VIE: Ben Luc-Long Thanh Expressway Project

Size: px
Start display at page:

Download "VIE: Ben Luc-Long Thanh Expressway Project"

Transcription

1 Social Monitoring Report 3rd Quarterly Report December 2017 VIE: Ben Luc-Long Thanh Expressway Project Prepared by the Viet Nam Expressway Corporation for the Asian Development Bank.

2 NOTE This social monitoring report is a document of the borrower. The views expressed herein do not necessarily represent those of ADB's Board of Directors, Management, or staff, and may be preliminary in nature. In preparing any country program or strategy, financing any project, or by making any designation of or reference to a particular territory or geographic area in this document, the Asian Development Bank does not intend to make any judgments as to the legal or other status of any territory or area. Page ii

3 SOCIALIST REPUBLIC OF VIETNAM MINISTRY OF TRANSPORT Vietnam Expressway Corporation (VEC) Land Acquisition and Resettlement Monitoring Report The 3 rd Quarter of 2017 Final Greater Mekong Sub region (GMS) Ben Luc-Long Thanh Expressway Project Package C1: Supervision Consulting Services Loan No: 2730-VIE (ADB) No: 65/HDTV VEC/2014 December 2017 DASAN CONSULTANTS CO. LTD., in joint venture with KUNHWA ENGINEERING & CONSULTING CO., LTD., and INTERCONTINENTAL CONSULTANTS AND TECHONOCRATS PVT., LTD Page iii

4

5 ACRONYMS ADB AHHs APs BLLT B CSC CoLUR DCCs DMS DoLISA DONRE EPMU GoV GMS GRC HCM City HHs IA IMR IRP IR MOT MOU M CoLFD PPCs PROW RP R & R SEPMU SPS TOR URP VEC Asian Development Bank Affected Households Affected Persons Ben Luc-Long Thanh Expressway Billion Construction Supervision Consultant Certification of land using Right District Compensation Committees Detailed Measurement Surveys Department of Labor, Invalids and Social Affairs Department of Natural Resource and Environment Expressway Project Management Unit Government of Vietnam Greater Mekong Sub region Grievance Redress Committee Ho Chi Minh City Households Implementing Agency Internal Monitoring Report Income Restoration Program Involuntary Resettlement Ministry of Transport Memorandum of understanding Million Center of land fund Development Provincial People s committee Proposed Right of Way Resettlement Plan Resettlement & Rehabilitation South Expressway Project Management Unit ADB Safeguard Policy Statement Terms of Reference Updated Resettlement Plan Vietnam Expressway Corporation

6 Table of Contents I. INTRODUCTION... 6 II. PROJECT DESCIPTION... 6 III. MONITORING AND REPORTING... 9 IV. OBJECTIVES OF INTERNAL MONITORING REPORT (IMR)... 9 V. LAND ACQUISITION AND RESETTLEMENT IMPACTS Number of Household affected by land acquisition Area of Impacted Land as per Updated Decision Budgeted amount for RP implementation...12 VI. PHYSICAL AND FINANCIAL PROGRESS OF LAND ACQUISITION Number of Affected Households (HHs) Fully Paid...13 *1HHs in J3, have not received the compensation as he is disputing. The amount of compensation has been put in Treasury Total Land Area under Acquisition paid Amount Disbursed to Affected Households...15 VII. GENERAL PROGRESS ON GROUND CLEARANCE AND HANDING OVER Status for land clearance and handing over of Acquired land Status on Ground Clearance and Handing over of land by Affected Households...16 VIII. OBSTRUCTION ON HANDING OVER OF LAND AND GROUND CLEARANCE Issues affecting Timely Land Handover: Initiative to resolve the Issues, affecting Timely Land Handover:...19 IX. RE-ESTABLISHMENT OF AHHs SETTLEMENTS AND BUSINESS ENTERPRISES; X. GRIEVANCES AND REDRESSAL Grievances Received and Redressed...26 XI. RELOCATION AND TRANSFER Resettlement Preferences of Eligible Affected Households Status of Resettlement Site development Obstruction in Relocation...30 XII. INCOME RESTORATION PROGRAM (IRP) IMPLEMENTATION Final list of HHs participated in the income restoration program (IRP) Vulnerable Group and their Participation in IRP Status on IRP Implementation Status on Schedule of IRP Implemetation: Evaluation of IRP Implementation in Can Gio District Completion Evaluation Report on IRP implementation in Can Gio District...45 XIII. PREPARATION OF RESETTLEMENT PLAN (RP) ADDENDUM : Page ii

7 LIST OF TABLES Table 1.The Package details and Length of the BLLT expressway project... 7 Table 2. The project profile and contractors... 7 Table 3. Updated number of Affected Households in comparison to RP list Table 4. Updated Area of Affected Land Table 5. Resettlement Budget as per URP and Updated Decision Table 6. Number of Fully Paid Affected Households (HHs) Table 7. Total Land area paid Table 8. Disbursement of Compensation to Affected Households Table 9. General Progress in Land Clearance and Handing over of Land Table 10. General Progress in Land Clearance and Handing over Land Table 11. Main Issues on Handing over of land up till Sept Table 12. Initiative to Resolve the Issues Table 13. Land recovery, compensation and ground clearance procedures Table 14. No. of Grievances Received and Resolved Table 15. Resettlement Preferences of Fully Affected Households Table 16. Status of Resettlement Site Development up till Sept Table 17. Obstruction in Relocation Table 18. Final Households list to Participate in IRP (Tranche-1) Table 19. Vulnerable Group Participation in IRP Table 20. Status on IRP implementation Table 21. Provision of Training to IRP Participating Households Page iii

8 LIST OF FIGURES Figure 1.Layout of Project Figure 2. General Location of Project in transport system of Ho Chi Minh City and Surrounding Figure 3. Package A1: Status of Project Location updated to February 24, 2016 on Aerial Photograph 29 Figure 4. Package A2-1: Status of Project Location updated to January 23, 2017 on Aerial Photograph29 Figure 5. Package A2-2: Status of Project Location updated to January 23, 2017 on Aerial Photograph31 Figure 6. Package A3: Status of Project Location updated to January 23, 2017 on Aerial Photograph.. 31 Figure 7. Package A4: Status of Project Location updated to January 23, 2017 on Aerial Photograph.. 33 Figure 8. Package J1, J2, J3: Status on Location updated January 23, 2017 on Aerial Photograph Figure 9. Package A5, A6, A7-ADB Section III- Status of Project Location Page iv

9 LIST OF ANNEXURES Annex 1: Status on Handing over of land and Ground Clearance (ADB Section) Annex 2: Critical Locations need urgent Ground Clearance and Handing Over Annex 3: Notification of HCMC People s committee (PC) on license to construct New House Annex 4: Minute of Meeting on handing over of land to construct P2 Pillar Annex 5: Final Updated List of households participated in IRP Annex 6: Updated list of Vulnerable Group, participated in IRP Annex 7: List of HHs already received input in IRP Annex 8: Income Restoration Program Implementation Schedule Page v

10 I. INTRODUCTION 1. The Ben Luc-Long Thanh Expressway Project (BLLT) is one of the 16 expressways under Eastern North-South Expressway as per Development planning of Vietnam expressway network toward 2020 and the vision after 2020 and Detailed planning of Eastern North-South Expressway, approved by the Prime Minister through Decision No. 1734/QD-TTg, dated 01 December 2008 and Decision No. 140/QD-TTg, dated 21 January The Ben Luc - Long Thanh Expressway Project has an overall length of 58km. It traverses through 16 Communes in 7 Districts of 3 Provinces. This proposed expressway starts from My Yen Commune and part of an access-road in Tan Buu Commune, Ben Luc District, Long An Province; and traverses through Binh Chanh Commune, Tan Quy Tay Commune, Hung Long Commune, Da Phuoc Commune in Binh Chanh District; Nhon Duc Commune, Long Thoi Commune in Nha Be District, and Binh Khanh Commune in Can Gio District, in Ho Chi Minh City; then goes through Phươc Khanh commune, Vinh Thanh Commune, Phuoc An Commune in Nhon Trach District, Long Phuoc Commune, and ends at Phuoc Thai Commune in Long Thanh District of Dong Nai Province. The proposed right of way (PROW) and land acquisition area along the route varies from 56m - 73m wide. 3. The project expressway is divided into three section; western section (21.14 km), middle section (10.71 km), and eastern section (25.25 km). For the expressway construction, ADB (Asian Development Bank) finances the western and eastern sections, and Japan International Cooperation Agency (JICA) finances the middle section. The project was estimated to cost $1.608 billion at appraisal, inclusive of local taxes, contingencies, and financing charges during development. Tranche 2 in the amount of $286 million will cover construction of the eastern section of the expressway. II. PROJECT DESCIPTION 4. Ben Luc Long Thanh Expressway has an overall length of 57.7 km and divided into 11 construction packages. Construction is being carried out at 8 packages and the entire budget for construction is being funded by ADB and JICA. The JICA funding covers section II (middle section), which include packages: J1; J2; J3. The ADB funding covers ADB section I (packages: A1; A2-1; A2-2; A3; A4) and ADB section III (Packages: A5, A6, A7). (Table 1 &2)

11 ADB section III JICA section II ADB section I Table 1.The Package details and Length of the BLLT expressway project Length Sl. No. Pkg. No. From Km to Km (in Km.) Province District Covered Commune My Yen/ Ben Luc Long An Tan Buu 1 Package A-1 Km0+600 Km Km Can Giuoc Phuoc Ly Ho Chi Minh City Binh Chanh Binh Chanh Tan Quy Tay Ho Chi Minh City Binh Chanh Tan Quy Tay 2 Package A 2-1 Km7+900 Km Km Long An Can Giuoc Long Thuong Ho Chi Minh city Binh Chanh Hung Long 3 Package A 2-2 Km Km Km Ho Chi Minh city Binh Chanh Hung Long Da Phuoc 4 Package A-3 Km Km Km Ho Chi Minh city Binh Chanh Da Phuoc Nha Be Nhon Duc 5 Package A- 4 Km Km km Ho Chi Minh city Nha Be Nhon Duc/ Long Thoi 6 Package J- 1 Km Km km Ho Chi Minh city Nha Be Long Thoi Can Gio Binh Khanh 7 Package J -2 Km Km km Ho Chi Minh city Can Gio Binh Khanh 8 Ho Chi Minh city Can Gio Binh Khanh Km Km km Package J- 3 Dong Nai Nhon Trach Phuoc Khanh 9 Phuoc Khanh Km Km km Dong Nai Nhon Trach Package A -5 Vinh Thanh 10 Vinh Thanh Km Km km Dong Nai Nhon Trach Package A- 6 Phuoc An Nhon Trach Phuoc An Km Km km Dong Nai Long Phuoc Long Thanh 11 Packager A- 7 Phuoc Thai Grand Total : 57,7 km Source: Resettlement Plan of all concerned sub-project road, VEC s documents and detail design Remark Table 2. The project profile and contractors Description ADB section I - Packages * Project Name A-1. A-2.1 A-2.2 A-3. A-4. Project Location Km Contract Number Executing Agency 03/HDXD- VEC/2015 Vietnam Expressway Corp. Km.: /HDXD- VEC/2015 Vietnam Expressway Corp. Km /HDXD- VEC/2014 Vietnam Expressway Corp. Km.: /HDXD- VEC/2015 Vietnam Expressway Corp. Km.: /HDXD- VEC/2015 Vietnam Expressway Corp Contract Length Km Km Km Km km Source of Fund ADB Loan No.: VIE ADB Loan No.: 2730-VIE ADB Loan No.: 2730-VIE ADB Loan No.: 2730-VIE ADB Loan No.: 2730-VIE Contractor JV Halla Corp Vinaconex Eng.Cons. & JV Kukdong Eng.Consut. Co.-Trung Chinh T.C. Joint Venture of Samwhan Corporation - Vạn Cuong JV Halla Corp Vinaconex Eng.Cons.& Invest.JSC. JV of Kukdong Eng. & Construction Co., Ltd., Dong Me Kong Construction and Page 7

12 Description ADB section I - Packages * Project Name A-1. A-2.1 A-2.2 A-3. A-4. Invest.JSC. NTP May 26 th, 2015 Trading Service Co. Ltd. May 19 th, 2015 Aug. 15th 2015 May 19 th, 2015 August 06 th, 2016 Contract Period 1080 days 1,076 days 1050 days 1,095 days 900 days Description JICA section I - Packages * Project Name J-1. J-2 J-3 Project Location Km Km.: Km Contract Number Executing Agency Vietnam Expressway Corp. Vietnam Expressway Corp. Vietnam Expressway Corp. Contract Length km km 2.92 km Source of Fund JICA JICA JiCA Contractor LD Shimizu Vinaconex E&C LD Sumitomo Mitsui Cienco 4 LD Sumitomo Mitsui Cienco 4 NTP 1/April / /October/2014 4/February/2016 Contract Period 47 months ( 1410 days) 32 months ( 960 days) 42 months ( 1260 days) Description ADB section III - Packages * Project Name A 5. A6 A7 Project Location Km Km.: Km Contract Number Executing Agency Vietnam Expressway Corp. Vietnam Expressway Corp. Vietnam Expressway Corp. Contract Length 3.45 Km 16.5 Km 5.3 Km Source of Fund ADB Loan No.: 2730-VIE ADB Loan No.: 2730-VIE ADB Loan No.: VIE Contractor have not signed contract have not signed contract have not signed contract NTP have not signed contract have not signed contract have not signed contract Contract Period have not signed contract have not signed contract have not signed contract Source: Resettlement Plan of all concerned sub-project road, VEC s documents and detail design Page 8

13 III. MONITORING AND REPORTING 5. This report is concerned with the monitoring and reporting of Resettlement Plan (RP) implementation. The main objective of monitoring of resettlement work is to provide an insight and guidelines to the management for assessing the progress of resettlement. Its objective is to identify probable difficulties and problem area, like a RADAR system providing an early warning system, which need correction. 6. In order to ensure effective implementation of the Resettlement Plan (RP) and achievement of the set targets, internal monitoring of Resettlement & Rehabilitation (R&R) components of the project has been carried out by the EA with the help of Resettlement Specialist of project supervision consultant (PSC), to enable timely adjustment of implementation set up and procedures. 7. Now, South Expressway Project Management Unit (SEPMU) of Ben Luc Long Thanh (BLLT) Expressway Project is the representative of the executing agency (VEC) and is responsible for internal monitoring. As per agreed RPs, SEPMU has to submit quarterly monitoring report to ADB and VEC. This quarterly monitoring report No.3 (QRNo-3) of 2017 presents the status of land acquisition and handing over of land for the project & income restoration program (IRP) implementation up till September, IV. OBJECTIVES OF INTERNAL MONITORING REPORT (IMR) 8. The objectives of the monitoring program are: 1) Monitoring of gender disaggregated resettlement progress of the affected HHs under RP implementation, in particular land acquisition and handing over land to project and implementation of IRP 2) Assessment of monitoring the standard of living of Affected Households (AHHs) are restored or improved; 3) monitoring whether the overall project and resettlement objectives are being met; 4) assess, if rehabilitation measures and compensation are sufficient; 5) Identify problems and risks; and identify measures to mitigate problems. 6) Identify and explain issues in Memorandum of Understanding ( MOU) of each ADB mission to meet Safeguards Policy Statement (SPS), The range of activities and issues that need to be recorded and verified, include: 1) Compensation, allowance payments and delivery of assistance measures to affected households (AHHs); 2) Re-establishment of AHHs settlements and business enterprises; 3) Reaction of AHHs, in particular, to resettlement and compensation packages; and 4) Implementation of IRP to restore income of HHs after land acquisition 5) Review and support (if necessary) to resolve disputes and grievances of AHHs 6) Assistance provided to AHHs in relocation to new resettlement sites. 10. SEPMU has invited bidding for the selection of external monitor to make compliance of ADB directives; however, no decision has been taken up till 3 rd Q There is no external monitor, who could monitor and evaluate the RP updating and implementation. Page 9

