNTY CLERK 03/31/2015 06:03 PM INDEX NO. 651052/2015 NYSCEF
More informationIN THE CIRCUIT COURT OF COOK COUNTY, ILLINOIS COUNTY DEPARTMENT, CHANCERY DIVISION MECHANICS LIEN SECTION
IN THE CIRCUIT COURT OF COOK COUNTY, ILLINOIS COUNTY DEPARTMENT, CHANCERY DIVISION MECHANICS LIEN SECTION REYES GROUP, LTD., ) an Illinois Corporation, ) ) Plaintiff, ) ) -vs- ) No.: ) POWERS & SONS CONSTRUCTION
More informationFILED: QUEENS COUNTY CLERK 03/06/ :01 PM INDEX NO /2017 NYSCEF DOC. NO. 12 RECEIVED NYSCEF: 03/06/2018
NYSCEF DOC. NO. 12.. NYSCEF FILED DOC. : QUEENS NO. 12 COUNTY CLERK 03 / 0 1/2 017 12 : 12 PM) SUPREME COURT OF THE STATE OF NEW YORK COUNTY OF QUEENS ------------------------------------------------------------------------X
More information