Notice Inviting E-Tender

Transcription

1 Website: ETendering Website: Notice Inviting ETender Online bids are hereby invited for the following work: 1) NAME OF WORK : CONSTRUCTION OF MTS CAP. GODOWNS, AT FSD DHAND(PHASEII)(BHATTU KALAN), FATEHABAD. Estimated Cost Lakh Time Limit Earnest Money 9 months Rs Tender Document Fee Rs / Downloading of Tender Document and online bid preparation / hash Submission Date & Time :01 Hrs To :00 Hrs Submission of online bid (ReEncryption of Bids) Date & time :01 Hrs To :00 Hrs Possession of Digital Signature Certificate (DSC) and r egistration of the contractors on the portal i.e. is a prerequisite for etendering. Kindly contact O/o Nextenders ( India) Pvt. Ltd., O/o PWD (B&R) Haryana, Nirman Sadan, Plot No. 1, Dakhan Marg, Sector 33A Chandigarh. Contact persons : Sh. Manmit Sharma / Kanwarjeet Singh For further details and etendering schedule, visit website Executive Engineer

2 PANCHKULA DIVISION ETENDER Contract for works, General rules & directions for the guidance of the Contractors 1 Name of work 2 Name of contractor 3 Address 4 (a) category of Enlistment (b) For the period 5 Estimated cost of work 6 Tender fee Rs 7 Earnest money 8 Time limit 9 Contact No 10 PAN No Dated Signature & Rubber Stamp of the Contractor

3 HARYANA STATE WAREHOUSING CORPORATION, PANCHKULA NOTICE INVITING ETENDER Online bids are hereby invited for the following work: 1) NAME OF WORK : CONSTRUCTION OF MTS CAP. GODOWNS, AT FSD DHAND(PHASEII)(BHATTU KALAN), FATEHABAD Estimated Cost Time Limit Earnest Money Tender Document Fee Downloading of Tender Document and online bid preparation / hash Submission Date & Time Submission of online bid (ReEncryption of Bids) Date & time Lakh 9 months Rs Rs / :01 Hrs To :00 Hrs :01 Hrs To :00 Hrs 1. Tender documents can be downloaded online from the Portal: by the Firms / Individual registered on the Portal. 2. As the Bids are to be submitted online and are required to be encrypted and digitally signed, the Bidders are advised to obtain Digital Signature Certificate (DSC) at the earliest. For obtaining Digital Certificate, the Bidders should follow point No. 3 under AnnexureA Conditions of etendering.

4 3. Key Dates Sr. No. 1 HSWC Stage Release of Tender document 2 3 Contractor Stage Downloading of Tender Document & Payment of Tender Document fees Online Bid Preparation, Hash Submission & Earnest Money Deposit Start Date and Time :00 Hrs :01 Hrs :01 Hrs Expiry Date and Time :00 Hrs :00 Hrs :00 Hrs 4 Technical & Financial Lock Open EMD & / Technical bid Eligibility criteria evaluation Open Financial / PriceBid Reencryption of Online Bids Manual Submission of EMD & additional documents :00 Hrs :01 Hrs :00 Hrs :01 Hrs :00 Hrs :00 Hrs :00 hrs :00 Hrs :00 Hrs :59 Hrs :00 Hrs :00 Hrs

5 a) The Bidders can download the tender documents from the Portal: Tender Documents Fees has to be paid online through payment gateway during the Online Bid Preparation & Hash Submission stage and Earnest Money Deposit has to be deposited through Demand Draft in the name of Haryana State Warehousing Corporation, Panchkula. Willing Contractors shall have to pay the Tender Document Fees through payment gateway during the Online Bid Preparation & Hash Submission stage. However, the details of the EMD are required to be filled at the time of Bid Preparation and Hash Submission Stage; the Bidders are required to keep the EMD details ready beforehand. 4. The tender shall be submitted by the bidder in the following two separate envelops online: 1. Earnest Money and all the documents In support of eligibility criteria Envelope T1 2. Price Bid Envelope C1 Reference of the EMD is to be mentioned online In the first instance, the Envelop T1 of all the Bidders containing the statement of Earnest Money and documents supporting eligibility criteria shall be opened online. If the Earnest Money and eligibility of bidder is found proper, the Envelop C1 containing financial bids shall be opened online in the presence of such bidders who either themselves or through their representatives choose to be present. The financial bid shall be opened only if the bidders meet the eligibility criteria as per the Bid document. Envelope T1 Earnest Money Deposit and eligibility criteria Envelope