14 11. For this Project, a Consulting service contracts has been made on 12th November 2014 between Vietnam Expressway Corporation (hereinafter refer to as VEC) and Joint Venture of Dasan Consultant Co., Ltd, with Kunhwa Engineering & Consultant Co., Ltd. and Intercontinental Consultants and Technocrats Pvt., Ltd, as project supervision consultant (PSC). The Team Leader /Highway Engineer of the project supervision consultant act as the Engineer of the Project, while Resettlement Specialist of PSC will assist in the updating, implementation and monitoring of RP activities V. LAND ACQUISITION AND RESETTLEMENT IMPACTS 5.1 Number of Household affected by land acquisition 12. There is no change in the final list of affected households from June 2017 up till September 2017, the reporting period. This list is updated and verified every quarter by Center of Land Fund Department (CoLFD) of the district on the basis of decision of land acquisition and compensation plan, and finally approved by Chairman, Peoples Committee of the Province. The details are presented in Table-3 below: Table 3. Updated number of Affected Households in comparison to RP list No of Affected HHs Sl. No. Station District/ Commune (As per URP) Up till June 2017 Updated Decision (Jul- Sept 17) Male (M) Female (F) Total Remarks 1 Km to Km Ben Luc District A. Tan Buu B. My Yen Total Km to Binh Chanh District A. Binh Chanh B. Tan Quy Tay C. Hung Long D. Da Phuoc Total 1, Km to Km Can- Giuoc District A. Phuoc Ly B. Long Thuong Total Km to Nha- Be District* A. Non-Duc B. Long Thoi Total JICA Section (J1, J2-J3)* Can Gio District Page 10

15 Sl. No. 6 Station Km to Km to District/ Commune (As per URP) Up till June 2017 No of Affected HHs Updated Decision (Jul- Sept 17) Male (M) Female (F) Total Binh Khanh Phuoc Khanh** Total Nhon Trach District Phuoc khanh NA NA 104 Vinh Thanh NA NA 376 Phuoc An NA NA 447 Remarks land acquisition is carrying out Total NA NA 861 Long Thanh NA NA District Long phuoc 1 1 NA NA 1 land Phuoc Thai NA NA 273 Total NA NA 274 acquisition is carrying out Grand Total Source: Resettlement Plan of all concerned sub-project road, updated decision of land acquisition and compensation plan, VEC s documents and detail design and DCC in each district * It is noted that -J1 part of JICA section II, falls in a part of Long Thoi Commune of Nha Be District (about 80 HHs) and **J3 part of JICA section II, fall in a part of Phuoc Khanh Commune of Nhon Trach District (about 80 HHs). 5.2 Area of Impacted Land as per Updated Decision 13. Land Acquisition is the major issues that determine the progress of work. Since, the project alignment has been designed in a new land, hence, major part of land consists of agriculture land (nearly 85%), while the remaining are residential land and swampy river area. The table below gives clear picture of updated status of land acquisition: Table 4. Updated Area of Affected Land Area of Affected Land Sl. No. District / Commune Package Govt. Land Up till June 2017 Jul- Sept 2017 Private Land Total Land Govt. Land Private Land Total Land % Change 1 Ben Luc A Binh Chanh A1, A2-1, A2-2 and A Can Giuoc A1, A Nha Be A3, A4, J Can Gio J2 & J Nhon Trach J3,A 5, A 6, A Page 11

16 7 Sl. No. District / Commune Long Thanh Package Govt. Land Area of Affected Land Up till June 2017 Jul- Sept 2017 Private Land Total Land Govt. Land Private Land Total Land % Change A Total Source: VEC s documents and detail design and DCCs of each project District 14. The above table shows that there is no change in recovered land area from previous reporting period. 15. The updating in recovered land area at this juncture is due to updating of land acquisition at micro level for each household, duly verified by the joint team of EPMU, Contractors and Local authorities of each District. The land area reflected in the DMS (Detailed Measurement Survey) at design stage was a generic assessment, while the updating of impact on land at this stage of implementation is being done as per actual measurement, considering the design consideration. 16. In the previous reporting period, a reduction in land acquisition area in different packages was observed, which was attributed to factors like, recording of land area not based on micro level assessment but based on general decision of DCC (district compensation committee); account of land concerning canal, ditch, and road and inclusion of small scrublands etc., which has been well explained in quartrerly-1 report (March 2017) 17. It is also pertinent to mention here that it was March 2017, when EPMU, Contractors and Local authorities of each District have decided to carry out updating of land acquisition area for each household at micro level. Accordingly, a detail of land acquisition for each household at micro level was started measured and updated. Now onwards, the data received from joint verification/ measurement of the stated team will be used for calculation of land acquisition area and will be updated each month. 18. A minor change in total land acquisitioin area is still expected in packages (A5, A6 & A7) of section-iii, where land acquisition process is in the way. 5.3 Budgeted amount for RP implementation 19. The table below shows the resettlement budget as per updated decision up till Sept 2017 and its comparison with the URP and the previous quarter (please see remarks column in the table): Sl. No. District Table 5. Resettlement Budget as per URP and Updated Decision Pkg LAR Budget Requirement (in Billion VND) Unit: (VND billion) Remarks Updated as Up till June As per URP on Sept Ben Luc A The updated information on final 2 Can Giuoc A1, A resettlement budget is based on Master list and various updated Page 12

17 Sl. No. District Pkg As per URP LAR Budget Requirement (in Billion VND) Up till June 2017 Updated as on Sept Binh Chanh A1, A2-1, A2-2, A3 1, Nha- Be A3, A4, J Can Gio J1, J2, J Remarks Decision of District compensation Committee to pay compensation, support and resettlement to each affected household 6 Nhon Trach A5, A6, A Long Thanh A Total 3, The above table, updated in Quarter-3 (Sept 2017), enunciates that there is no change in land acquisition budget as there is no in land recovered area. The Land acquisition cost is being updated at micro level at the time of actual payment during implementation. This budget will keep changing up till completion of RP implementation activities, which will be updated in every quarterly report. VI. PHYSICAL AND FINANCIAL PROGRESS OF LAND ACQUISITION 21. Monitoring of resettlement progress of the affected HHs under RP implementation, in particular land acquisition and handing over land of land has been carried out in this quarter like previous quarter. During this reporting period it was tried to appraise gender segregated monitoring of the resettlement progress of the affected HHs, reflected in subsequent sections. 6.1 Number of Affected Households (HHs) Fully Paid 22. Acting upon the action plan on distribution of compensation, district and commune people s committee are almost in advance stage for Compensation payment with the help of their team members and Executing Agency. 23. As against the acquired land and property, the compensation has been paid in full to 87.94% affected households up till September 2017 in comparison to % % in Q-2, June 2017, a substantial progress from last reporting period. The payment detail up till date has been drawn in the Table-6. The payment was made in accordance with priority of construction activities % compensation has been made to JICA section, while it is % in Section-1 (Western section- A1, A2-1, A2-2, A3 & A4), a little increase from last reporting period. 25. A significant improvement has been witnessed in compensation payment for section-iii (Eastern Section- A5, A6 & A7), where an average 68.50% HHs have been paid up till this reporting period, as against % from last reporting period % HHs have been paid in package A6, a huge advancement from previous reporting period, while in last reporting period the payment was only 37.17%. 27. Remaining unpaid HHs is being paid as per priority. Page 13

18 Table 6. Number of Fully Paid Affected Households (HHs) Total Number of No. of Affected Households Paid Packages Affected Households Up till March 2017 Up till June2017' Up till Sept (HHs) HHs % HHs % HHs % Package A % % % Package A % % % Package A % % % Package A % % % Package A % % % Total % % % Package J % % % Package J % % % Package J % % 107* % Total % % % Package A % % % Package A % % % Package A % % % Total % % % Grand Total % % % *1HHs in J3, have not received the compensation as he is disputing. The amount of compensation has been put in Treasury 6.2 Total Land Area under Acquisition paid % of acquired land has been paid up till this reporting period, while it was % in last reporting period. The payment has been made maximum % in JICA section (1 HH is diputing the compensation and amount of which is put into treasury, however, he handed over the land for construction), while it is more than % in Packages A1, A2-1 A3 & A4, comprising Ben Luc, Can Giouc, and Can Gio districts respectively. The payment in Long Thanh District, which was just initiated in last reporting period, has got momementum during this reporting period and % land area in this district has been paid. The package wise detail on status of land area paid is delineated in Table 7. Packages Recovered land area (ha) Table 7. Total Land area paid Land area already paid Up till June 2017 Up till Sept Area (Ha) % Area (Ha) % Package A % % Package A % % Package A % % Package A % % Package A % % Total % % Package J % % Page 14

19 Land area already paid Recovered land Packages Up till June 2017 Up till Sept area (ha) Area (Ha) % Area (Ha) % Package J % % Package J % % Total % % Package A % % Package A % % Package A % % Total % % Grand Total % % 6.3 Amount Disbursed to Affected Households 29. Payment of compensation is being carried out by District Compensation Committee (DCC) in each District. The compensation to affected households is being paid through a/c payee cheques to maintain the transparency in the payment process. In this context, financial progress of compensation and allowances, paid to eligible HHs, was aslo monitored. 30. The summary of district wise progress of disbursed amount, are presented in Table-8, which indicates the disbursement of compensation and allowances up till Sept 2017 Sl. No District Table 8. Disbursement of Compensation to Affected Households Updated Compensation Cost As of Up to June 2017 Sept 2017 Up to June 2017 Paid % Up to Sept Ben Luc Can Giuoc Binh Chanh Nha Be Can Gio Nhon Trach Long Thanh Total Remarks Unit: (VND billion) *1 case pending due to court case, however, compensation amount has been deposited in treasury Unpaid cases due to unresolved cases of Grievances In the process of resolving grievances in branch A Land Acquisition and approval of Budget is linked to construction activites, hence, payment is being made in accordance with priority of construction activities. Land Acquisition and approval of Budget is linked to construction activites, hence, payment is being made in accordance with priority of construction activities.. Page 15

20 VII. GENERAL PROGRESS ON GROUND CLEARANCE AND HANDING OVER 7.1 Status for land clearance and handing over of Acquired land 31. Land Acquisition and Ground Clearance are nearly on completion in all concerned districts of ADB section-1 (reached up 97% for all packages). Handing over of land area in Packages A1, A2-1, A2-2 and A3 & A4 is 98 %, 99%, 94%, and 100 % respectively. Only in Binh Chanh District, especially in package A2-2, the handing over of land witnessed a little progress. 32. The disbursement in two Districts; Nhon Trach and Long Thanh are being carried out as per priority, linked to construction activity. However, during this reporting period, there was a good progress in compensation payemtnas as well as handing over of land, where 77 % of the affected Households have handed over the land 33. The details of progress in land clearance and status of handing over of land to Civil works up till Sept 2017 has been weighed up in Table No 9: (See detail in Annex 1) Package Table 9. General Progress in Land Clearance and Handing over of Land Recovered land area (ha) / AHHs No. Up till June 2017 Up to Sept Land Handed over (ha) % Handed Over land handed over ( ha) % hand over Percentage progreaa from previous rep;orting period (%) Remaining % up till Sept 2017 (%) Package A % % 0.0% 2% Package A % % 0.0% 1% Package A % % 0.1% 6% Package A % % 0.0% 0% Package A % % 0.0% 0% Total (A) % % 0.1% 3% Package J % % 0.0% 0% Package J % % 0.0% 0% Package J % % 0.0% 0% Total (B) % % 0.0% 0% Package A % % 0.0% 9% Package A % % 12.8% 18% Package A % % 7.4% 53% Total (C) % % 10.2% 23% Grand Total (A+B+C) % % 4.0% 10% * Resource: Report from contractors and EPMU s staffs and construction sites in each package and report of CoLFD and DCC in each District to Sept, Status on Ground Clearance and Handing over of land by Affected Households 34. The assessment of handing over of land by affected households (HHs) in eastern section has also been done. The finding reveals % HHs have handed over the land for construction up till Sept 2017, which is about 10. 5% more than last reporting period, June 2017 (77.76 % of the HHs). The percentage of affected households in western section, who handed over the land is now 96.9 % higher than last reporting period of 96.8 %, while remaining districts in western section have Page 16

21 achieved the target of either100.00% or over % (Ben Luc District is 99.7 %; Can Giuoc is 100%, Nha Be is 99.8% and Can Gio is 100 % respectively). Nhon Trach district of eastern section has also achieved good progress, i.e., % in land handing over. District A-Ho Chi minh city Table 10. General Progress in Land Clearance and Handing over Land Total HHs Already Handed over Up till June 2017 Not yet hand over % rate of hand over Already handed over Up to Sep 2017 not yet hand over % rate of hand over % rate of hand over in reporting period ( July - Sep 2017) Ben Luc % % 0.0% Binh Chanh % % 0.3% Can Giuoc % % 0.0% Nha Be % % 0.0% Can Gio % % 0.0% Total % % 0.2% B-Dong Nai Province Nhon Trach % % 39.28% Long Thanh % % 0.00% Total % % 30.45% Grand Total % % 10.52% Resource: Report from contractors and SEPMU s staffs in each package and report of CoLFD and DCC in each District to Sept, 2017 VIII. OBSTRUCTION ON HANDING OVER OF LAND AND GROUND CLEARANCE 8.1 Issues affecting Timely Land Handover: 35. The total number of HHs, who have not handed over the land to the project due to various reasons, is 866 in number. Most of the Households, who haven t handed over the land in eastern section, fall in Binh Chanh District; i.e., 71 HHs. These HHs have not yet handed over the land to Project (most of in package A2-2). The details of HHs, who have not handed over the land is due to the following reasons: Ben Luc District 1) In Ben Luc District there is still one household with disputes over land ([This information has been removed as it falls within exceptions to disclosure specified in paragraph 97, (exception (x) Information that, if disclosed, would or would be likely to endanger the life, health, safety, or security of any individual, or safety or security of ADB assets, or to prejudice the defense or national security of a member) of ADB s Public Communications Policy (2011).] (2,770 m2)) with a compensation amount of VND), has not handed over the land. However, on 01/8/2017, the decision has been awarded by the People's Court of Long An Province and now District People's Committee will request handover of premises after 15 days. In the meantime, HHs has agreed to hand over a part of land plot No 1435 to facilitate the construction of Piers for interchange for the Project. Binh Chanh District Page 17

22 1) Binh Chanh District witnessed a tremendous urban development in recent past. The affected households are asking for more compensation. 2) In 2 Communes of Binh Chanh district; Hung long and Da Phươc, payment of compensation is very slow in comparison to other Communes in the project. 3) 6 HHs are disputing for compensation and lodging grievances; not yet receive Compensation 4) Currently, there are 15 HHs, who have received all payment but not handing over the land due to various reasons related to problem in resettlement (waiting Permit/ license to be constructed on remaining land part - 2 HHs; applied for construction of new house -13 HHs) 5) 46 HHs in Binh Chanh district didn t receive the money, and their money has been deposited in treasury). 6) Cases of 4 HHs are waiting Decision from court and additional supply of legal base to receive compensation, (package A HHs; 2 HHs in Package A2-2 in Hung Long Commune) Nha Be District 1) 39 HHs are disagree to sign the payment agreement and not handed over the land yet in Nha Be District. Nhon Trach District 1) 481 HHs have been paid but not handed over the land as they are waiting for Building Permits and other reason 2) 30 HHs are waiting for compensation payment Long Thanh District 1) 123 HHs have been paid but not handed over the land as they are waiting for Building Permits and other reason 2) 120 HHs are waiting for compensation payment 36. There various reasons, stated above, for delay in handing over of the land have been drawn, here, in the table below: Table 11. Main Issues on Handing over of land up till Sept 2017 No 1 2 Contents Disagree to sign the payment Agreement HHs are disputing and grievances; not yet receive Compensation Long An Province Ben Luc Main Reasons for not Handing over the land Ho Chi Minh City Province Binh Nha Be Chanh Dong Nai Province Nhon Trach Long Thanh Total Being resolved by the court In process to complete legal status 0 Page 18

23 No Contents Long An Province Ben Luc Main Reasons for not Handing over the land Ho Chi Minh City Province Binh Nha Be Chanh Dong Nai Province Nhon Trach Long Thanh Total 5 In process to issue decision of compensation 6 Put in treasury Paid but not handed over (No Building Permits and other reasons) Not yet Compensation Total * Resource: Report from contractors and EPMU s staffs are supervising construction sites in each package and report of CoLFD and DCC in each District to Sept The information on critical locations and other details of obstruction, which need urgent action on Ground Clearance, is highlighted in Annex. -2 and also see the minute in Annex Initiative to resolve the Issues, affecting Timely Land Handover: Table 12. Initiative to Resolve the Issues No Contents No. of HHs who have received compensation but waiting for Resettlement Issues to be resolved Apply for permission to build house on the remaining land. Long An Province Ben Luc Ho Chi Minh City Province Binh Chanh Nha Be Dong Nai Province Nhon Trach Long Thanh Total M F M F M F M F M F M F T NA NA NA NA Waiting for relocation NA 123 NA Applied for construction permits on agricultural land, which does not conform the planning. Number of households not receiving money. Number of HHs disputing total claims, have not received compensation Number of HHs, the cases of which are being handled by court Amount deposited in temporary custody/ NA NA NA NA NA NA NA NA NA NA NA NA NA NA NA NA NA Remarks Different Cities and Binh Chanh District will soon decide, deploying permits for households Finalization of legal procedures, early planning of consciousness raising and forcible handover of premises. 3 Not Paid NA 120 NA 150 NA 150 M / F not assessed Total No. (1+2+3) (Not Handed Over) NA 243 NA M/F HHs of Nhon Trach and Long Page 19

24 No Contents *M- Male, F- Female, T- Total Long An Province Ben Luc Ho Chi Minh City Province Binh Chanh Nha Be Dong Nai Province Nhon Trach Long Thanh Total M F M F M F M F M F M F T Remarks Thanh not available 38. As described in the last reporting period that People s committee (PC), Ben Luc District and Binh Chanh District and CoLFD and Committee of Compensation of District have organized a dialogue with HHs to resolve the pending issues of handing over of land for the Project (see minute in Annex 4). The positive outcome of this dialogue is visible on ground, when the HHs have started handing over the land for civil construction 39. There is no change up till Sept 2017 when it was reported in Q-2 report that about 8 HHs near National Highways -1, are complaining for low compensation. The CoLFD and Committee of Compensation of District are trying to convince the specified HHs through dialogue to hand over the land, however, if they fail to get the handing over of the land, the authority may issue an enforcement decision. 40. It is pertinent to mention here that Article 39 of Law of Land on Land recovery for use for objectives of national defence and security, national interest or public interest says that after a decision on land recovery and a plan for compensation, site clearance and resettlement have been approved by the competent State body, publicly announced and become effective, the person, having land to be recovered, must comply with the decision on land recovery. Where a person, having land to be recovered, fails to comply with the decision on land recovery, the people's committee at district level, which is authorized to make the decision on land recovery, shall have the right to issue an enforcement decision. 41. Land recovery, compensation and ground clearance procedures were first touched upon in Decree No. 197 and then detailed in Decree No. 84 with 12 steps. However, some of these procedures proved impractical and their implementation time limits were not clearly set, causing rampant project construction delay and affecting investor interests.in face of such situation, Decree No. 69 was issued, re-arranging the land recovery, compensation and ground clearance procedures defined in Decree No. 84 in only four steps, which is well illustarted in the following Table: Table 13. Land recovery, compensation and ground clearance procedures Steps Measures Time line for different steps Step-1 Step-2 Location recommendation and land recovery notification Formulation of compensation, support and resettlement plans The time limit for issuance of written recommendations on investment locations, land recovery notices and setting up of compensation, support and resettlement councils is 30 days after the receipt of valid investment dossiers The time for posting and public comment is at least 20 days. Past this time, the compensation, support and resettlement body will summarize the comments, indicating the numbers of pros, cons and other comments. If a large number of people disagree with the compensation, support and resettlement plan, the compensation body must clearly explain or consider and Page 20

25 Step-3 Step-4 Decision on land recovery Coercive land recovery adjust it, then finalize and send it together with summarized comments to the natural resource and environment agency for appraisal. The time limit for handover of land to compensation bodies is 20 days after they receive adequate compensation money Coercive land recovery is a strong, albeit undesirable, administrative measure to be taken by the State in necessary cases. In order to prevent such coercion from abuse and protect people s interests, coercive land recovery must be only carried out in certain cases 42. The decision on Coercive land recovery by cometent authority can be imposed in following cases: 1. If, the land recovery has been strictly carried out according to the above-mentioned three steps; or, 2. Past 30 days after the deadline for land handover, the land users concerned fail to hand over to-be-recovered land; or, 3. The land users decline to hand over to-be-recovered land though they have been persuaded by local administrations and compensation bodies; or, 4. A coercion decision has been issued according to law by a competent state body; or, 5. The coercion decision has been received by the land users concerned or publicly displayed at the office of the commune- level People s Committee of the place with the land to be recovered. 43. Coercion decisions will be enforced by coercion forces under the direction of district-level People s Committees 15 days after the decisions are received by the land users concerned or publicly displayed at the offices of the commune-level People s Committees and the land areas are not handed over. Any person, subject to a land recovery enforcement decision, must comply with it, howevr; he has the right to make a complaint. 44. The District People's Committee has directed the Compensation Site Clearance Board of Binh Chanh District to speed up the completion of the legal documents so that the site clearance can be completed. 45. Can Gio District have completed handing over of land to Project of 100%. 46. The resolved cases of handing over and present obstruction, updated up till September 2017, is shown in the figures below (Fig.-1- Fig. 14) Pictures of status of Handing over land to Project updated as on Sept Page 21

26 Fig.-1: A pilot study of road at Km 7+00 of package A1- Tan Quy Tay commune- Binh Chanh District, Ho Chi Minh city Fig.-2: HH: [This information has been removed as it falls within exceptions to disclosure specified in paragraph 97, (exception (x) Information that, if disclosed, would or would be likely to endanger the life, health, safety, or security of any individual, or safety or security of ADB assets, or to prejudice the defense or national security of a member) of ADB s Public Communications Policy (2011).] have temporary agreed for drilling foundation of EP 2 and EP 3 but not yet hand over land in August-September 2017 Fig.-3: 1 HH ([This information has been removed as it falls within exceptions to disclosure specified in paragraph 97, (exception (x) Information that, if disclosed, would or would be likely to endanger the life, health, safety, or security of any individual, or safety or security of ADB assets, or to prejudice the defense or national security of a member) of ADB s Public Communications Policy (2011).]) is obstructing handver land by waiting for Permit of house construction- A1 Binh Chanh Commune- June 2017 Fig.-4: Confirmation page of Service Organization is carrying out procedure to have Permit of new house construction for family May 2017 of HH: ([This information has been removed as it falls within exceptions to disclosure specified in paragraph 97, (exception (x) Information that, if disclosed, would or would be likely to endanger the life, health, safety, or security of any individual, or safety or security of ADB assets, or to prejudice the defense or national security of a member) Page 22

27 Fig.-5: Some households in left side of HW 1A, they already relocated and handed over land in July Contractor is constructing along HW 1A Fig.-6: Land acquisition of HW1A from the HW1A to Ben Luc District is handed over land completely in Quarter 3 of 2017 Fig.-7: Location of 1 Household is obstructing in right side of HW 1A in Package A1 ( complaint of low compensation price- HH already relocated but not yet hand over land Fig.-8: 1 HH at HW 50 is constructing new house after relocation A2-2 at Hung Long commune Fig.-5: Fig.-9: an house relocated in agust 2017 to In HW 50 in A2-2- Hung Long Commune Fig.-10: Completion of land acquisition in Da Phuoc Commune (area of agricultural land ), A2-2- June 2017 Page 23

28 Fig.-11: Completion of land acquistion in A3- Nhon Duc commune, Nha Be district- June 2017 Fig.-12: Remaining 1 HH, waiting for permit of house construction, Branch A-A4- June 2017 ( HH: Fig.-13: The Household already handed over land in August 2017, Branch A- A4 and other house now already relocated in July 2017 Fig.-14: Household is obstructing relocation in April 2017 Branch A, A4, Nguyen Van Tao street, while in June 2017 this house already completed relocation (Before & After) IX. RE-ESTABLISHMENT OF AHHs SETTLEMENTS AND BUSINESS ENTERPRISES; 47. Basic principles in guidelines under SPS-2009 of ADB is to avoid involuntary resettlement wherever possible and or to minimize involuntary resettlement by exploring project and design alternatives; to enhance, or at least restore, the livelihoods of all displaced persons in real terms relative to pre-project levels; and to improve the standards of living of the displaced poor and other vulnerable groups. The involuntary resettlement safeguards covers physical displacement (relocation, loss of residential land, or loss of shelter) and economic displacement (loss of land, assets, access to assets, income sources, or means of livelihoods) as a result of involuntary acquisition of land and properties. 48. Harmonized with the basic principles of ADB Policy on compensation, assistance and resettlement, Vietnam Government, in agreement with ADB, has adopted a specific Resettlement Framework for the BLLT Expressway project, which could minimize involuntary resettlement, enhance, or at least restore, the livelihoods of all displaced persons in real terms relative to preproject levels. Page 24

29 49. The several RPs, prepared for this project, establishes the provisions for payment of resettlement assistance to AHs, CBEs and income restoration assistance to the poor and vulnerable households and provides the budget and cost estimate for implementation. 50. The agencies, involved in RP implementation, maintained continuous efforts to achieve the desired result on timely execution of resettlement and IRP activities. In the process, the agency/ authority have initiated following activities to make sure effective implementation of resettlement and restoration of livelihood: Consulting project affected people viable solutions for resettlement and livelihood restoration; Providing affected people options of resettlement and livelihood restoration; Compensating entire replacement cost for damages and loss; Selecting sites for resettlement, which could provide minimum benefits and services similar to their existing place ; Providing finance for assistance, training and income support to help them go well during the transitional period; Recognizing vulnerable groups and providing special support for these groups; and Establishing a structure on institution and organization to assist this process to finally succeed. 51. In order to conduct objective implementation of the RP and minimize the adverse social impacts a periodic evaluation will be carried out. This evaluation will involve identifying the gaps between the implementation of the RP and the mitigation measures proposed in the RP. Any gaps thus identified will be discussed in consultation with the EPMU officials and the local administration as necessary and corrective actions executed. These corrective actions will be examined and then implemented in a timely manner. Other than that the evaluation criteria will examine resettlement status and the quality of life with respect to the income levels of the persons or families losing livelihood and business structures, if any. There will be a direct comparison of the income level preproject period and post project implementation stage. If there have been any families that are impoverished due to the project development, measures will be suggested to address the same. 52. To evaluate the status on re-establishment of AHHs settlements and business enterprises, an evaluation of resettlement/relocation and implementation of IRP activities will be required, which has not initiated as up till now. 53. Based on the assessment during monitoring on re-establishment of AHHs settlement and business enterprises, the following results have been witnessed: There are 502 eligible HHs in Tranche-1 (ADB section I), who needs relocation. Out of which 499 HHs opted for self-relocation, while only 3 HHs opted for relocating at resettlement site. The resettlement site was identified by the authority which is now almost completed (near 90 %) and ready for relocation. Out of 873 HHs, 269 HHs received the IRP inputs (96 HHs Ben Luc District, 76- Can Giuoc District, and 92 Can Gio district). The evaluation of IRP implementation has been completed in Can Gio district only. Page 25

30 54. The details of status on re-establishment of settlement and business enterprises for eligible HHs are well explained in relevant sections; section-xi on Relocation & Transfer and section-xii of Income Restoration program (IRP) implementation respectively X. GRIEVANCES AND REDRESSAL 10.1 Grievances Received and Redressed 55. The nature of grievances and its redressal requirement are diverse, which need corrective action at different levels and by different institutions. Most of the grievances, specified below, are concern with the inadequacy of compensation and rate and disputes among HHs. The nature of the grievances received and redressed up till Sept are summarized in the table below: Table 14. No. of Grievances Received and Resolved No Districts Nature of Grievances Grievances Received Up till Sept.2017 Remarks Up till June 2017 Up till Sept 2017 Redressed Remaining Ben Luc Internal Family Dispute Family dispute. (HH: Nguyen Viet Cuong) Court decision have come in August Binh Chanh Disagree on compensation amount Meeting of District compensation committee with DPs is in progress Disagreement with Family member on share of compensation Waiting for court decision Pending Court cases on compensation Waiting for court decision already signed compensation, not yet receieved compensation, which was put in tresury some HHs already received compensation after dialogue and concensus 2 Can Giuoc No Grievances 3 Nha Be Disputing on rate of compensation, not yet receive Compensation Only 1 HH in A4 is obstructing relocation because of permit/ license of new house construction. (Section-8, sub section 8.1, para -35 (10) Can Gio Total Nhon Trach already received compensation, but not yet handed over land Pending complaints of land valuation as per ocation of HHs are collecting crop after just received compensation District PC have submitted to Province DoNRE to re check and Page 26