6 in support of deposit of Earnest Money. EE Online Technical Envelope Reference details of the Earnest Money Deposit instrument and scanned copy of documents supporting deposition of EMD and eligibility criteria. Envelope CI Price Bid Envelope To be submitted mandatory online Information related to Price Bid of the Tender. The bidder can submit their tender documents as per the dates mentioned in the schedule above. CONDITIONS: 1) EMD of Societies and the contractors shall be the same. 2) Conditional tenders will not be entertained & are liable to be rejected. 3) The undersigned reserves the right to reject any tender or all the tenders without assigning any reason. 4) The societies shall upload & produce a copy of the resolution authorizing the person to file the tender from the Co Operative department for etendering. 5) The tender without earnest money payment will not be opened. 6) The jurisdiction of court will be at Panchkula. 7) The tender of the bidder who does not satisfy the eligibility criteria in the bid documents will be rejected summarily without assigning any reason and no claim whatsoever on this account will be considered. 8) Bids shall be valid for 3 months from the date of expiry of online ReEncryption of online Bids stage. The bid for the work shall remain open for acceptance during the bid validity period to be reckoned from the expiry date of Re Encryption of online Bids stage. If any bidder withdraws his bid during bid validity period, any modifications in the terms and conditions of the bid, the said earnest money shall stand forfeited.

7 ANNEXUREA CONDITIONS OF ETENDERING Instruction to Contractor on Electronic Tendering These conditions will overrule the conditions stated in the tender documents, wherever relevant and applicable. 1. Registration of contractors on Etendering Portal: All the Contractors intending to participate in the tenders Tendering System on the Portal info link on the home page. processed online, are required to get registered on the Electronic For more details, please see the information on the Registration 2. Obtaining a Digital Certificate: 2.1 The Bids submitted online should be encrypted and signed electronically with a Digital Certificate to establish the identity of the bidder bidding online. These Digital Certificates are issued by an Approved Certifying Authority, by the Controller of Certifying Authorities, Government of India. 2.2 A Digital Certificate is issued upon receipt of mandatory identity (i.e. Applicant s PAN Card) and Address proofs and verification form duly attested by the Notary Public / Charted Account / Any Gazatted Officer whose stamp carrying emblem of Ashoka. Only upon the receipt of the required documents, a digital certificate can be issued. 2.3 The contractors may obtain ClassII digital certificate from any Certifying Authority or Subcertifying Authority authorized by the Controller of Certifying Authorities or may obtain information and application format and documents required for the issue of digital certificate from:

8 M/s NexTenders (India) Pvt. Ltd. YUCHIT, Juhu Tara Road, Mumbai or Nex Tenders (India) Pvt. Ltd. O/o PWD (B&R) Haryana Nirman Sadan Building (Basement) Plot No.1, Dakshan Marg Sector 33 A, Chandigarh Tel. No Bid for a particular tender may be submitted online using the digital certificate, which is used to encrypt the data and sign the hash during the stage of bid preparation & hash submission. In case, during the process of a particular tender, the user looses his digital certificate (be it due to virus attack, hardware problem, operating system or any other problem) he will not be able to submit the bid online. Hence, the users are advised to keep a back up of the certificate and also keep the copies at safe place under proper security (for it s use in case of emergencies). 2.5 In case of online tendering, if the digital certificate issued to the authorized user of a firm is used for signing and submitting a bid, it will be considered equivalent to a noobjection certificate/power of attorney /lawful authorization to that User. The firm has to authorize a specific individual through an authorization certificate signed by all partners to use the digital certificate as per Indian Information Technology Act Unless the certificates are revoked, it will be assumed to represent adequate authority of the user to bid on behalf of the firm in HSWC tenders as per Information Technology Act The digital signature of this authorized user will be binding on the firm.

9 2.6 In case of any change in the authorization, it shall be the responsibility of management / partners of the firm to inform the certifying authority about the change and to obtain the digital signatures of the new person / user on behalf of the firm / company. The procedure for application of a digital certificate however will remain the same for the new user. 2.7 The same procedure holds true for the authorized users in a private/public limited company. In this case, the authorization certificate will have to be signed by the directors of the company. 3 Opening of an Electronic Payment Account: For purchasing the tender documents online, contractors are required to pay the tender documents fees online using the electronic payments gateway service. For online payments, please refer to the Home page of the etendering Portal 4 Set up of machine: In order to operate on the electronic tender management system, the user s machine is required to be set up. A help file on setting up of the system can be obtained from M/s Nextenders (India) Pvt. Ltd. or can be downloaded from the home page of the website 5 Online Viewing of Detailed Notice Inviting Tenders: The contractors can view the detailed N.I.T and the time schedule (Key Dates) for all the tenders floated through the electronic tendering system on the HSWC s etenders website 6 Download of Tender Documents: The tender documents can be downloaded from the Electronic Tendering System through the Portal 7 Key Dates:

10 The contractors are strictly advised to follow dates and times as indicated in the Notice Inviting Tenders. The date and time will be binding on all contractors. All online activities are time tracked and the system enforces time locks that ensure that no activity or transaction can take place outside the start and end dates and the time of the stage as defined in the Notice Inviting Tenders. 8 Bid Preparation (Technical & Financial) Online Payment of Tender Document Fee and Submission of Bid Seal (Hash) of online Bids: 8.1 The Payment can be made by eligible / contractors online directly through Credit Cards / Internet Banking Accounts / Cash Cards. The contractors have to pay the cost of the tender documents online by making online payment of tender document fees using the service of the secure electronic payment gateway. The secure electronic payments gateway is an online interface between contractors and credit card / online payment authorization networks. 8.2 Submission of bids will be preceded by submission of the digitally signed bid seal (Hash) as stated in the time schedule (Key Dates) of the Tender. 9 Generation of Super Hash: After the submission of Bids (Hash) by the Contractors, the bidding round will be closed and a digitally signed Super Hash will be generated by the authorized HSWC officers. This is equivalent to sealing the tender box. 10 Submission of actual online bids: Contactors have to submit their encrypted bids online and upload the relevant documents for which they generated the hash at the stage of hash generation & submission after the generation of Super Hash. The process is required to be completed within the date and time as stated in the Notice Inviting Tenders (Key Dates). The electronic bids of only those contactors who have submitted their bid seals (Hashes) within the stipulated time, as per the tender time schedule (Key Dates), will be accepted by the system. A contractor who does not submit his bid seal (Hash) within the stipulated time will not be allowed to submit his bid.

11 Note:Bidders participating in etendering shall check the validity of his/her Digital Signature Certificate before bidding in the Tenders floated online at etendering portal of HSWC s website CONDITIONS OF CONTRACT Clause1 Clause2 Security deposit. At the time of making payments to the contractor, a sum at the rate of 10% (or such other percentage as may be prescribed ) of the gross amount of each running bill shall be deducted till the cumulative amount of deduction along with the amount of earnest money already deposited reaches 5%(or such percentage as may be prescribed) of the tendered value. Onehalf of the security deposit will be refunded on completion of the work/issue of taking over certificate, and the other half will be released one year after expiry of the defects Liability Period. The contractor shall have the option to replace the 2 nd half of the retention money with unconditional bank guarantee for the desired period. For minor works 100% security deposit may be released after defects liability period is over. The successful tenderer will furnish performance security (5% of the contract price or such percentage as may be prescribed) which may be in the form of bank guarantee, to be kept as a surety that the contractor completes the work satisfactory. Initially, the performance guarantee will be valid up to end of the defects liability period plus 30 days or as prescribed in the contract data. In case the time of completion is enlarged, the validity of the guarantee shall be correspondingly extended. It carries no interest and is returned to the contractor after the date specified in the contract. Compensation of Delay : The time allowed for carrying out the work as entered in the tender shall be strictly observed by the contractor and shall be reckoned from the date on which the order to commence work is given to the contractor. The work shall through out the stipulated period of the contract be proceeded with all due diligence (time being deemed to be the essence of the contract on the part of the contractor) and the contractor shall pay as compensation an amount equal to one percent which the Executive EngineerinCharge may levy on the estimated cost of the whole work as shown by the tender for everyday that the work remains uncommenced or unfinished, after the proper dates. And further to ensure good progress during the execution of the work the contractor shall be bound in all such cases in which the time allowed for any work exceeds one month to, complete one fourth of the whole of the work before one

12 fourth of the whole of time allowed under the contract has elapsed, one half of the work before one half of such time has elapsed and threefourth of the work before three fourth such time has elapsed. In the event of the contractor failing to comply with this condition, he shall be liable to pay as compensation, an amount equal to one percent which the ExecutiveEngineerin Charge may levy on the said estimated cost of the whole work for everyday that the due quantity of work remains incomplete. Provided always that the entire amount of compensation to be paid under the provisions of this clause shall not exceed ten percent of the estimated cost of work as shown in the tender. The Managing Director HSWC, Panchkula may on representation from the contractor, reduce the amount of compensation and his decision, in writing shall be final. Clause3 Action when whole of security deposit is forfeited: In any case in which under any clause in the contract, the contractor shall have rendered himself liable to pay any compensation to the Executive Engineer on behalf of the Haryana State Warehousing Corporation shall have power to adopt any of the following courses, as he may deem best suited in the interest of Haryana State Warehousing Corporation: (a) (b) (c) To rescind the contract of which rescission notice in writing to the contractor under the hand of the Executive Engineer shall be conclusive evidence and in such case the security deposit of the contractor shall stand forfeited and belong absolutely to the Haryana State Warehousing Corporation. To employ labour paid by the Haryana State Warehousing Corporation to supply material to carry out the work or any part of the work debiting the contractor with the cost of the labour and the price of the materials (for the amount a certificate of the Executive Engineer shall be final and conclusive, against the contractor) and crediting him with the value of the work done in all respects in the same manner and at the same rate as if it had been carried out by the contractor under the terms of his contract. The certificate of Executive Engineer as to the value of the work done shall be final and conclusive against contractor. To measure up the work of the contractor, and to take such part there of as shall be unexecuted out of his hands and to gives it to another contractor to complete, in which case any expenses which may be incurred in excess of the sum which would have been paid to the original contractor of the whole work has been executed by him (for the amount the certificate in writing of the Executive Engineer shall be final and conclusive) shall be borne and paid by the original contractor and may be deducted from any money due to him by Haryana State Warehousing Corporation under the contract or otherwise or from his security deposit.