31 recovered land plot decide 2 Long Thanh already received compensation, but not yet handing over land HHs are collecting crop after just received compensation Total XI. RELOCATION AND TRANSFER 11.1 Resettlement Preferences of Eligible Affected Households 56. There are significant changes in the number of eligible HHs, who opted for relocating at resettlement site as part of resettlement preferences from previous reporting period. In ADB section I and JICA section II, only 3 HHs have opted for relocation at resettlement sites in the reporting period June 2017, while it is now 44 HHs, opted for relocation site, especially in Binh Chanh district where 42 HHs opted for relocation site. Remaining 458 HHs, selected for self-relocation. In westrn section 273 HHs have opted for resettlement sites in two districts; i.e., Nhan Trach and Long Thanh Households (1 in Binh Chanh District: HH: ([This information has been removed as it falls within exceptions to disclosure specified in paragraph 97, (exception (x) Information that, if disclosed, would or would be likely to endanger the life, health, safety, or security of any individual, or safety or security of ADB assets, or to prejudice the defense or national security of a member) and 1 HH in Nha Be District: HH: ([This information has been removed as it falls within exceptions to disclosure specified in paragraph 97, (exception (x) Information that, if disclosed, would or would be likely to endanger the life, health, safety, or security of any individual, or safety or security of ADB assets, or to prejudice the defense or national security of a member)), who have opted for Resettlement sites have already received land plot in Resettlement site. Another 1 household, namely: ([This information has been removed as it falls within exceptions to disclosure specified in paragraph 97, (exception (x) Information that, if disclosed, would or would be likely to endanger the life, health, safety, or security of any individual, or safety or security of ADB assets, or to prejudice the defense or national security of a member) of Vulnerable group (disabled), in Can Giuoc District have petitioned to receive a plot in Hai Son resettlement site, which was latter approved by Can Giuoc District people s committee and CoLFD and he has already received the plot in Hai Son Resettlement site in December It is pertinent to mention here that the families belonging to women heded (WHFs), land less, poor, elderly, disable and specified under policy are considered as vulnerable. The details are given in Table- 15. Sl. No Location Table 15. Resettlement Preferences of Fully Affected Households. Fully Affected (HHs) Required to Relocate Opting relocation at Resettlement Sites (RSs) Opting for Self Relocation (HHs) (HHs) (HHs) 1 Ben Luc Can Giuoc Binh Chanh Nha Be Can Gio Nhon Trach Long Thanh Total *Resource: Report of CoLFD and DCC in each District to Sept, 2017 Page 27

32 11.2 Status of Resettlement Site development 58. The identified and specified resettlement site was almost ready to move. Now, while the specified resettlement sites are almost completed (near 90 %), almost all the relocating family have opted for self-relocation. 59. Ho Chi Minh City and Dong Nai Province are developing more new urban areas and industrial zones and which may need more resettlement sites. To meet the challenges and demand, the authority is setting up new resettlement sites for local people, workers and to reduce the population density from central area into suburban. In 2 suburb districts, Binh Chanh and Nhà Be, more resettlement sites are being developed to meet the resettlement demands. The same resettlement sites will be available for the affected persons of Ben Luc- Long Thanh expressway project. 60. The status of development of Resettlement Sites and relocation status of affected households are described in the Table -16: Table 16. Status of Resettlement Site Development up till Sept No Name of Resettlement Site Approximate progress of infrastructure development Approximate progress of facility development Remarks Amenities Status Facilities Status 1 An Ha RS(Le Minh Xuan, Binh Chanh, HCMC) Electricity Done Plot in Resettlement site for AHHs Enough number of plots as required. Water Done Facility: Health Available nearby Road Done Facility: Education Available nearby Other Done Facility: Market Available nearby 1 AH Mr. ([This information has been removed as it falls within exceptions to disclosure specified in paragraph 97, (exception (x) Information that, if disclosed, would or would be likely to endanger the life, health, safety, or security of any individual, or safety or security of ADB assets, or to prejudice the defense or national security of a member) Hieu received plot in Resettlement Site (RS). Built new house. The rest of AHHs received resettlement money. 2 Nhon Duc RS Nhon Duc com., Nha Be dis., HCMC) Electricity Done Plot in Resettlement site for AHHs Enough number of plots as required. Water Done Facility: Health Available nearby 1 AH Mr. ([This information has been removed as it falls within exceptions to disclosure specified in paragraph 97, (exception (x) Information that, Page 28

33 No Name of Resettlement Site Approximate progress of infrastructure development Approximate progress of facility development Remarks Amenities Status Facilities Status Road Done Facility: Education Available nearby Other Done Facility: Market Available nearby if disclosed, would or would be likely to endanger the life, health, safety, or security of any individual, or safety or security of ADB assets, or to prejudice the defense or national security of a member) received plot in Resettlement Site (RS). Built new house. The rest of AHHs received resettlement money. 3 Go Dau RS(Can Gio District, HCMC) Electricity Done Plot in Resettlement site for AHHs Enough number of plots as required. Water Done Facility: Health Available nearby Road Done Facility: Education Available nearby No HH opts to resettle in this resettlement site. Other Done Facility: Market Available nearby 4 Tan Kim RS(Can Giuoc District, Long An Province) Electricity Done Plot in Resettlement site for AHHs Enough number of plots as required. Water Done Facility: Health Available nearby Road Done Facility: Education Available nearby No HH opts to resettle in this resettlement site. Other Done Facility: Market Available nearby 5 Hai Son resettlement site (in Long Thuong Commune, Can Giuoc District Electricity Done Plot in Resettlement site for AHHs Enough number of plots as required. This resettlement site is not serviced for the project. It is Resettlement Site (RS) for business but project bought a plot for HH: Huynh thi Thanh Tuyen 5 Nhon Trach 4 Long Thanh Water Done Facility: Health Available nearby Road Done Facility: Education Available nearby Other Done Facility: Market Available nearby Plot of land 167 plot Plot of land 167 plot Over 5 plot of land Not yet identify at this time Tan Hiep Commune resettlement site (total of Page 29

34 No Name of Resettlement Site Approximate progress of infrastructure development Approximate progress of facility development Remarks Amenities Status Facilities Status Electricity Done Plot in Resettlement site for AHHs Enough number of plots as required. Water Done Facility: Health Available nearby designed plot land is 167 plots, request to be resettlement of 162 plots, over 5 plot of land ) Road Done Facility: Education Available nearby Other Done Facility: Market Available nearby * Resource: Report of CoLFD and DCC in each District up till Sept Obstruction in Relocation 61. In Nha Be District 99% of HHs have handed over the land for project, only 1 HH in A4 pkg. are obstructing relocation, even after receiving the compensation. The detail of impediments in relocation from the construction site is outlined in the Table below: Table 17. Obstruction in Relocation Package A1 Package A2-1 Package A2-2 Package A 4 Binh Chanh District Nha Be Total No Contents Binh Chanh Hung Long Hung Long Da Phuoc Long Thuong 1 HHs already received compensation but not yet relocated HHs are constructing new house 1.2 Waiting Permit/ license to be constructed on remaining land part Applied for construction of new house on agricultural land and is not as per plan (As per Act in Vietnam, no permission is granted to construct a house on agricultural land) Total HHs of two Districts; Nhon Trach and Long Thanh of Dong Nai Province will be relocated after land acquisition will be completed as all 273 HHs have opted for relocation on Resettlement sites, set up in the district 63. During monitoring of obstruction in relocation at construction sites by social Team at the end of Aug-Sept. 2017; it was witnessed that in package A1, 4HHs, are not able to be relocated due Page 30

35 to non-issuance of permit/license of new house construction. Out of these 4 HHs, 3 households, namely: ([This information has been removed as it falls within exceptions to disclosure specified in paragraph 97, (exception (x) Information that, if disclosed, would or would be likely to endanger the life, health, safety, or security of any individual, or safety or security of ADB assets, or to prejudice the defense or national security of a member) are creating hindrance in construction of main road. Not only this due to continued rain, these households are facing acute problem in living there. Therefore, it has been proposed by the implementing agency to Binh Chanh District PC to resolve the issue soon to avoid delay in construction and damage and hazards to HHs. 64. To resolve above issues on building permit / license for constructing new house. People's committee of Ho Chi Minh City issued a Notification No 725/TB-VP dated 19/9/2016: for affected households, whose land are acquired by the project and have requested to change land use purpose on remaining land area part or bought new land plot to construct a new house on remaining land. In the light of the above notification the People s Committee of Districts: Binh Chanh, Nha Be, and Can Gio will review the request on change of land use purposal and will approve construction of new houses on remaining land or other new land plot for construction of house. See Annex.- 3: Notification No Currently. Binh Chanh District People s committee is agreed to permit the Households, to construct a new house on remaining land /part of the land. Page 31

36 Figure 1.Layout of Project

37

38 Figure 2. General Location of Project in transport system of Ho Chi Minh City and Surrounding

39 Figure 3. Package A1: Status of Project Location updated to February 24, 2016 on Aerial Photograph Figure 4. Package A2-1: Status of Project Location updated to January 23, 2017 on Aerial Photograph

40 Page 30

41 Figure 5. Package A2-2: Status of Project Location updated to January 23, 2017 on Aerial Photograph Figure 6. Package A3: Status of Project Location updated to January 23, 2017 on Aerial Photograph Page 31

42 Page 32

43 Figure 7. Package A4: Status of Project Location updated to January 23, 2017 on Aerial Photograph Page 33

44 Figure 8. Package J1, J2, J3: Status on Location updated January 23, 2017 on Aerial Photograph Page 34

45 Figure 9. Package A5, A6, A7-ADB Section III- Status of Project Location (Being implemented Land Acquisition and Ground Clearance, updated March 10, 2017) Page 35

46 XII. INCOME RESTORATION PROGRAM (IRP) IMPLEMENTATION 12.1 Final list of HHs participated in the income restoration program (IRP) 66. Up till Sept. 2017, the final list of eligible HHs in Tranche-1, who participated in IRP, is 873, an increase in 32 from 845 of the first survey list. It includes 102 HHs in Ben Luc, 135 HHs in Can Giuoc, 407 HHs in Binh Chanh, 137 HHs in Nha Be and 92 HHs in Can Gio district respectively. The IRP activities has not beem initiated yet in Tranche-2 part of the project 67. The changes in the number of IRP participants are attributed to change in their perception during implementation. In first instance, the eligible Households could not visualize the benefits of IRP. Eventually they decided to participate in IRP, when they saw other HHs have started deriving income from IRP. The final list of Eligible households in Tanche-1 is delineated in Table 18. Table 18. Final Households list to Participate in IRP (Tranche-1) 1 No Commune Long An province No of HHs Total Cultivation Component Livestock & farming component Income Activities selected by HHs Handicraft and other Vocational training and job Trade and service promotion component M F T M F Total M F Total M F Total M F Total M F Total Ben Luc district My yen commune Tan Buu commune Can Giuoc district* Phuoc Ly commune LongThuong commune Ho Chi Minh city Binh Chanh district Binh chanh commune Tan Quy Tan commue Hung Long commune Da Phuoc Nha Be district Long Thới Nhon Duc commune Can Gio district Binh Khanh Total Resource: Report of CoLFD and DCC in each District, Sept 2017 *Can Giuoc 135 households in Can Giouc includes76 HHs approved first and 59 HHs submitted for approval in second list. 1 The number of vulnerable HHs is already included in the list, except for Binh Chanh, as data on this is not yet available

47 12.2 Vulnerable Group and their Participation in IRP 68. With reference to the MOU of ADB mission in March 2016 to identify the HHs of vulnerable group, the Conultant and the EPMU have worked with CoLFD in each District of the project from March to June The identification of vulnerable groups at Commune level was obligatory, with the objective to invite them to participate in the IRP. EPMU and the Consultant, with the exception of Binh Chanh District (where the information is still is unavailable), were able to identify and listing of vulnerable population. 69. Moreover, by the end of Sept 2017, information on the vulnerable households in Binh Chanh District is still not yet available even after a letter (No 27/BLLT-QLTCMB) issued by EPMU on 09 January 2017, to CoLFD Binh Chanh in order to speed up collection of this information for the IRP (see Annex. 6), but the information was unavailable at the time of preparation of this report. The local authority argued that as of now they are focusing on resolving obstructions in 3 Communes: Binh Chanh commune for HHs on two sides of HW 1A; Hung Long and Da Phuoc of Grievance, disputing and complaints of compensation price, hence, no time to identify the information of vulnerable group. 70. Most of the vulnerable households were invited to participate in IRP implementation and select income restoration activities. 71. Additionally, in two Districts; Long Thanh and Nhon Trach of Dong Nai Province, land acquisition is at slow pace, hence, the list of vulnerable group has not been prepared by the CoLFD 72. The number of vulnerable households, with name and address in each district, is summarized in Table-19 and annexed as Annex.- 6 of this quarter No 3 report of 2017 No Địa Phương Total Table 19. Vulnerable Group Participation in IRP Vulnerable Group Updated up till Sept 2017 WHF Landless Poor Eldelry Disable Policy A Long An Province Ben Luc District My Yen commune Tan Buu commune 0 No vulnerable Household 2 Can Giuoc district Phuoc Ly Commune Long Thuong commune 2 2 B Ho Chi Minh City Binh Chanh ( waiting) Binh Chanh commune Tan Quy Tay commune Hung Long commune Da Phuoc commune 2 Nha Be District Nhon Duc Commune Page 37

48 No Địa Phương Total Vulnerable Group WHF Landless Poor Eldelry Disable Policy Long Thoi commune Can Gio District C BInh Khanh Commune Dong Nai Province 1 Nhon Trach District Phuoc Khanh commune Vinh Thanh Commune Phươc An commune 2 Long Thanh District Long Phuoc Commune No vulnerable Household Phuoc Thai Commune Tổng *Resource: Districts committee of IRP implementation 12.3 Status on IRP Implementation 73. The updated information up till Sept 2017 ensures that out of 873 HHs, who have participated in IRP, 264 HHs have received the input. The handing over of input is made to 96 HHs in Ben Luc district, 76 HHs in Can Giuoc district, and 92 HHs in Can Gio district respectively. 74. IRP implementation is being carried out in each district, except Nhon Trach and Long Thanh districts up till Sept The status on Handing over of input has been made in Can Giuoc, Ben Luc and Can Gio Distrcit only, detailed in Annex.-7. Can Gio district have achieved 100% target in handing over input to eligible HHs. 75. As described above that currently, implementation of IRP in Long Thanh district is not initiated as of now due to non accomplismnet of organization by District PC to implement the IRP, as communicated to Resettlement Specialist of PSC by ([This information has been removed as it falls within exceptions to disclosure specified in paragraph 97, (exception (x) Information that, if disclosed, would or would be likely to endanger the life, health, safety, or security of any individual, or safety or security of ADB assets, or to prejudice the defense or national security of a member) of Farmers union, one of the stakeholders in IRP implementation. 76. ([This information has been removed as it falls within exceptions to disclosure specified in paragraph 97, (exception (x) Information that, if disclosed, would or would be likely to endanger the life, health, safety, or security of any individual, or safety or security of ADB assets, or to prejudice the defense or national security of a member) also suggested us to contact ([This information has been removed as it falls within exceptions to disclosure specified in paragraph 97, (exception (x) Information that, if disclosed, would or would be likely to endanger the life, health, safety, or security of any individual, or safety or security of ADB assets, or to prejudice the defense or national security of a member) of District People's Committee in this regard. Accordigly, Mr. Duc was contacted by the Resettlement Specialist of PSC, who communicated that presently the district PC is concentrating on the airport project. If we urgently in need of carrying out IRP, EPMU should send a letter to district PC for IRP implementation. In response, the District People's Committee will organize a meeting and specific assignment to agencies of The District to carry out IRP. The Resettlement Specialist of PSC will support and supervise this implementation of IRP. 77. A draft letter of this request was prepared by the Resettlement Specilaist of PSC and sent it to EPMU for finalization and further issue it to District PC. The Page 38