13 In the event of any of the above courses adopted by the Executive Engineer, the contractor shall have no claim for the compensation for any loss sustained by him by reason of his having purchased or procured any materials or entered into any engagement or made any advance on account or with a view to the execution of the work or the performance of the contract and in case the contract shall be rescinded under the provision aforesaid the contractor shall not be entitled to recover or be paid any sum for any work thereof, actually performed under this contract unless and until the Executive Engineer have certified, in writing, the performance of such work and the value payable in respect, thereof, and he shall only be entitled to be paid the value so certified. Clause 4 Contractor remains liable to pay compensation if action not taken under clause 3: In any case in which any of the powers conferred upon the Executive Engineer by clause 3 hereof shall have become exercisable and the same shall not exercised the nonexercise there of shall not constitute a waiver of any of the condition thereof and such powers shall not withstanding be exercisable in the event of any future case of default by the contractor for which by any clauses thereof he is declared liable to pay compensation amounting to the whole of his security deposit and the liability of contractor, for past and future compensation shall remain unaffected. Power to take possession or require removal or sell contractor's plant: In the event of the Executive Engineer putting in force either of the power (a) or (c) vested in him under the proceeding clause he may, if he so desire to take possession of all or any tools, plant, materials and stores in or upon the works, or at the site thereof or belonging to the contractor or procured by him and intended to be used for execution of the work or any part thereof paying or allowing for the same on account at the contract rates, in case of these not being applicable at current market rates to be certified by the Executive Engineer where certificate thereof shall be final, otherwise the Executive Engineer may by notice, in writing, to the contractor or his clerk of the work, foreman or other authorized agent require him to remove such tools, plants, materials or stores from the premises within a time to be specified in such notice and in the event of the contractor failing to comply with any such requisition, the Executive Engineer may remove them at the contractor s expense or sell them by auction or private sale, on account of the contractor and at his risk in all respect and the certificate of the Executive Engineer to the expenses for such removal and the amount of the proceeds and expenses, if any, shall be final and conclusive against the contractor. Clause 5 Extension of time: If the contractor desire an extension of the time for completion of the work on the ground of his having been unavoidably hindered in its execution or on any other ground, he shall apply, in writing, to the Executive Engineer within 30 days of the date of the hindrance but before the expiry of the contractual period on account of which

14 and Road Branch rates for that District EE he desires such extension as aforesaid and the competent authority shall, if in his opinion (which shall be final reasonable ground) be shown therefore authorize such extension of time if any so may in his opinion be necessary or proper. Clause5(a) Contractor to submit a return every month on any work claimed as extra: The contractor shall deliver in the office of the Executive Engineer on or before 10 th day of every month during the continuance of the work covered by this District rate mean contract a return showing details of any work claimed for as extra and such return shall contain the value of such work the as claimed by the contractor, which value shall be based upon the prices in the contract or in Schedule of rates inforce Haryana in the District for the time being. The contractor shall include in such monthly return particulars of all claims of PWD whatsoever kind. However arising which at the date thereof, he has or may claim to have against the Executive Building Engineer under or in respect of or in any manner, arising out of the execution of work and the contractor shall be deemed to have waived all claims not included in such return and will have no right to enforce any such claim not so included whatsoever be the circumstances. Clause6 Final Certificate Without prejudice to the right of Haryana State Warehousing Corporation, under any clause hereinafter contained on completion of the work, the contractor shall be furnished with the certificate by the Executive Engineer (hereinafter called the Engineerincharge) of such completion, but no such certificate shall be given nor work shall be considered to be completed until the contractor shall have removed from the premises on which the work shall be executed all scaffolding, surplus materials and rubbish and clean off dirt from all wood works, floor, other parts of any building in, upon or around which the work is to be executed, or part of which he had in possession for the purpose of the execution thereof and the measurements in the said certificate shall be binding and conclusive against the contractor. If the contractor shall fail to comply with the requirements of this clause as to removal of scaffolding surplus materials and rubbish and cleaning of dirt on or before the date fixed for the completion of the work, the Engineerincharge at the expense of the contractor shall remove such scaffolding, surplus materials and rubbish and dispose of the same as he may think fit and clean off such dirt as aforesaid and the contractor shall pay the amount of all expenses so incurred and shall have no claim in respect of any such scaffolding or such surplus materials as aforesaid except for any sum actually realized on account of sales, thereof.

15 Clause7 Payments on intermediate certificates to be regarded as advances: No payment shall be made for works estimated to cost less than Rs. One thousand, till the whole of the works shall have been completed and the certificate of completion given. But in the case of work estimated to cost more than Rs. One thousand the contractor not submitting the bill thereof, be entitled to receive a monthly payment proportionate to the part thereof as approved and passed by Engineerincharge, whose certificate of such approval and passing of the sum so payable shall be final and conclusive against the contractor. But all such intermediate payment shall be regarded as payments by way of advances against the final payment only and not as payments for the works actually done and completed and shall not preclude the requiring of bad, unsound and imperfect or unskilled work to be removed and taken away and reconstructed, or reerected or be considered as an admission of due performance of the contract or any part thereof in any respect or the accruing of any claim. Nor shall it conclude, determine or effect in any way the powers of the Engineerincharge under these terms and conditions or any of them as far the final settlement and adjustments of the accounts or otherwise or in any other way vary or effect the contract. The final bill shall be submitted by the contractor within one month of the date fixed for completion of the work, otherwise the Engineerincharge s certificate of the measurements and the total amount payable for work, accordingly, shall be final and binding on all parties. The amount, payable, however, shall be determined after preaudit of the bill by the accounts Departments authorities within fifteen days of the presentation of the bill by the Engineerincharge to Accounts Department, otherwise the amount already determined by the Engineerincharge shall become binding on both parties. Both the Engineerincharge and the Accounts Department shall inform the contractors by registered post about the facts of the movement of the final bill and the amount thereof. Clause7 (a) The deduction referred to in ClauseI herein before or such part thereof as may be due to contractor under this contract shall be payable to contractor after a period of three months has lapsed after the payment of final bill. Clause8 Bills to be submitted monthly: A bill shall be submitted by the contractor each month on or before the date fixed by the Engineerincharge for all work executed in the previous month and the Engineerincharge shall take the requisite measurement for the purpose of having the same verified and the claim, as far as admissible, adjusted if possible, before the expiry of ten days from the presentation of the bill. If the contractor do not submit the bill within the time fixed as aforesaid, the Engineerincharge may depute a subordinate to measure up the said work in the presence of the contractor whose counter signature to the measurement list will be sufficient and the Engineerincharge may prepare, a bill from such list which shall be binding on the contractor in all respect.

16 Clause9 Clause 10 Clause 11 Bills to be on printed forms: The contractors shall submit all bills, in triplicate, on printed forms to be had on application from the office of the Engineerincharge and the charge in the bill shall always be entered at the rates specified in the tender or in the case of any extra works ordered in pursuance of these conditions and not mentioned or provided for in the tender at the rate hereinafter provided for such work. If the specification of estimate of the work provides for the use of any special description of materials to be supplied from Engineerincharge s store or if it is required that contractor shall use certain store to be provided by the Engineerincharge (such materials and stores and the prices to be charged thereof as hereinafter mentioned being so far as practicable for the convenience of the contractor, but not so in any way to control the meaning for effect of this contract specified in the schedule or memorandum hereto annexed) the contractor shall be supplied with such materials and stores required from time to time to be used by him for the purpose of the contract only and the value of the full quantity of the materials and stores so supplied at the rates specified in the said schedule of memorandum may be set off or deducted from any sums due or thereafter to become due, to the contractor under the contract or otherwise against or from the security deposit. Materials supplied to the contractor shall remain the property of the HSWC and shall be kept in safe custody of contractor but shall not on any account be removed from the site of the work without the written permission of the Engineerincharge & shall all times be opened for inspection by him. Any such materials unused and in perfectly good condition at the time of the completion of the contract shall be returned to the Engineerincharge s store if by a notice, in writing, under his hand he shall so require, but the contractor shall not be entitled to return any such materials without such consent and shall have no claims for compensation on account of any such materials to be supplied to him as aforesaid being unused by him, or any wastage in or damage to any such materials. Works to be executed in accordance with specifications drawing orders etc: The contractor shall execute the whole and every part of the work in most substantial and workmen like manner, both as regards to materials and otherwise in every respect in strict accordance with Haryana P.W.D. specification latest edition / specifications as may be specifically provided for. The contractor shall also confirm exactly, fully and faithfully to the designs, drawing and instructions in writing relating to the work (signed by the Engineer incharge) and lodged in the office and to which the contractor shall be entitled to have access at his office or at the site of the work. For the purpose of inspection during office hours, the contractors shall if he so requires, be entitled at his own expenses to make or cause to be made copies of the specifications and of all such designs and instruction as aforesaid.