49 Resettlement Specilaist of PSC will follow up this communication and will contact Mr. Duc and or Mr.Thanh for progress on IRP implementation. 78. The summary of status on handing over of IRP input is briefed here in Table 20: Table 20. Status on IRP implementation No A Commune Long An province Ben Luc district My yen commune Eligible HHs Status on IRP Implementation up till June 2017 Received Input of IRP Not Received M F Total M F M F Progress % Remarks It is 102 HHs, who were registered to participate in IRP implementation in Ben Luc District. 06 HHs did not participate IRP when it was carried out. Oout of 96 HHs, who participated in IRP, 94 HHs haave already received input of IRP up till May Remaining 2HHs did not recieve input of IRP with reasons that they themselves have bought the Cow and having no red bill, a certification of prevention of disease, which is mandatory to receive the reimbursement. Board of IRP implementation management of Ben Luc District is now contacting and discussing with these 2 HHs comlete the formalities. The name and address of these 2 HHs are as follows: ([This information has been removed as it falls within exceptions to disclosure specified in paragraph 97, (exception (x) Information that, if disclosed, would or would be likely to endanger the life, health, safety, or security of any individual, or safety or security of ADB assets, or to prejudice the defense or national security of a member) DoLISA issued a Plan, No 1250/SLDTBXH-KH, dated 23 June 2017 for monitoring and Evaluation of IRP implementation in Long An provinve of Ben Luc- Long Thanh Expressway project. The monitoring will be done in Page 39

50 No B Commune Tan Buu commune Can Giuoc district Phuoc Ly commune LongThuong commune Ho Chi Minh city Binh Chanh district Binh chanh commune Tan Quy Tan commue Hung Long Eligible HHs Status on IRP Implementation up till June 2017 Received Input of IRP Not Received M F Total M F M F Progress % Remarks this section for which necessary monitoring formats have been provided to monitoring team. DoLISA issued a letter No 1027/SLDTBXH-BTXH dated 24 May 2017 for request of budget to carry out IRP implementation at province Long An Province people's committee are reviewing to approve additional list of IRP household list (in addition: 59 new household into IRP Household list (added second ) and submitted letter to EPMU to have budget and waiting for disbursement DoLISA issued Plan No 1250/SLDTBXH-KH dated 23 June 2017 for monitoring and Evaluation of IRP implementation in Long An provinve of Ben Luc- Long Thanh Expressway project, Section passes Long An Province and detailed contents for the monitoring and evaluation for 76 HHs, who already recieved Input of IRP Completion of final household list, who will participate in IRP and was submitted to Binh Chanh District people s committee for approval Will carry out process of disbursement for IRP implementation According to plan, after August 2017, IRP implementation at Binh Chanh District will begin Currently, Binh Chanh do not start IRP implementation because they are oncentrating land acquisition in The District Da Phuoc Page 40

51 No Commune Nha Be district Long Thoi commune Nhon Duc Commune Eligible HHs Status on IRP Implementation up till June 2017 Received Input of IRP Not Received M F Total M F M F Progress % Remarks Nhà Bè district have completed the procedure for IRP implementation at the district level Currently.Nha Be District is waiting for disbursement for providing IRP input Can Gio A completion report of implementation of the IRP in Can Gio District has already Binh Khanh commune been submitted immediately after submission of Quarter No 2/2017 c Total Dong Nai province Nhon Trach District Long Thanh district HHs list is being prepared in each district, based on decision of land acquisition District peoples committee has started identifying list of affected households, who are entitled to participate in IRP activities. EPMU and Consultant have met and worked with local authorities (Nhon Trach and Long Thanh) in June 2017 to guide them how and what to collect the required document inclduing address and telephone number so that they could be contacted during preparing of IRP implementation in each District 79. For successful implementation of income generation programme, it is essential to provide proper training to IRP participating households on how to initiate and take best return from the income models; they selected as part of their income generation activites. 80. The key issues of such type of training is to have specific knowledge of the selected income activites and skill development of the participating households, through which, they can improve their abilities to manage and run the selected trade, occupation or service. Such type of training gives ample exposure and experience to run the ideal model successfully to generate income. This training helps the participating households to understand the positive and negative perspective of various income activities. 81. The working groups, involved in IRP Implementation activities, prepared a detailed plan to organize training camp/ workshop for eligible HHs under IRP. They prepared a proper plan, Page 41

52 equipped with relevant materials and tools, for imparting the training to the participant HHs including technical requirements, human resources and operating costs for each income activity 82. In keeping with the above objectives and to make compliance of MOU of ADB review missions in March and October 2016, the training for IRP participating households was organized. 83. The proposed IRP workshops or training program was organized at commune level and was meant to help and advice to each participant to make their choices of income activity based on their education and skills and how to carry out the specified income activity and contact the relevant persons or institutions, in case they require any advice and technical inputs to run their business. The training program were organized as per following program: Table 21. Provision of Training to IRP Participating Households Sl. No. District Date of Training Type of Training Reference 1 Can Giouc 23 Fer /3/ June Ben Luc 24 march 2016 and 29march 2016 at My Yen 3 Binh Chanh Not yet carried out 4 Can Gio Organized 3 time according to income activity group: -16/3/2015 1/4/2015 IRP implementation board/working Group organized training program/ workshop for eligible HHs on IRP activites: Can Giuoc District PC through a Notification No 34 dated 23 Fer 2015 for tarining to each HH to guide HHs how to carry out IRP in any time 13/3/2015 at Long Thuong (afternoon) and Phuoc Ly ( morning) Notification letter No 16/TB BQL dated 1 June : training to each HH (agricultural activities; small business, vocational training activities and Number of cellphone Organized Training Program/ workshop on IRP for HHs on income activities of fields like: agriculture, small business and service, vocation training: HHs were also given the details of local staff is in charge of type of income activity: name and information of them including handphone number Organized Training Program/ workshop on how to implement IRP activities for eligible HHs on specified income activities: 16/3/2015: raising fish, pig, and shrimp(for HHs participated) Loan 2730-vie: GMS Ben Luc Long Thanh Expressway Project, Midterm Review Mission 1. Memorandum of Understanding (draft) 29 February 7 March Memorandum of Understanding (draft) October 2016 Page 42

53 Sl. No. District Date of Training Type of Training Reference 26/4/ Nha Be Not yet carried out 1/4/2015: handicraft (HHs participated) 26/4/2015: HHs participated small business and service 6 Nhon Track Not yet carried out 7 Long Than Not yet carried out 84. Handing over of IRP input in Can Giuoc and Ben Luc district in Aug-Sept 2017 have been shown in the figures below: (Fig.1-8). Fig-1: Discussing with cards of DoLISA of Long Anh Province and Can Giuoc district and My yen Commune before conducting monitoring and evaluating IRP at commune- 16 August 2017 Fig-2: Delegation go to Surveying and Interviewing to Household, the HH is raising cow ( 16 August 2017) Fig-3: Local staff is interviewing household of proccesing IRP implementation ( 16 August 2017) Fig-4: Raising Bird in a HHs in Tan Buu commune, Can giuoc District, Long An province of IRP Page 43

54 Fig-5: Local staff is interviewing a households of IRP after received cow at Tan Bưu commune, Can giuoc District, Long an province in Agust 2017 Fig-6: Duck is be raising by HH in IRP at My Yen commune, Ben Luc District, Long An province Fig-7: Meeting to deploy IRP implementation at Long Thanh District, Dong nai Province dated 1 Sep 2017 Fig-8: Meeting to carry out IRP at Long Thanh District, Dong nai Province dated 1 Sep Status on Schedule of IRP Implemetation: 85. The implementation plan of Income Restoration is part of the RP, which aims to specify the directions, strategies and objectives set out in the Resettlement Plan, the ADB and the Government of Vietnam. 86. The implementation plan for the income restoration program activities are generally designed in 2 years (24 months); from date of commencement of the implementation of the project. Keeping in mind, the implementation plan schedule of IRP was made and updated from time to time to match the project progress in each commune. 87. However, due to various reasons, there are delays in implementation schedule of original plan, attributed to various reasons; i.e., due to Ignorance of procedures to be established by local officials, the minimum level of capacity of working group, who were first time for IRP implementation, Delay in procedures to set up Committee of IRP implementation management at District, delay in issuance of decision at different levels of IRP committee, delay in availability of budget to carry out IRP implementation (for local staffs and impelmentation), absence and Page 44

55 traceabilty of HHs in IRP participation meeting and unavailability of selected inputs models of IRP in local market etc. 88. The execution of different activities and implementing time, specified in implementation schedule has been assessed and outlined in Annex.-8 for ready reference. This assessement has tried to understand the completion date of IRP activities, the lagging behind of IRP activities from original proposed schedule and the proposed plan of IRP implementation committees to comlete the IRP activites Evaluation of IRP Implementation in Can Gio District 89. Though the handing over of IRP input has been initiated or completed in three district; Ben Luc, Can Giuoc and Can Gio, however, evaluation of IRP implementation could be carried out in Can Gio district only. 90. The handing over of input in Ben Luc and Can Giuoc district has been done very recently and is not matured enough to go for evaluation work, while the input provided in Can Gio district has started getting return. 91. IRP implementation committee in Can Giuoc district has communicated that 76 HHs, who have received the IRP input before march 2017, the evaluation of those HHs has been initiated in the month of August Can Gio District have already carried out 3 time of checking, monitoring and evaluating on IRP implementation and report is being prepared on monitoring and evaluation 93. Total 39 households in Can Gio District have participated in the income restoration activities of raising livestock and farming in which raising Shrimp is carried out by most of the households, which produces good earnings despite the risk and cost. 94. Out of 39 AHHs, who were monitored and evaluated, it was found that 16 AHHs, did not earn any income from raising shrimp during the harvesting due to reasons (affected by sea salt water entered the ponds, drought, price of shrimp on the market was low, price of food to raise shrimp is increasing high, while other shrimp ponds caused diseases. 95. In 2 cases of HHs (([This information has been removed as it falls within exceptions to disclosure specified in paragraph 97, (exception (x) Information that, if disclosed, would or would be likely to endanger the life, health, safety, or security of any individual, or safety or security of ADB assets, or to prejudice the defense or national security of a member)), infectious disease were identified in pig rearing and African Carp fish raising, during IRP Monitoring and evaluation 96. The completion report on IRP implementation of Can Gio district has already been submitted in the month of Sept Completion Evaluation Report on IRP implementation in Can Gio District 97. A summary completion Report on Evaluation of IRP implementationt of Can Gio District prrpared and submitted after comleting the IMR report of 2nd Quarter 2017 XIII. PREPARATION OF RESETTLEMENT PLAN (RP) ADDENDUM : 98. As per requirement in MOU in March 2016, the Resettlement Plan Addendum for internal road T14 have been revised and updated, incorporating the comments of ADB, and was submitted to EPMU in May 2017 Page 45

56 99. Resettlement Plan (RP) addendum for electricity Pole removal, as required by MOU of ADB, May 2017, is prepared for Ben Luc District only and was submitted to EPMU in June However, the RP addendum of other districts is pending due to following reasons: Binh Chanh District: additional Compensation plan for relocating Power lines in The District was prepared and submitted to department of finance of Ho Chi Minh City but pending, they do not approve with reason: MOT s approval on assessment of compensation price is not clear. Currently this submission is pending at Department of Finance of Ho Chi Minh City and EPMU is working with them on this issue. Nha Be District: CoLFD is preparing and identifying recovered land area for issuing decision of land acquisition, therefore, Compensation plan is not yet prepared up till now. Nhon Trach District: CoLFD is carrying out land acquisition for project and not yet started process for preparing Compensation Plan for relocating Power lines. Page 46

57 APPENDIX Page 47

58 Annex 1: Status on Handing over of land and Ground Clearance (ADB Section) No. Name of the tender package Province / district Chainage Km Phạm vi GPMB Total Length (M) Land Area (ha) Total budget (million VND) Paid (in VND million) Tình hình GPMB Total paid (ha) Handover rate (%) Total number of Households Number of households handed over Content of problems (1) (2) (3) (4) (5) (6) (7) (8) (9) (10) I Package A1 Halla _ Vinaconex Km0+000 Km , H.Bến Lức Km0+000 Km , , , , , % % Super Court of Ho Chi Minh City have issued Document No 24/HTHA-DS dated 30 /8/2017: requirement of postponed execution of the sentence. The household have temporary haned over land to project to drill and conduct iron frame part for piers in August and Sepmtember 2017 afterward they re-paled Continue dialogy and mobilization to hand over land H.Cần Giuộc 2, , , % Finished End of September of 2017.Local authority have mobilized 03 HHs on main line to hand over land in 17 October 2017 H.Bình Chánh 3, , , % Currently, remaining 15 HHs are 2 sides of HW 1a have not handed over land with reason is low rate of compensation Local authority is contacting toeach HH to mobilize handver of land II Package A2-1 Kuddong - TC Km7+900 Km , , , % H.Bình Chánh Km7+900 Km , , , % Current. Remaining 4 households are disputing and local authority is waiting the court s decision to resolve H.Cần Giuộc Km8+120 Km , , , % Finished

59 No. Name of the tender package Province / district Chainage Km Phạm vi GPMB Total Length (M) Land Area (ha) Total budget (million VND) Paid (in VND million) Tình hình GPMB Total paid (ha) Handover rate (%) Total number of Households Number of households handed over Content of problems III Package A2-2 Bình Chánh Km Km , , , % Currently. Remaining 58 HHs are not yet handing over land, however wich of 11 households have commited that they will hand over land in October 2017 IV V Package A3 Package A4 Xã Hưng Long Km Km , % Xã Đa Phước Km Km , % Halla _ Vinaconex Km Km , , , % Finished H.Bình Chánh Km Km ,965 19, % 5 5 Finished H.Nhà Bè Km K m , , , % Finished H.Nhà Bè Km Km , , , % Remaining 1 Household is not yet handed over land because problem of resettlement on bough agricultural land Local authority is dialogy and mobilization to hand over land in next October 2017 VI Package J1 Km Km , , , % Finished 1 H.Nhà Bè Km Km , , , % H.Cần Giờ Km Km ,480 14, % VII Package J2 H.Cần Giờ Km Km , ,257 91, % Finished IIX Package J3 Km Km , ,004 43, % IX Package A5 H.Cần Giờ Km Km , ,044 19, % Finished H.Nhơn Trạch Km Km , ,960 24, % Entangled 1 dispute disputes The court has trial, Dong Nai People's Committee is adjusting the compensation decision and negotiating for construction H.Nhơn Trạch Km Km , ,935 63, % Paying now of compensation xã Phước Khánh ,170 29, Handed over Page 49