17 Clause11A Removal of employee workman and foreman: The Engineerincharge shall have full powers at all time to object to the employment of any workman, Foreman or other employees on the works by the contractor and if the contractor shall receive notice in writing from the Engineerincharge requesting the removal of such workman from the work, the contractor shall comply with the request forth with. No such workman, foreman or other employees after his removal from the works by orders of the Engineerincharge shall be reemployed or engaged on the works by the contractor at any time, except with the prior approval, in writing, from the Engineerincharge. The contractor shall not be entitled to demand the reason from the Engineerincharge, requiring the removal of any such workman or other employees. Clause 12 Alterations in specifications and designs: The Engineerincharge shall have power to make any alteration or omission or additions from the original specifications, drawings designs, and instructions that may appear to him to be necessary or advisable during the progress of the work and the contractor shall be bound to carry out the work in accordance with the instructions given to him, in writing, duly signed by the Engineerincharge and such alterations omissions, additions or substitutions shall not invalidate the contract & any altered, additional or substituted work which the contractor may be directed to do in the manner above specified as part of the work shall be carried out by the contractor on the same rates, terms & conditions on which he agreed to do the main work. The time for the completion of the works shall be extended in the proportion that the altered, additional or substituted works bears to the original contract work and certificate of the Engineerincharge shall be conclusive as to such proportion. If the altered, additional or substituted work includes any class of work for which no rate is specified in this contract, then such class of work shall be carried out at the rate entered in the Haryana schedule of rates, subject to the same percentage above or below for items and if such class or work is not entered in the Haryana PWD Schedule of rates, then the contractor shall within seven days of the date of his receipt of the order to carry out the work, inform the Engineerincharge of the rate, which it is his intention to charge for such class of work. If Engineerincharge does not agree to his rate, he shall by notice, in writing, be at liberty to cancel his order to carry out such class of work and arrange to carry it out in such manner as he may consider advisable, provided always that the contractor shall commence the work or incur any expenditure in regard thereto before the rates shall have been determined herein before mentioned and in such case he shall be entitled to be paid in respect of the work carried out or expenditure incurred by him prior to the date of the determination of the rates as aforesaid according to such rate or rates as shall be fixed by the Engineerincharge. In the event of a dispute, the decision of the respective Managing Director, HSWC shall be final.

18 Clause 13 Clause 14 Clause 15 No compensation for alternation in or restriction of work to be carried out: If at any time, after the commencement of the work, the Haryana State Warehousing Corporation shall for any reason whatsoever not require the whole work thereof as specified in the tender to be carried out, the Engineerincharge shall give notice, in writing, of the fact to the contractors who shall have no claim to any payment or compensation, whatsoever on account of any profit or advantage which he might have derived from execution of the work in full which he did not drive in consequence of the full amount of the work not having been carried out, neither shall have any claim for compensation by reason of any alteration having been made in the original specification, drawing, designs and instructions which shall involve any curtailment of the work originally contemplated. Action and compensation payable in case of bad work: If it shall appear to the Engineerincharge or his subordinateincharge of the work, that any work has been executed with unsound, imperfect or unskillful workmanship or with material of any inferior description or that any material or article provided by him for the execution of the work are unsound or of a quality inferior to the contract or otherwise not in accordance with the contract, the contractor shall on demand, in writing, from the Engineerincharge specifying the work, materials or articles complained or not withstanding that the same may have been inadvertently passed, certified and paid for the forthwith rectify or removed and reconstruct the work so specified in whole or in part as the case may require or as the case may be, remove the materials or articles so specified and provide other proper and suitable materials or article at his own charge and cost. In the event of its failing to do so within a period to be specified by the Engineerincharge in his demand aforesaid then the contractor shall be liable to pay compensation at the rate of one percent on the amount of estimate of everyday not exceeding ten days, while his failure to do so shall continue and in case of any such failure the Engineerincharge may rectify or remove and reexecute the work or remove and replace with other materials or articles complained of, as the case may be, at the risk and expense of the contractor. Work to be open to inspections, contractor or his responsible agent to be present: All works under or in course of execution or executed in pursuance of the contract shall at all times be open to the inspection and supervision of the Engineerincharge and his subordinates and the contractor shall at all times, during the usual working hours and at all other time with reasonable notice of the inspection of the Engineerincharge or his subordinates to visit the work shall have been given to the contractor either himself be present to receive orders and instruction, or have a responsible agent duly authorized, in writing, present for that purpose. Orders given to the contractor s agent shall considered to have the same force as they had been given to the contractor himself.