60 No. Name of the tender package Province / district Chainage Km Phạm vi GPMB Total Length (M) Land Area (ha) Total budget (million VND) Paid (in VND million) Tình hình GPMB Total paid (ha) Handover rate (%) Total number of Households Number of households handed over Content of problems Xã Vĩnh Thanh ,765 34, There are 6 households with 0.8 hectares of land have not received about 2.5 billion due to complaints about land positions. The district submitted a report to the Department of Natural Resources and Environment, DOLISA to send a notice to the commune requesting the farmers to collect new crops, structures and hand over the land. X Package A6 H.Nhơn Trạch Km Km , , , % Handed over land 272 households with 29.5 ha in Vinh Thanh commune Xã Vĩnh Thanh ,280 79, There are 28 households with area of 4.72 ha have not received money about 6.6 billion due to complaining land location. The district submitted a report to the Department of Natural Resources and Environment, DOLISA to send a notice to the commune requesting the farmers to collect new crops, structures and hand over the land. Xã Phước An ,021 52, On 5 October 2017, Handed over 365 households equivalent to 60.8 ha in Vinh Thanh Commune. Remaining 78 HHs is not yet recieved compensation XI Package A7 Km Km , ,609 47, % H.Nhơn Trạch Km Km , Xã Phước An ,180 1 H.Long Thành Km Km , ,429 47, From April 25, 2017 up to now, 170 households have been paid about 64 billion or 8.2 ha. On 2/8/2017 local authorities invited to hand over 2.3 hectares ( equivation : 29 HHs) Xã Long Phước ,323 2, One Long Thanh protection forest organization was handed over and 3 households were handed over Page 50

61 No. Name of the tender package Province / district Chainage Km Phạm vi GPMB Total Length (M) Land Area (ha) Total budget (million VND) Paid (in VND million) Tình hình GPMB Total paid (ha) Handover rate (%) Total number of Households Number of households handed over Content of problems Xã Phước Thái ,106 45, Handed over a Long Thanh protective forest organization and 29 Households Total 57, ,552,761 3,131, % 3,558 2,759 Page 51

62 Annex 2: Critical Locations need urgent Ground Clearance and Handing Over ([This information has been removed as it falls within exceptions to disclosure specified in paragraph 97, (exception (x) Information that, if disclosed, would or would be likely to endanger the life, health, safety, or security of any individual, or safety or security of ADB assets, or to prejudice the defense or national security of a member)

63 Annex 3: Notification of HCMC People s committee (PC) on license to construct New House (A resolution of obstruction in ground clearance of BLLT project) Page 53

64 HO CHI MINH CITY PEOPLE S COMMITTEE Office of Ho Chi Minh city PC SOCIALIST REPUBLIC OF VIỆT NAM Independent freedom happiness

VIE: GMS Ben Luc Long Thanh Expressway Project

VIE: GMS Ben Luc Long Thanh Expressway Project Internal Monitoring Report Quarterly Report October-December 2015 VIE: GMS Ben Luc Long Thanh Expressway Project Prepared by Dasan Consultants Co. Ltd., in joint venture with Kunhwa Engineering & Consulting

More information

VIE: GMS Ben Luc - Long Thanh Expressway

VIE: GMS Ben Luc - Long Thanh Expressway Social Monitoring Report Inception Report May 2013 VIE: GMS Ben Luc - Long Thanh Expressway Prepared by Thanglong Infrastructure Development for Vietnam Expressway Corporation and the Asian Development

More information

VIE: GMS Ben Luc - Long Thanh Expressway Project

VIE: GMS Ben Luc - Long Thanh Expressway Project Updated Resettlement Plan Can Giuoc district province November 2013 VIE: GMS Ben Luc - Long Thanh Expressway Project Prepared by the Vietnam Expresssway Corporation for the Asian Development Bank. This

More information

VIE: Ha Noi and Ho Chi Minh City Power Grid Development Sector Project

VIE: Ha Noi and Ho Chi Minh City Power Grid Development Sector Project RESETTLEMENT DUE DILIGENCE REPORT Project Number: 46391-001 January 2018 VIE: Ha Noi and Ho Chi Minh City Power Grid Development Sector Project Prepared by Ho Chi Minh City Power Corporation, Electricity

More information

VIE: Central Mekong Delta Region Connectivity Project

VIE: Central Mekong Delta Region Connectivity Project Social Monitoring Report Quarterly Report No. 3 April 2014 VIE: Central Mekong Delta Region Connectivity Project Prepared by Joint Venture: CDM Smith, Inc., WSP Finland Limited & Yooshin Engineering Corporation

More information

DUE DILIGENCE REPORT AND CORRECTIVE ACTION PLAN. VIE: Northern Power Transmission Expansion Sector Project SON LA HIEP HOA 500 KV TRANSMISSION LINE

DUE DILIGENCE REPORT AND CORRECTIVE ACTION PLAN. VIE: Northern Power Transmission Expansion Sector Project SON LA HIEP HOA 500 KV TRANSMISSION LINE DUE DILIGENCE REPORT AND CORRECTIVE ACTION PLAN Project Number: Loan 2225-VIE September 2013 VIE: Northern Power Transmission Expansion Sector Project SON LA HIEP HOA 500 KV TRANSMISSION LINE Prepared

More information

Involuntary Resettlement Due Diligence Report

Involuntary Resettlement Due Diligence Report Involuntary Resettlement Due Diligence Report # Report May 2016 VIE: Second Lower Secondary Education for the Most Disadvantaged Areas Project (LSEMDAP2) Quang Binh Province Prepared by the Ministry of

More information

Involuntary Resettlement Due Diligence Report

Involuntary Resettlement Due Diligence Report Involuntary Resettlement Due Diligence Report # Report May 2016 VIE: Second Lower Secondary Education for the Most Disadvantaged Areas Project (LSEMDAP2) Soc Trang Province Prepared by the Ministry of

More information

Income and Livelihood Restoration Plan. Viet Nam: Thanh Hoa City Comprehensive Socioeconomic Development

Income and Livelihood Restoration Plan. Viet Nam: Thanh Hoa City Comprehensive Socioeconomic Development Income and Livelihood Restoration Plan Income and Livelihood Restoration Plan Document Stage: Final Project Number: 41013 June 2013 Viet Nam: Thanh Hoa City Comprehensive Socioeconomic Development Prepared

More information

Involuntary Resettlement Due Diligence Report

Involuntary Resettlement Due Diligence Report Involuntary Resettlement Due Diligence Report # Report May 2016 VIE: Second Lower Secondary Education for the Most Disadvantaged Areas Project (LSEMDAP2) Binh Thuan Province Prepared by the Ministry of

More information

Involuntary Resettlement Due Diligence Report

Involuntary Resettlement Due Diligence Report Involuntary Resettlement Due Diligence Report # Report May 2016 VIE: Second Lower Secondary Education for the Most Disadvantaged Areas Project (LSEMDAP2) Nghe An Province Prepared by the Ministry of Education

More information

ASIAN DEVELOPMENT BANK

ASIAN DEVELOPMENT BANK ASIAN DEVELOPMENT BANK TAR: VIE 34055 TECHNICAL ASSISTANCE TO THE SOCIALIST REPUBLIC OF VIET NAM FOR ENHANCING THE RESETTLEMENT LEGAL FRAMEWORK AND INSTITUTIONAL CAPACITY September 2001 CURRENCY EQUIVALENTS

More information

Indigenous Peoples Development Planning Document. VIE: Calamity Damage Rehabilitation Project

Indigenous Peoples Development Planning Document. VIE: Calamity Damage Rehabilitation Project Indigenous Peoples Development Planning Document Indigenous Peoples Development Framework Document Stage: Final Project Number: 40282 September 2006 VIE: Calamity Damage Rehabilitation Project The summary

More information

Involuntary Resettlement Due Diligence Report

Involuntary Resettlement Due Diligence Report Involuntary Resettlement Due Diligence Report # Report May 2016 VIE: Second Lower Secondary Education for the Most Disadvantaged Areas Project (LSEMDAP2) Bac Lieu Province Prepared by the Ministry of Education

More information

Involuntary Resettlement Due Diligence Report

Involuntary Resettlement Due Diligence Report Involuntary Resettlement Due Diligence Report # Report May 2016 VIE: Second Lower Secondary Education for the Most Disadvantaged Areas Project (LSEMDAP2) Ha Tinh Province Prepared by the Ministry of Education

More information

Involuntary Resettlement Due Diligence Report

Involuntary Resettlement Due Diligence Report Involuntary Resettlement Due Diligence Report # Report May 2016 VIE: Second Lower Secondary Education for the Most Disadvantaged Areas Project (LSEMDAP2) Thua Thien Hue Province Prepared by the Ministry

More information

Viet Nam: GMS Flood and Drought Risk Management and Mitigation Project Thuong Toi Tien Subproject

Viet Nam: GMS Flood and Drought Risk Management and Mitigation Project Thuong Toi Tien Subproject Social Monitoring Report Corrective Action Plan September 2013 Viet Nam: GMS Flood and Drought Risk Management and Mitigation Project Thuong Toi Tien Subproject Prepared by the Department of Agriculture

More information

Viet Nam: University of Science and Technology of Hanoi (New Model University) Project

Viet Nam: University of Science and Technology of Hanoi (New Model University) Project Social Monitoring Report Quarterly Report December 2017 Viet Nam: University of Science and Technology of Hanoi (New Model University) Project Prepared by the Viet Nam Academy of Science and Technology

More information

Internal Monitoring Report. PAK: Loan 2299: Lower Bari Doab Canal Improvement Project

Internal Monitoring Report. PAK: Loan 2299: Lower Bari Doab Canal Improvement Project Internal Monitoring Report 37231-023 March 2016 PAK: Loan 2299: Lower Bari Doab Canal Improvement Project This social monitoring report is a document of the borrower. The views expressed herein do not

More information

SOCIALIST REPUBLIC OF VIET NAM Independence - Freedom Happiness No. 182/2013/ND-CP Hanoi, November 14, 2013 DECREE

SOCIALIST REPUBLIC OF VIET NAM Independence - Freedom Happiness No. 182/2013/ND-CP Hanoi, November 14, 2013 DECREE THE GOVERNMENT ------- SOCIALIST REPUBLIC OF VIET NAM Independence - Freedom Happiness --------- No. 182/2013/ND-CP Hanoi, November 14, 2013.. DECREE STIPULATING REGION-BASED MINIMUM WAGE LEVELS FOR LABORERS

More information

Lao People s Democratic Republic Peace Independence Democracy Unity Prosperity. Prime Minister s Office Date: 7 July, 2005

Lao People s Democratic Republic Peace Independence Democracy Unity Prosperity. Prime Minister s Office Date: 7 July, 2005 Lao People s Democratic Republic Peace Independence Democracy Unity Prosperity Prime Minister s Office No 192/PM Date: 7 July, 2005 DECREE on the Compensation and Resettlement of the Development Project

More information

SOCIALIST REPUBLIC OF VIET NAM Independence - Freedom Happiness No. 107/2010/ND-CP Hanoi, October 29, 2010 DECREE

SOCIALIST REPUBLIC OF VIET NAM Independence - Freedom Happiness No. 107/2010/ND-CP Hanoi, October 29, 2010 DECREE THE GOVERNMENT ------- SOCIALIST REPUBLIC OF VIET NAM Independence - Freedom Happiness --------- No. 107/2010/ND-CP Hanoi, October 29, 2010 DECREE STIPULATING REGION-BASED MINIMUM WAGE LEVELS FOR VIETNAMESE

More information

Resettlement Due Diligence Report

Resettlement Due Diligence Report Resettlement Due Diligence Report August 2015 VIE: Power Transmission Investment Program, Tranche 2-500kV Pleiku-My Phuoc-Cau Bong Transmission Line Binh Phuoc Province Prepared by Central Vietnam Power

More information

Viet Nam: Central Region Small and Medium Towns Development Cam Ranh (Khanh Hoa) Subproject

Viet Nam: Central Region Small and Medium Towns Development Cam Ranh (Khanh Hoa) Subproject Resettlement Monitoring Report Annual Report October 2012 Viet Nam: Central Region Small and Medium Towns Development Cam Ranh (Khanh Hoa) Subproject Prepared by the InvestConsult Group for the Provincial

More information

VIET NAM: GREATER MEKONG SUBREGION FLOOD AND DROUGHT RISK MANAGEMENT AND MITIGATION PROJECT

VIET NAM: GREATER MEKONG SUBREGION FLOOD AND DROUGHT RISK MANAGEMENT AND MITIGATION PROJECT Resettlement Framework February 2012 VIET NAM: GREATER MEKONG SUBREGION FLOOD AND DROUGHT RISK MANAGEMENT AND MITIGATION PROJECT Prepared by the Ministry of Agriculture and Rural Development (MARD), Socialist

More information

VIE: Comprehensive Socioeconomic Urban Development Project Viet Tri, Hung Yen, and Dong Dang (Dong Dang)

VIE: Comprehensive Socioeconomic Urban Development Project Viet Tri, Hung Yen, and Dong Dang (Dong Dang) Resettlement Plan August 2011 VIE: Comprehensive Socioeconomic Urban Development Project Viet Tri, Hung Yen, and Dong Dang (Dong Dang) Prepared by the Lang Son Provincial People s Committee for the Asian

More information

Resettlement Plan. September 2016

Resettlement Plan. September 2016 Resettlement Plan September 2016 VIE: GMS Flood and Drought Risk Management and Mitigation Project - Upgrading and Rehabilitation of Four Primary Canals in Plain of Reeds, Dong Thap Province - Cai Cai

More information

VIE: Northern Power Transmission Expansion Sector Project

VIE: Northern Power Transmission Expansion Sector Project Resettlement Monitoring Report March 2014 VIE: Northern Power Transmission Expansion Sector Project Prepared by the Local Implementation Consultant (LIC) Social for Viet Nam Electricity (EVN) Northern

More information

VIE: Ha Noi and Ho Chi Minh City Power Grid Development Sector Project

VIE: Ha Noi and Ho Chi Minh City Power Grid Development Sector Project RESETTLEMENT PLAN Project Number: 46391-001 December 2017 VIE: Ha Noi and Ho Chi Minh City Power Grid Development Sector Project Prepared by Hanoi City Power Corporation, Electricity of Vietnam for Asian

More information

VIE: Ho Chi Minh City Urban Mass Rapid Transit Line 2 Project

VIE: Ho Chi Minh City Urban Mass Rapid Transit Line 2 Project Resettlement Plan July 2012 VIE: Ho Chi Minh City Urban Mass Rapid Transit Line 2 Project Prepared by Ho Chi Minh City People s Committee Management Authority Of Urban Railway for the Asian Development

More information

ABBREVIATED RESETTLEMENT ACTION PLAN

ABBREVIATED RESETTLEMENT ACTION PLAN Public Disclosure Authorized Public Disclosure Authorized Public Disclosure Authorized Public Disclosure Authorized Project: Irrigated Agriculture Improvement (IAIP) Subproject 1, Hoa Binh province SOCIALIST

More information

VIE: Hanoi and Ho Chi Minh City Power Grid Development Sector Project. EVN HCMC: 220kV Tan Cang Substation

VIE: Hanoi and Ho Chi Minh City Power Grid Development Sector Project. EVN HCMC: 220kV Tan Cang Substation Resettlement Due Diligence Report Stage of the document: Final Loan number: 3163-VIE October 2016 VIE: Hanoi and Ho Chi Minh City Power Grid Development Sector Project EVN HCMC: 220kV Tan Cang Substation

More information

VIE: Power Transmission Investment Program, Tranche 1 220kV Song May-Uyen Hung Transmission Line

VIE: Power Transmission Investment Program, Tranche 1 220kV Song May-Uyen Hung Transmission Line Social Monitoring Report Semi-Annual Report January-June 2014 VIE: Power Transmission Investment Program, Tranche 1 220kV Song May-Uyen Hung Transmission Line Prepared by the Southern Vietnam Power Projects

More information

VIE: Ho Chi Minh City Urban Mass Rapid Transit Line 2 Investment Program

VIE: Ho Chi Minh City Urban Mass Rapid Transit Line 2 Investment Program Social Monitoring Report Quarterly Report (1 st Quarter 2018) June 2018 VIE: Ho Chi Minh City Urban Mass Rapid Transit Line 2 Investment Program Prepared by Management Authority for Urban Railway for the

More information

MON: Urban Development Sector Project Bulgan Subproject

MON: Urban Development Sector Project Bulgan Subproject Resettlement Completion Report Annual Report 24 December 2012 MON: Urban Development Sector Project Bulgan Subproject Prepared by Purevsuren Dorjnamjil, Resettlement Specialist, Project Management Unit

More information

RESETTLEMENT FRAMEWORK. Supplementary Appendix to the Report and Recommendation of the President to the Board of Directors. on the

RESETTLEMENT FRAMEWORK. Supplementary Appendix to the Report and Recommendation of the President to the Board of Directors. on the RESETTLEMENT FRAMEWORK Supplementary Appendix to the Report and Recommendation of the President to the Board of Directors on the Secondary Education Modernization Project II in Sri Lanka Ministry of Education

More information

RESETTLEMENT ACTION PLAN

RESETTLEMENT ACTION PLAN Public Disclosure Authorized Public Disclosure Authorized PEOPLE S COMMITTEE OF PHU YEN PROVINCE PHU YEN PROJECT MANAGEMENT UNIT OF CONSTRUCTION INVESTMENT WORKS FOR AGRICULTURE AND RURAL DEVELOPMENT ----------------o0oo---------------

More information

VIETNAM ELECTRICITY NATIONAL POWER TRANSMISSION CORPORATION

VIETNAM ELECTRICITY NATIONAL POWER TRANSMISSION CORPORATION Public Disclosure Authorized VIETNAM ELECTRICITY NATIONAL POWER TRANSMISSION CORPORATION ------------------------------------------------------------------ SFG1163 V11 Public Disclosure Authorized Public

More information

Subproject: Hai Lang Province: Quang Tri

Subproject: Hai Lang Province: Quang Tri Public Disclosure Authorized Public Disclosure Authorized Public Disclosure Authorized Public Disclosure Authorized RP299 vol. 4 Ministry of Agriculture and Rural Development The World Bank Natural Disaster

More information

VIE: Greater Mekong subregion Flood and Drought Risk Management and Mitigation Project (GMS1)

VIE: Greater Mekong subregion Flood and Drought Risk Management and Mitigation Project (GMS1) Resettlement Monitoring Report #1 Semestral Report August 2015 VIE: Greater Mekong subregion Flood and Drought Risk Management and Mitigation Prepared by Vietnam Water, Sanitation and Environment joint

More information

VIE: Hanoi Metro Rail System Project Line 3: Nhon-Hanoi Station Section

VIE: Hanoi Metro Rail System Project Line 3: Nhon-Hanoi Station Section Social Due Diligence Report Document Stage: Second Draft Project Number: 40080 May 2013 VIE: Hanoi Metro Rail System Project Line 3: Nhon-Hanoi Station Section Prepared by Hanoi Metro Railway Board for

More information

DANANG DEPARTMENT OF TRANSPORT DANANG PRIORITY INFRASTRUCTURE INVESTMENT PROJECT MANAGEMENT UNIT DANANG SUSTAINABLE CITY DEVELOPMENT PROJECT

DANANG DEPARTMENT OF TRANSPORT DANANG PRIORITY INFRASTRUCTURE INVESTMENT PROJECT MANAGEMENT UNIT DANANG SUSTAINABLE CITY DEVELOPMENT PROJECT DANANG DEPARTMENT OF TRANSPORT DANANG PRIORITY INFRASTRUCTURE INVESTMENT PROJECT MANAGEMENT UNIT DANANG SUSTAINABLE CITY DEVELOPMENT PROJECT (Loan No. 5233-VN) SFG1981 V2 RESETTLEMENT PLAN Public Disclosure

More information

DANANG DEPARTMENT OF TRANSPORT DANANG PRIORITY INFRASTRUCTURE INVESTMENT PROJECT MANAGEMENT UNIT DANANG SUSTAINABLE CITY DEVELOPMENT PROJECT

DANANG DEPARTMENT OF TRANSPORT DANANG PRIORITY INFRASTRUCTURE INVESTMENT PROJECT MANAGEMENT UNIT DANANG SUSTAINABLE CITY DEVELOPMENT PROJECT DANANG DEPARTMENT OF TRANSPORT DANANG PRIORITY INFRASTRUCTURE INVESTMENT PROJECT MANAGEMENT UNIT DANANG SUSTAINABLE CITY DEVELOPMENT PROJECT (Loan No. 5233-VN) SFG2443 V2 RESETTLEMENT PLAN FOR THE ADJUSTMENT

More information

Internal Monitoring Report. VIE: Second Greater Mekong Subregion Corridor Towns Development Project. Semestral Report (From July to December 2017)

Internal Monitoring Report. VIE: Second Greater Mekong Subregion Corridor Towns Development Project. Semestral Report (From July to December 2017) Internal Monitoring Report Semestral Report (From July to December 2017) VIE: Second Greater Mekong Subregion Corridor Towns Development Project Prepared by: PMUs Bac Giang, Lao Cai and Mong Cai for Asian

More information

Semi-annual Social Safeguards Monitoring Report (January to June 2012)

Semi-annual Social Safeguards Monitoring Report (January to June 2012) Semi-annual Social Safeguards Monitoring Report (January to June 2012) Armenia: Sustainable Urban Development Investment Program Tranche 1 Project Number: 42417 Loan Number: L2752 Prepared: July 2013 Prepared

More information

VIE: Power Transmission Investment Program, Tranche 2 500kV Pleiku-My Phuoc-Cau Bong Transmission Line (Dak Nong Province)

VIE: Power Transmission Investment Program, Tranche 2 500kV Pleiku-My Phuoc-Cau Bong Transmission Line (Dak Nong Province) Social Monitoring Report July 2014 VIE: Power Transmission Investment Program, Tranche 2 500kV Pleiku-My Phuoc-Cau Bong Transmission Line (Dak Nong Province) Prepared by Central Vietnam Power Projects

More information

CAN THO URBAN DEVELOPMENT AND RESILIENCE PROJECT

CAN THO URBAN DEVELOPMENT AND RESILIENCE PROJECT CAN THO CITY PEOPLE S COMMITTEE CONSTRUCTION & INVESTMENT MANAGEMENT UNIT USING OFFICIAL DEVELOPMENT ASSISTANCE (ODA), CAN THO CITY ***** SFG1562 REV RESETTLEMENT POLICY FRAMEWORK FOR CAN THO URBAN DEVELOPMENT

More information

Social Safeguards Monitoring Report. CAM: Rural Roads Improvement Project II

Social Safeguards Monitoring Report. CAM: Rural Roads Improvement Project II Social Safeguards Monitoring Report Full Report November 2018 CAM: Rural Roads Improvement Project II Prepared by the Ministry of Rural Development for the Kingdom of Cambodia and the Asian Development

More information

VIE: Greater Mekong Subregion Southern Coastal Corridor

VIE: Greater Mekong Subregion Southern Coastal Corridor Resettlement Plan March 2012 VIE: Greater Mekong Subregion Southern Coastal Corridor Updated Resettlement Plan of Xa Xia Ha Tien Section Prepared by Cuu Long Corporation for Investment, Development and

More information

VIE: Yen Vien-Lao Cai Railway Upgrading Project

VIE: Yen Vien-Lao Cai Railway Upgrading Project Social Monitoring Report Semi-Annual Report June 2014 VIE: Yen Vien-Lao Cai Railway Upgrading Project External Monitoring Report on RP Implementation Yen Bai Province Prepared by Railway Projects Management

More information

VIE: Phuoc Hoa Water Resources Project

VIE: Phuoc Hoa Water Resources Project Resettlement Plan Sept 212 VIE: Phuoc Hoa Water Resources Project Component: Duc Hoa main canal Cu Chi section Prepared by Project Management Unit for Investment and Construction of Cu Chi District for

More information

VIE: Mong Duong 1 Thermal Power Plant

VIE: Mong Duong 1 Thermal Power Plant 11 th Independent Monitoring Report November 2014 VIE: Mong Duong 1 Thermal Power Plant Prepared by the Development Research and Consultancy Center (DRCC) for Viet Nam Electricity (EVN) Thermal Power Project

More information

L3173-VIE: INTEGRATED RURAL DEVELOPMENT SECTOR PROJECT IN THE CENTRAL PROVINCES (Additional Financing)

L3173-VIE: INTEGRATED RURAL DEVELOPMENT SECTOR PROJECT IN THE CENTRAL PROVINCES (Additional Financing) INTERNAL SOCIAL SAFEGUARDS MONITORING REPORT ON RESETTLEMENT (From July 2017 to December 2017) Document stage: Final report Loan Number: 3173 January, 2018 L3173-VIE: INTEGRATED RURAL DEVELOPMENT SECTOR

More information

VIE: Ho Chi Minh City-Long Thanh-Dau Giay Expressway Project

VIE: Ho Chi Minh City-Long Thanh-Dau Giay Expressway Project Social Monitoring Report May 2010 VIE: Ho Chi Minh City-Long Thanh-Dau Giay Expressway Project Prepared by EPC Co., Ltd. for the Viet Nam Expressway Corporation under the Ministry of Transport and the

More information

VIET NAM: MEDIUM CITES DEVELOPMENT PROJECT (MCDP) PHU LY CITY SUBPROJECT HA NAM PROVINCE. (Final Draft)

VIET NAM: MEDIUM CITES DEVELOPMENT PROJECT (MCDP) PHU LY CITY SUBPROJECT HA NAM PROVINCE. (Final Draft) Public Disclosure Authorized VIET NAM: MEDIUM CITES DEVELOPMENT PROJECT (MCDP) PHU LY CITY SUBPROJECT HA NAM PROVINCE COMPENSATION, ASSISTANCE AND RESETTLEMENT POLICY FRAMEWORK (Final Draft) Table of Contents

More information

Bangladesh: Urban Public and Environmental Health Sector Development Program

Bangladesh: Urban Public and Environmental Health Sector Development Program Resettlement Planning Document Draft Resettlement Framework Document Stage: Draft for Consultation Project Number: 39305 May 2009 Bangladesh: Urban Public and Environmental Health Sector Development Program

More information

Annex 2: Does the Xayaburi resettlement comply with Lao law?

Annex 2: Does the Xayaburi resettlement comply with Lao law? Annex 2: Does the Xayaburi resettlement comply with Lao law? The Xayaburi project s resettlement scheme has not complied with Lao laws and policies on involuntary resettlement and compensation. As the

More information

VIE: Central Mekong Delta Region Connectivity Project

VIE: Central Mekong Delta Region Connectivity Project Social Monitoring Report Quarterly Report No. 8 November 2015 VIE: Central Mekong Delta Region Connectivity Project Prepared by Joint Venture: CDM Smith, Inc., WSP Finland Limited & Yooshin Engineering

More information

VIE: Phuoc Hoa Water Resources Project

VIE: Phuoc Hoa Water Resources Project Resettlement Plan Loan: 2025/2747 Document stage: updated Dec 2013 VIE: Phuoc Hoa Water Resources Project Component: Tan Bien Irrigation Area Five drainage canals in Chau Thanh District, Tay Ninh Province

More information

Involuntary Resettlement Due Diligence Report

Involuntary Resettlement Due Diligence Report Involuntary Resettlement Due Diligence Report # Report May 2016 VIE: Second Lower Secondary Education for the Most Disadvantaged Areas Project (LSEMDAP2) Cao Bang Province Prepared by the Ministry of Education

More information

Resettlement and Ethnic Minority Development Framework (REMDF)

Resettlement and Ethnic Minority Development Framework (REMDF) Resettlement and Ethnic Minority Development Framework (REMDF) Stage of the document: FINAL Project number: 49026-002 April 2017 VIE: Basic Infrastructure for Inclusive Growth in the Northeastern Provinces

More information

VIE: Development of the Northern Chu and Southern Ma Rivers Irrigation System Project

VIE: Development of the Northern Chu and Southern Ma Rivers Irrigation System Project Social Monitoring Report 2nd Semi-annual Report January 2018 VIE: Development of the Northern Chu and Southern Ma Rivers Irrigation System Project Prepared by Development Research and Consultancy Centre

More information

VIE: GMS Southern Coastal Corridor Project

VIE: GMS Southern Coastal Corridor Project Social Monitoring Report 2nd Report September 2014 VIE: GMS Southern Coastal Corridor Project Prepared by External Monitor, Romeo Cleto, for the Ministry of Transport of Viet Nam and the Asian Development

More information

Flagship Capital Corporation

Flagship Capital Corporation Resettlement Planning Document Resettlement Framework Project Number: 39906 June 2005 REG: Proposed Equity Investment Flagship Capital Corporation Prepared by Flagship Capital Corporation (Singapore) Ltd.