19 Clause 16 Clause 17 Clause 18 And be liable for damage arising non provision of lights and fencing etc. Notice to be given before work is covered up: The contractor shall give not less than five days notice in writing to the Engineerincharge or his subordinateincharge of the work before covering up or otherwise placing beyond the reach of measurement any work in order that same may be measured and correct dimensions thereof be taken before the same is so covered up or placed beyond the reach of measuring and shall not cover up or place beyond the reach of measurement without the consent, in writing, of the Engineerincharge or his subordinateincharge of the work. If any work shall be covered up or placed beyond the reach of measurement such notice having been given or consent obtained, the same shall be uncovered at the contractor's expense, or in default thereof no payment or allowance shall be made for such work or the materials with which the same was executed. Contractor liable for damage done and for imperfections for 1 2 months after certificate: If the contractor or his work people or servants shall break, deface, injure or destroy any part of a building in which they may be working, on any building, Road, Fence, enclosure or grass, land, cultivated ground or the premises on which the work or any part of it is being executed, or if any damage happens to the work, while in progress from any cause whatever or any imperfection become apparent in it within three months after the final certificate or order of its completions, shall have been given by the Engineerincharge as aforesaid, the contractor shall make the same good at his own expenses and in default, the Engineerincharge may cause the same to be made good by other workmen and deduct the expense (of which the certificate of the Engineerincharge shall be final) from any sums that may be then, or at any time thereafter, may become due to the contractor or from his security deposit. Contractor to supply plant ladders, scaffoldings etc: The contractor shall supply at his own cost all material except such special material, in accordance with the contract be supplied from the Engineerincharge s stores, plants, tools appliances, ladders, cordage, scaffolding and temporary works required for proper execution of the work, whether original, altered or substituted and whether included in the specifications or other documents forming part of the contract referred to in these conditions or not, or which may be necessary for the purpose of satisfying or complying with the requirements of the Engineerincharge, as to any matter as to which, under these conditions he is entitled to be satisfied or which he is entitled to require together with carriage thereof to and from the work. The contractor shall also supply without charge the requisite number of persons with the means and materials, necessary for the purpose of setting out works and counting, weighing and assisting in the measurement of examination at any time and from time to time of the work or material. Failing to do so, the same may be provided by the Engineerincharge at the expenses of the contractor, and the expense may be deducted from any money due to the contractor under the contract or from any other contract of the agency or from his security deposit or the proceeds of sale thereof or a sufficient portions thereof.

20 The contractor shall also provide all necessary fencing & lights required to protect the public from accident and shall be bound to bear the expenses of defence of every suit, actions or other proceedings at law that may be brought by any person for injury sustained owing to neglect of the above precautions and to pay any damages and cost which may be awarded in any such suit, action or proceedings to any such person or which may with the consent of the contractor be paid to compromise any claim by any such person. Clause 19 No female labour shall be employed within the limits of Cantonment. Clause 19A No labour below the age of 12 years shall be employed on the work.. Clause 19B The contractor shall pay his labourer not less than the wages determined under minimum wages act for the District. Clause 20 Work on Sunday: No work shall be done on Sunday without the sanction, in writing, of Engineerincharge. Clause 20A Contractor liable for payment of compensation to injured workman or in case of death to his relations: In every case in which by virtue of the provision of section 12, sub section (1) of the workmen s compensation Act, Haryana State Warehousing Corporation is obliged to pay compensation to workman employed by the contractor, in execution of the works. Haryana State Warehousing Corporation will recover from the contractor the amount of the compensation so paid and without prejudice to the right of Haryana State Warehousing Corporation under section 12, sub section (2) of the said acts, Haryana State Warehousing Corporation shall be at liberty to recover such amount or any part thereof by deducting it from the security or from any sum due to the contractor, whether under this contract or otherwise. Haryana State Warehousing Corporation shall not be bound to contest any claim made against it under section 12 subsection (1) of the said act except on the written request of the contractor and upon his giving request to Haryana State Warehousing Corporation full security for all costs for which Haryana State Warehousing Corporation might become liable in consequence of contesting such claim. Clause 21 Work not be sublet. Contract may be rescinded and security deposit forfeited: The contract shall not be assigned or sublet without the written approval of the Engineerincharge. And if the contractor shall reassign or sublet his contract or attempt to do so or become insolvent or commence any insolvency proceedings or make any composition with his creditors or attempts to do so or if any bribe, gratuity, gift, loan, reward or otherwise, shall either directly or indirectly be given, promised or offered by the contractor or any of his servants or agents to any public officer or person

21 in the employment of Haryana State Warehousing Corporation, in any way relating to his office or employment or if any such officer or person shall become in any way directly or the indirectly interested in the contract, the Engineerincharge may thereupon by notice, in writing, rescind the contract and security deposit of the contractor shall stand forfeited and be absolutely at the disposal of Haryana State Warehousing Corporation. The same consequence shall ensure as if the contract had been rescinded under clause 3 thereof and in addition the contractor shall not be entitled to recover or be paid for any work thereof actually performed under the contract. Clause 22 Sum payable by way of compensation to be considered as reasonable compensation without reference to actual loss: All sums payable by way of compensation under any of these condition shall be considered as reasonable compensation without reference to the actual loss or damage sustained and whether or not any damage shall have been sustained. Clause 22A Deduction of amounts due to Government on any account whatsoever to be recoverable from sums payable to a contractor: Any excess payment made to the contractor inadvertently or otherwise under this contract or on any account whatsoever and any other sum found to be due to Haryana State Warehousing Corporation by the contractors in respect of this contract or any other contract or work order for any sum whatsoever shall be recoverable from the contractor from the payment due to him either in respect of this contract or any other work order or contract or any other account by any other department of the Haryana Government / Haryana State Warehousing Corporation. Clause 23 Clause 24 Clause 25: Changes in constitution of firm: In the case of a tender by partners, any change in the constitution of the firm shall be forthwith notified by the contractor to the Engineerincharge for his information. Work to be under directions of Executive Engineer: All works to be executed, under the contract shall be executed under the directions of and subject to the approval of the Executive Engineer, Haryana State Warehousing Corporation Panchkula for the time being who shall be entitled to direct at what point or points and in what manner they are to be commenced or from time to time carried on. Claims for payment of any extra ordinary nature to be referred to HSWC for decision: No claims for payment of an extraordinary nature, such as claims for a bonus for extra labour employed in completing the work before the expiry of the contractual period at the request of the EngineerInCharge or claims for compensation where work has been temporarily brought to a standstill with no fault of the contractor, shall be allowed unless and to the extent that the same shall have been sanctioned by the Haryana State Warehousing Corporation.