More information

VIE: Mong Duong 1 Thermal Power Plant

VIE: Mong Duong 1 Thermal Power Plant Resettlement Monitoring Report Quarterly Report July September 2013 VIE: Mong Duong 1 Thermal Power Plant Prepared by Viet Nam Electricity (EVN) GENCO 3 Thermal Power Projects Management Board 1. Internal

More information

Vietnam: GMS Sustainable Tourism Development Project

Vietnam: GMS Sustainable Tourism Development Project December 2010 Vietnam: GMS Sustainable Tourism Development Project Prepared by Quang Binh Provincial Implementation Unit for the Asian Development Bank. CURRENCY EQUIVALENTS (as of 17 August 2010) Currency

More information

VIE: Ha Noi Metro Rail System Project (Line 3: Nhon Ha Noi Station Section)

VIE: Ha Noi Metro Rail System Project (Line 3: Nhon Ha Noi Station Section) Safeguards Monitoring Report External Social Safeguards Monitoring Report October 2017 VIE: Ha Noi Metro Rail System Project (Line 3: Nhon Ha Noi Station Section) Prepared by External Resettlement Monitor

More information

VIE: Northern Power Transmission Expansion Sector Project

VIE: Northern Power Transmission Expansion Sector Project Resettlement Monitoring Report June 2013 VIE: Northern Power Transmission Expansion Sector Project Subprojects: 1) 500kV Hiep Hoa substation 2) 500kV Son La- Hiep Hoa Transmission Line 3) 220 kv Thuong

More information

THE WORLD BANK INSPECTION PANEL S EARLY SOLUTIONS PILOT APPROACH: THE CASE OF BADIA EAST, NIGERIA

THE WORLD BANK INSPECTION PANEL S EARLY SOLUTIONS PILOT APPROACH: THE CASE OF BADIA EAST, NIGERIA THE WORLD BANK INSPECTION PANEL S EARLY SOLUTIONS PILOT APPROACH: THE CASE OF BADIA EAST, NIGERIA In July 2014 the World Bank Inspection Panel, the Bank s complaints mechanism for people who believe that

More information

Viet Nam: Water Sector Investment Program Tranche 3. Constructing New Water Treatment Plant, Phuc Triu Commune, Thai Nguyen City, Thai Nguyen Province

Viet Nam: Water Sector Investment Program Tranche 3. Constructing New Water Treatment Plant, Phuc Triu Commune, Thai Nguyen City, Thai Nguyen Province Resettlement Plan Resettlement Plan Document Stage: Revised Project Number: 41456-043 January 2019 Viet Nam: Water Sector Investment Program Tranche 3 Constructing New Water Treatment Plant, Phuc Triu

More information

SUMMARY RESETTLEMENT PLAN OF WATER SUPPLY AND SOLID WASTE MANAGEMENT TRANCHE-2 SUB PROJECT OF GANGTOK UNDER ADB ASSISTED NERCCDIP PROJECT

SUMMARY RESETTLEMENT PLAN OF WATER SUPPLY AND SOLID WASTE MANAGEMENT TRANCHE-2 SUB PROJECT OF GANGTOK UNDER ADB ASSISTED NERCCDIP PROJECT SUMMARY RESETTLEMENT PLAN OF WATER SUPPLY AND SOLID WASTE MANAGEMENT TRANCHE-2 SUB PROJECT OF GANGTOK UNDER ADB ASSISTED NERCCDIP PROJECT A. Introduction and Subprojects Components 1. Tranche 2 of the

More information

NH21/2 LAC QUAN THINH LONG RESETTLEMENT ACTION PLAN

NH21/2 LAC QUAN THINH LONG RESETTLEMENT ACTION PLAN Public Disclosure Authorized Public Disclosure Authorized Public Disclosure Authorized Public Disclosure Authorized SOCIALIST REPUBLIC OF VIETNAM MINISTRY OF TRANSPORT PROJECT MANAGEMENT UNIT 18 ROAD NETWORK

More information

PEOPLE S COMMITTEE OF BEN TRE PROVINCE PEOPLE S COMMITTEE OF BEN TRE CITY

PEOPLE S COMMITTEE OF BEN TRE PROVINCE PEOPLE S COMMITTEE OF BEN TRE CITY PEOPLE S COMMITTEE OF BEN TRE PROVINCE PEOPLE S COMMITTEE OF BEN TRE CITY SFG2836 V2 REV SCALING UP URBAN UPGRADING PROJECT SUBPROJECT OF BEN TRE CITY, BEN TRE PROVINCE RESETTLEMENT PLAN (Final Version)

More information

Recommendation 1: Establish a compensation deficit payment scheme.

Recommendation 1: Establish a compensation deficit payment scheme. Eleventh Quarterly Progress Report ADB Management s Action Plan to Implement the Board Decision on the Recommendations of the CRP Final Report: Rehabilitation of the Railway in Cambodia Project This report

More information

Viet Nam: Thanh Hoa City Comprehensive Socioeconomic Development Project

Viet Nam: Thanh Hoa City Comprehensive Socioeconomic Development Project Resettlement Planning Document Resettlement Plan Document Stage: Revised Project Number: 41013-013 March 2012 Viet Nam: Thanh Hoa City Comprehensive Socioeconomic Development Project Prepared by Provincial

More information

Final Monitoring Report to the Board of Directors. on the. Implementation of Remedial Actions. for the

Final Monitoring Report to the Board of Directors. on the. Implementation of Remedial Actions. for the Final Monitoring Report to the Board of Directors on the Implementation of Remedial Actions for the Integrated Citarum Water Resources Management Investment Program Project 1 in the Republic of Indonesia

More information

SOCIAL SAFEGUARD MANUAL

SOCIAL SAFEGUARD MANUAL Public Disclosure Authorized Public Disclosure Authorized Public Disclosure Authorized Public Disclosure Authorized SOCIALIST REPUBLIC OF VIETNAM HO CHI MlNH CITY'S INFRASTRUCTURE DEVELOPMENT FUND ********

More information

VIE: Yen Vien-Lao Cai Railway Upgrading Project

VIE: Yen Vien-Lao Cai Railway Upgrading Project Social Monitoring Report Semi-Annual Report June 2014 VIE: Yen Vien-Lao Cai Railway Upgrading Project Resettlement Monitoring Report Prepared by Railway Projects Management Unit of Viet Nam Railway for

More information

NH21/1 NAM DINH - LAC QUAN RESETTLEMENT ACTION PLAN

NH21/1 NAM DINH - LAC QUAN RESETTLEMENT ACTION PLAN Public Disclosure Authorized Public Disclosure Authorized Public Disclosure Authorized Public Disclosure Authorized SOCIALIST REPUBLIC OF VIETNAM MINISTRY OF TRANSPORT PROJECT MANAGEMENT UNIT 18 ROAD NETWORK

More information

IND: Railway Sector Investment Program

IND: Railway Sector Investment Program Resettlement Framework Document Stage: Final March 2011 IND: Railway Sector Investment Program Prepared by Ministry of Railways for the Asian Development Bank. CURRENCY EQUIVALENTS (as of 16 March 2011)

More information

DIRECTORATE FOR ROADS OF VIETNAM PROJECT MANAGEMENT UNIT 3 ================= RESETTLEMENT PLAN

DIRECTORATE FOR ROADS OF VIETNAM PROJECT MANAGEMENT UNIT 3 ================= RESETTLEMENT PLAN Public Disclosure Authorized Public Disclosure Authorized Public Disclosure Authorized Public Disclosure Authorized DIRECTORATE FOR ROADS OF VIETNAM PROJECT MANAGEMENT UNIT 3 ================= RESETTLEMENT

More information

VIE: Strengthening Water Management and Irrigation Systems Rehabilitation Project

VIE: Strengthening Water Management and Irrigation Systems Rehabilitation Project Resettlement Plan Updated Resettlement Plan for Nghi Xuyen pumping station Sub-project October 2012 VIE: Strengthening Water Management and Irrigation Systems Rehabilitation Project Prepared by CPMO for

More information

POLICIES ON COMPULSORY SI FOR THE EMPLOYEES WHO HOLD CITIZENSHIP OF FOREIGN COUNTRY AND WORK IN VIETNAM

POLICIES ON COMPULSORY SI FOR THE EMPLOYEES WHO HOLD CITIZENSHIP OF FOREIGN COUNTRY AND WORK IN VIETNAM Ministry of Labour Invalids and Social Affairs of Viet Nam 1 POLICIES ON COMPULSORY SI FOR THE EMPLOYEES WHO HOLD CITIZENSHIP OF FOREIGN COUNTRY AND WORK IN VIETNAM Bangkok, July 2017 July 6, 2017 Agenda

More information

VOLUME 4 CHAPTER 1 PROJECT DESCRIPTION

VOLUME 4 CHAPTER 1 PROJECT DESCRIPTION VOLUME 4 CHAPTER 1 PROJECT DESCRIPTION Table of Content Volume 4 Chapter 1: Project Description 1 PROJECT DESCRIPTION...1 1.1 THE NT2 PROJECT...1 1.2 THE NEED FOR RESETTLEMENT AND DEVELOPMENT...1 1.3 THE

More information

Viet Nam: Secondary Cities Development Project. Package TK-02: Dien Bien Phu Road, Tam Ky City, Quang Nam Province

Viet Nam: Secondary Cities Development Project. Package TK-02: Dien Bien Phu Road, Tam Ky City, Quang Nam Province Resettlement Plan Resettlement Plan Document Stage: Revised Project Number: 45198 June 2016 Viet Nam: Secondary Cities Development Project Package TK-02: Dien Bien Phu Road, Tam Ky City, Quang Nam Province

More information

Social Monitoring Report

Social Monitoring Report Social Monitoring Report #4 Report November GMS: Kunming-Hai Phong Transport Corridor - Noi Bai - Lao Cai Highway Project Vinh Phuc Province Prepared by Scientific Technological Center and Environment

More information

Viet Nam: Central Region Rural Water Supply and Sanitation Sector Project

Viet Nam: Central Region Rural Water Supply and Sanitation Sector Project Resettlement Plan July 2015 Viet Nam: Central Region Rural Water Supply and Sanitation Sector Project WATER SUPPLY AND SANITATION OF THANH TRACH COMMUNE, BO TRACH DISTRICT, QUANG BINH PROVINCE Prepared

More information

Viet Nam: Central Region Urban Environmental Improvement Project

Viet Nam: Central Region Urban Environmental Improvement Project Resettlement Planning Document Resettlement Plan Document Stage: Updated Project Number: 34355 June 2008 Viet Nam: Central Region Urban Environmental Improvement Project Prepared by Project Coordination

More information

FINAL ETHNIC MINORITY POLICY FRAMEWORK

FINAL ETHNIC MINORITY POLICY FRAMEWORK SOCIALIST REPUBLIC OF VIETNAM Independence Freedom Happiness ******** SFG2829 REV FINAL ETHNIC MINORITY POLICY FRAMEWORK SCALING-UP URBAN UPGRADING PROJECT PROJECT S LOCATION BEN TRE (BEN TRE PROVINCE),

More information

RESETTLEMENT PLAN FOR THE DUC HOA IRRIGATION AREA

RESETTLEMENT PLAN FOR THE DUC HOA IRRIGATION AREA SOCIALIST REPUBLIC OF VIETNAM MINISTRY OF AGRICULTURE AND RURAL DEVELOPMENT HYDRAULIC INVESTMENT AND CONSTRUCTION MANAGEMENT BOARD 9 Phuoc Hoa Water Resource Project ADB Loan No 29296-02 VIE RESETTLEMENT

More information

2622-BAN: Natural Gas Access Improvement Project, Part B: Safety and Supply Efficiency Improvement in Titas Gas Field

2622-BAN: Natural Gas Access Improvement Project, Part B: Safety and Supply Efficiency Improvement in Titas Gas Field Draft Safeguards Monitoring Report Project No. 38164-013 Draft Semi Annual Report December 2015 2622-BAN: Natural Gas Access Improvement Project, Part B: Safety and Supply Efficiency Improvement in Titas

More information

IND: Railway Sector Investment Program Tranche 3

IND: Railway Sector Investment Program Tranche 3 Resettlement Due Diligence Report September 2017 IND: Railway Sector Investment Program Tranche 3 Prepared by the Ministry of Railways for the Republic of India and the Asian Development Bank. CURRENCY

More information

RESETTLEMENT FRAMEWORK HA TINH, QUANG NAM, QUANG NGAI, QUANG TRI, THANH HOA, THUA THIEN HUE

RESETTLEMENT FRAMEWORK HA TINH, QUANG NAM, QUANG NGAI, QUANG TRI, THANH HOA, THUA THIEN HUE RESETTLEMENT FRAMEWORK HA TINH, QUANG NAM, QUANG NGAI, QUANG TRI, THANH HOA, THUA THIEN HUE Supplementary Appendix to the Report and Recommendation of the President to the Board of Directors on the CENTRAL

More information

Resettlement and Ethnic Minority Development Plan (REMDP)

Resettlement and Ethnic Minority Development Plan (REMDP) Resettlement and Ethnic Minority Development Plan (REMDP) Document Stage: Final 20 July 2010 GMS: Kunming-Hai Phong Transport Corridor - Noi Bai- Lao Cai Highway Project Bao Thang District, Lao Cai Province

More information

NINH THUAN UPDATED RESETTLEMENT PLAN

NINH THUAN UPDATED RESETTLEMENT PLAN SOCIALIST REPUBLIC OF VIETNAM MINISTRY OF TRANSPORT PROJECT MANAGEMENT UNIT No.1 CENTRAL REGION TRANSPORT NETWORKS IMPROVEMENT SECTOR PROJECT (ADB5) NINH THUAN UPDATED RESETTLEMENT PLAN August 2009 Table

More information

NH18: CUA ONG MONG DUONG RESETTLEMENT ACTION PLAN

NH18: CUA ONG MONG DUONG RESETTLEMENT ACTION PLAN Public Disclosure Authorized Public Disclosure Authorized Public Disclosure Authorized Public Disclosure Authorized SOCIALIST REPUBLIC OF VIETNAM MINISTRY OF TRANSPORT PROJECT MANAGEMENT UNIT 18 ROAD NETWORK

More information

VIE: Phuoc Hoa Water Resources Project

VIE: Phuoc Hoa Water Resources Project Resettlement Plan April 2012 VIE: Phuoc Hoa Water Resources Project Prepared by Project Management Board for Investment and Construction of Agriculture and Rural Development of Tay Ninh Province for the

More information

VIE: Yen Vien-Lao Cai Railway Upgrading Project

VIE: Yen Vien-Lao Cai Railway Upgrading Project Social Monitoring Report Semi-Annual Report July December 2015 VIE: Yen Vien-Lao Cai Railway Upgrading Project Resettlement Monitoring Report Prepared by CDM Smith DBI Joint Venture for the Ministry of

More information

VIE: Second Health Care in the Central Highlands Project in Dak Nong Province

VIE: Second Health Care in the Central Highlands Project in Dak Nong Province Due Diligence Report March 2016 VIE: Second Health Care in the Central Highlands Project in Dak Nong Province Prepared by the Ministry of Health, Socialist Republic of Viet Nam, for Asian Development Bank.

More information

India: Madhya Pradesh Urban Services Improvement Project (MPUSIP)

India: Madhya Pradesh Urban Services Improvement Project (MPUSIP) Resettlement Planning Document Resettlement Framework Document Stage: Draft for Consultation Project Number: 42486 June 2016 India: Madhya Pradesh Urban Services Improvement Project (MPUSIP) The resettlement

More information