22 Clause 25(A): (i) If any dispute or difference of any kind whatsoever shall arise between the HSWC/or authorized representative of HSWC and the contractor in connection with or arising out of the contract, or the execution of the work that is (i) whether before its commencement or during the progress of the work or after its completion, (ii) and whether before or after the termination, abandonment or breach of the contract, it shall, in the first instance, be referred to, for being settled by the Executive EngineerInCharge of the work at that time and E x e c u t i v e EngineerInCharge shall with in a period of sixty days after being requested, in writing, made by the contractor to do so, convey his decision to the contractor, and subject to arbitration as hereinafter provided, such decision in respect of every matter so referred, shall be final and binding upon the contractor. In case the work is already in progress, the contractor will proceed with the execution of the work on receipt of the decision by the Executive EngineerIncharge as aforesaid, with all due diligence whether HSWC/or authorized representative of HSWC or contractor requires arbitration as hereinafter provided for, or not. If the Executive Engineer, In charge of the work has conveyed his decision to the contractor and no claim to arbitration has been filed with him by the contractor within a period of sixty days from the receipt of letter communicating the decision, the said decision shall be final and binding upon the contractor and will not be a subject matter of arbitration at all. If the Executive Engineer, Incharge of the work fails to convey his decision within a period of sixty days, after being requested, as aforesaid, the contractor may, within further sixty days of the expiry of first sixty days, after being requested, from the date on which request has been made to the Executive Engineer InCharge request the Managing Director, HSWC that the matters in dispute be relevant to arbitration, as hereinafter provided. (ii) Or All dispute or difference in respect of which the decision is not final and conclusive shall at the request, in writing, of either party, made in a communication sent through Registered A.D. Post, be referred to arbitration, to be nominated by designation by the Managing Director, HSWC at the relevant time. There will be no objection to any such appointment that the arbitrator so appointed is a Govt. servant/in service of HSWC or that he had to deal with the matters to which the contract relates in the course of his duties as a Govt. servant/in service of HSWC he has expressed his views on all or any of the matter in dispute. The Arbitrator to whom the matters is originally referred being transferred or vacating his office, his successorinoffice, as such shall be entitled to proceed with the reference from the stage at which it was left by his predecessor. In case the arbitrator nominated by the Managing Director, HSWC is unable or unwilling to act as arbitrator such for any reason, whatsoever the Managing Director, HSWC shall be competent to appoint and nominate any other person as arbitrator in his place and the arbitrator so appointed shall be entitled to proceed with the reference.

23 (iii) (iv) EE It is also a term of this arbitration agreement that no person other than a person appointed by the Managing Director, HSWC shall act as arbitrator and if for any reason that is not possible the matter shall not be referred to arbitration at all. In all cases where the aggregate amount awarded exceeds Rs / the arbitrator must invariable give reasons for his award in respect of each claim and counter / claims separately. The arbitrator shall award separately giving his award against each claim and dispute raised by either party including any counterclaim individually and that any lumpsum award shall not be legally enforceable. (v) The following matters shall not lie within the preview of arbitration: a) Any dispute relating to the levy of compensation as liquidated damages, which has already been referred to the Managing Director and is being heard or/ and has been finally decided by the Managing Director. b) Any dispute in respect of substituted, altered, additional work/omitted work / defective work referred by the contractor for the decision of Executive Engineer of the work if it is being heard or has already been decided by the said Executive Engineer. c) Any dispute regarding the scope of the work or its execution or suspension or abandonment that has been referred by the contractor for the decision of the HSWC and has been so decided finally by the HSWC. (vi) (vii) The independent claims of the party other than the one getting the arbitrator appointed, as also counterclaims of any party will be entertained by the arbitrator notwithstanding that the arbitrator had been appointed at the instance of the other party. It is also a term of this arbitrator agreement that where the party invoking arbitrator is the contractor, no reference for arbitrator shall be maintainable unless the contractor, furnishes to the satisfaction of the Executive Engineer In charge of the work, a security deposit of a sum determined according to details given below and the sum so deposited shall, on the termination of the arbitration proceedings, be adjusted against the cost, if any, awarded by the arbitrator against the claimant party and the balance remaining after such adjustment or whole sum in the absence of any such cost being awarded will be refunded to him within one month from the date of the award.